Fairfield Connecticut Building Expert Directory

Housing Markets Continue to Improve

February 11, 2013 — CDJ STAFF
The National Association of Home Builders reports that for a sixth consecutive month there has been an increase in the number of housing markets that have shown improvement. The January report saw 242 improving markets, which in February grew to 259. The NAHB notes that there are now improving markets in every state, “suggesting that the housing recovery has substantial momentum.” Not all markets showed continued improvement. Three metropolitan areas were dropped from the list of improving markets, but another twenty were added. The NAHB has been tracking this data since September 2011, when there were only twelve improving markets through the whole country. Read the court decision
Read the full story...
Reprinted courtesy of

Recommencing Construction on a Project due to a Cessation or Abandonment

October 26, 2017 — David Adelstein - Florida Construction Legal Updates
There are instances where the owner of a construction project terminates its general contractor prior to the completion of the project. There are instances where the owner suspends the work prior to the completion of the project, meaning there is a cessation in the construction. And, there are instances where the project is simply abandoned. I have been involved in all instances, and the owner’s reasons vary…from an owner claiming a termination for default, termination for convenience, or a suspension or abandonment due to the market or financial factors. Regardless of the owner’s reasoning, at some point—hopefully—the owner will want to resume or, more properly stated, recommence construction and complete the project. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at Dadelstein@gmail.com

No Repeal Process for Rejected Superstorm Sandy Grant Applications

February 12, 2014 — Beverley BevenFlorez-CDJ STAFF
Even though it’s been revealed that “faulty data” was used to reject many New Jersey recovery grants for victims of Superstorm Sandy, the state has announced that it’s too late to appeal, according to The Wall Street Journal. “The applicants were informed by letter that they weren't eligible,” state officials told The Wall Street Journal, “and it should have been clear that they needed to appeal last year, so the application process won't be reopened.” The majority of the rejected applicants that did appeal within the open period were found to be eligible for the grant: “Nearly 80% of people who appealed their rejections ended up winning their cases, according to data released by the Fair Share Housing Center, a public-interest law firm critical of the Christie administration. And of the 8,007 applicants rejected from both programs, 5,583 didn't appeal, or 70%, according to Fair Share Housing Center's analysis.” U.S. Representative Bill Pascrell called for “an independent monitor” to be “appointed to oversee the state’s storm spending ‘to ensure there isn’t further mismanagement.’” Read the court decision
Read the full story...
Reprinted courtesy of

Ten-Year Statute Of Repose To Sue For Latent Construction Defects

November 12, 2019 — David Adelstein - Florida Construction Legal Updates
If you are dealing with latent construction defects, it is imperative that you consult with counsel to understand your rights. This not only includes claims for property damage stemming from latent construction defects, but also personal injury stemming from such defects. There is a ten-year statute of repose to sue for latent construction defects. See Fla.Stat. s. 95.11(3)(c). After the expiration of this statute of repose you are out of luck, meaning you can no longer sue. Now, I probably will not be the first to tell you that the statute of repose is not written so clear that you know the precise date it ends (or the last date you can sue for a latent defect). For this reason, you really want to operate conservatively, meaning it is always better to sue early if you think you could be running on the end of the statute of repose period. It is always advisable to avoid any legitimate argument that you filed your construction defect lawsuit too late. In Harrell v. The Ryland Group, 44 Fla. L. Weekly D2054b (Fla. 1st DCA 2019), a subsequent owner of a house sued the original homebuilder in negligence for a construction defect causing a personal injury. The subsequent owner claimed the homebuilder defectively installed an attic ladder (that provided access to the attic for the original construction) which collapsed as he was using it. The homebuilder filed a motion for summary judgment that the statute of repose expired so the owner’s claim was time-barred. The First District agreed. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Fire Damages Unfinished Hospital Tower at NYU Langone Medical Center

December 15, 2016 — Jeff Rubenstone – Engineering News-Record
A fire broke out Dec. 14 at a hospital tower under construction at NYU Langone Medical Center in New York City. The blaze sent a column of thick black smoke up through the Manhattan skyline. Read the court decision
Read the full story...
Reprinted courtesy of Jeff Rubenstone, Engineering News-Record
Mr. Rubenstone may be contacted at rubenstonej@enr.com

Defining Constructive Acceleration

March 22, 2021 — David Adelstein - Florida Construction Legal Updates
When it comes to the definition of “constructive acceleration,” the case of Fraser Const. Co. v. U.S., 384 F.3d 1354 (Fed.Cir. 2004) is a cited case and contains an instructive definition, quoted below, for proving a constructive acceleration claim. In a nutshell, a constructive acceleration claim is when the contractor incurs added costs for trying to complete the contract on time when it should be provided extensions of time to perform based on excusable delay (i.e., delay not caused by the contractor). These added costs could be bringing in additional supervision to manage the work, adding manpower to perform the work, working overtime, working weekends, adding more shift work, stacking trades, etc. However, just because a contractor claims they have been constructively accelerated does not make it so. The contractor has to actually ask for an extension of time based on an excusable delay and the owner either denied the extension or unreasonably sat on the request for an extension of time; thus, the contractor incurred significant costs to accelerate in order to finish the project on time because it was deprived of a requested time extension for excusable delay. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Want to Build Affordable Housing in the Heart of Paris? Make It Chic.

November 01, 2022 — Marie Patino & Kriston Capps - Bloomberg
The project at 12 Rue Jean-Bart is a modest one, just eight units of affordable housing on a narrow lot in Paris near the Luxembourg Gardens. The social housing project nevertheless caused a stir with neighbors in the 6th arrondissement, one of the city’s more affluent areas. When local politicians backing the project came to visit the building during its construction, neighbors shouted from windows across the street that it was a shame to build social housing here, according to Jean-Christophe Quinton, the Paris-based architect who designed the small in-fill development. Local resistance was a persistent feature of the project throughout its three-year-long construction, Quinton says; the building regularly faced harsh scrutiny in local newspaper Le Parisien. Reprinted courtesy of Marie Patino, Bloomberg and Kriston Capps, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

Why Should Businesses Seek Legal Help Early On?

December 03, 2024 — Scott L. Baker - Los Angeles Litigation Blog
Most business owners are natural problem solvers. They assess the issue that lies before them and develop a strategy to overcome it. It’s a critical mindset to have, but do all business owners have the skillset to solve every issue? While it is understandable that business owners may want to attempt to resolve issues on their own, it is invariably beneficial to obtain guidance for legal issues earlier rather than later. 3 Reasons to Consult an Attorney Sooner than Later Many people might consider working with an attorney to be a last resort. Typically, this is not the case; rather, getting knowledgeable legal counsel sooner than later can help business owners because:

It’s Cheaper: Early legal intervention can often prevent disputes from leading to litigation, which can be expensive. Working with an attorney to resolve a conflict before it escalates into a larger issue is often a good business decision and wise investment.

Read the court decision
Read the full story...
Reprinted courtesy of Scott L. Baker, Baker & Associates
Mr. Baker may be contacted at slb@bakerslaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES