Fairfield Connecticut Building Expert Directory

Fundamental Fairness Trumps Contract Language

September 24, 2014 — Craig Martin – Construction Contractor Advisor
The Texas Supreme Court recently ruled that a “no-damages-for-delay” clause would not be enforced where the delay was caused by the owner. The court’s ruling flies squarely in the face of the contract language that attempted to insulate the owner from any delay claims, even those it caused. In the case of Zachary Construction v. Port of Houston underlying contract, proposed by the Port of Houston, was heavy handed, to say the least. The contract provided: “[Contractor] shall receive no financial compensation for delay or hindrance to the Work. In no event shall the Port Authority be liable to [Contractor] … for any damages arising out of or associated with any delay or hindrance to the Work, regardless of the source of the delay or hindrance, including events of Force Majeure, AND EVEN IF SUCH DELAY OR HINDRANCE RESULTS FROM, ARISES OUT OF OR IS DUE IN WHOLE OR IN PART, TO THE NEGLIGENCE, BREACH OF CONTRACT OR OTHER FAULT OF THE PORT AUTHORITY. [Contractor’s] sole remedy in any such case shall be an extension of time.” Wow, that’s some one-sided language. If the contract was enforced, the contractor could not get any damages for delay, even those damages caused by the active interference of the Port of Houston. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Blackstone to Buy Apartments From Greystar in $2 Billion Deal

December 10, 2015 — Sarah Mulholland – Bloomberg
Blackstone Group LP agreed to buy 32 multifamily properties for about $2 billion from Greystar Real Estate Partners LLC as the private equity giant expands its push into the U.S. apartment market. The buildings, with a total of 10,399 units, are spread throughout the country in states such as California, Florida, Washington and New York, Greystar said in a statement Tuesday. The Charleston, South Carolina-based company, the largest U.S. apartment manager, will continue to oversee the properties. Peter Rose, a Blackstone spokesman, declined to comment on the transaction. Read the court decision
Read the full story...
Reprinted courtesy of Sarah Mulholland, Bloomberg

Art Dao, Executive Director of the Alameda County Transportation Commission, Speaks at Wendel Rosen’s Infrastructure Forum

April 01, 2015 — Garret Murai – California Construction Law Blog
On March 2, 2015, Art Dao, Executive Director of the Alameda County Transportation Commission, spoke to a packed house at the Wendel Rosen Construction Practice Group’s Infrastructure Forum on the Commission’s plans for nearly $8 billion in transportation improvement funding approved by voters this past year under Measure BB. The Alameda County Transportation Commission The Commission, which was formed in 2010 following the merger of the Alameda County Congestion Management Agency and the Alameda County Transportation Improvement Authority, serves as the congestion management agency for the County of Alameda and is responsible for planning, funding and delivering transportation programs and projects throughout the county. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Be Careful with Mechanic’s Lien Waivers

June 09, 2016 — Christopher G. Hill – Construction Law Musings
Mechanic’s liens are near and dear to my heart here at Construction Law Musings. These powerful tools can and should be properly used to help you, as a construction professional, get paid for your good work. Of course, the correct steps toward perfecting one of these liens must be followed, including being sure to meet the stringent lien deadlines. I’ve discussed the steps for filing such a lien and the various pitfalls relating to the very picky statutory requirements for recording an enforceable memorandum of lien in Virginia. One important area that I have not discussed as thoroughly as these basic requirements (and an area of which I have been reminded by my pals at the Construction Payment Blog) is the area of mechanic’s lien waivers. While the Virginia General Assembly has ended the days of pre-payment contractual waiver of mechanic’s lien rights for subcontractors and suppliers, mechanic’s lien waivers that waive rights either simultaneous with or after receipt of progress and final payments are still valid and used on a regular basis. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

First-Time Buyers Shut Out of Expanding U.S. Home Supply

August 13, 2014 — Prashant Gopal – Bloomberg
The four-bedroom house that Ilia Nielsen-Dembe purchased in west Denver earlier this year wasn’t her top choice. The first-time buyer had to settle on a home in a neighborhood with a high crime rate after losing out on bids for five properties in more desirable areas. “I definitely sacrificed in terms of location,” said Nielsen-Dembe, 33, who lives with her husband and two daughters in the house she bought in April for $184,500. “I had to cross streets that were not ideal in order to get a house.” While the supply of U.S. homes for sale is at an almost two-year high and price gains are moderating, buyers such as Nielsen-Dembe wouldn’t know it. An inventory crunch for entry-level houses has only worsened during the past year as discounted foreclosures become scarce and cash-paying investors snap up affordable listings to convert to rentals. Properties at the lower end of the market are also the most likely to have underwater mortgages, keeping would-be sellers from moving. Read the court decision
Read the full story...
Reprinted courtesy of Prashant Gopal, Bloomberg
Mr. Gopal may be contacted at pgopal2@bloomberg.net

Crane Firm Pulled Off NYC Projects Following Multiple Incidents

October 07, 2019 — Jeff Rubenstone - Engineering News-Record
Following a partial crane collapse at a site on Manhattan’s Lower East Side and a fatality in April on a jobsite in lower Manhattan, the New York City Dept. of Buildings announced on Aug. 12 that it is suspending United Crane & Rigging’s work on 21 construction sites across the city. Jeff Rubenstone, Engineering News-Record Mr. Rubenstone may be contacted at rubenstonej@enr.com Read the court decision
Read the full story...
Reprinted courtesy of

California Booms With FivePoint New Schools: Real Estate

May 13, 2014 — John Gittelsohn – Bloomberg
FivePoint Communities Management Inc. is already constructing a school at its Great Park Neighborhoods project in Irvine, California, for 1,000 elementary and middle school students even as it’s still building the first 700 homes. “We build the schools ahead of time,” said Emile Haddad, chief executive officer of Aliso Viejo, California-based FivePoint, which has permits for about 10,000 homes at Great Park. “That way we always have them ready.” Local schools, along with parks and recreation facilities, have long been draws for buyers in new communities. Now, as school districts face tight construction budgets and homebuilders compete to attract families able to qualify for mortgages, developers are taking the lead on school construction instead of waiting for local governments to do the job. Read the court decision
Read the full story...
Reprinted courtesy of John Gittelsohn, Bloomberg
Mr. Gittelsohn may be contacted at johngitt@bloomberg.net

Faulty Workmanship an Occurrence in Iowa – as Long as Other Property Damage is Involved

November 30, 2016 — Austin D. Moody – Saxe Doernberger & Vita, P.C.
The Eighth Circuit recently weighed in on one of the more contentious issues in insurance coverage litigation: is faulty workmanship an occurrence? In Decker Plastics Inc. v. West Bend Mut. Ins. Co., the Eighth Circuit ruled that, under Iowa law, faulty workmanship is an occurrence – as long as it leads to other property damage. Read the court decision
Read the full story...
Reprinted courtesy of Austin D. Moody, Saxe Doernberger & Vita, P.C.
Mr. Moody may be contacted at adm@sdvlaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES