Fairfield Connecticut Building Expert Directory

ZLien Startup has Discovered a Billion in Payments for Clients

March 19, 2014 — Beverley BevenFlorez-CDJ STAFF
The New Orleans startup company zlien “tracks liens for contractors through an online service” and has “secured more than $1 billion in payments for clients on 33,000 construction projects” according to its founder Scott Wolfe, as reported by The Times-Picayune. When Wolfe practiced law, he noticed “an absence of any centralized service to help firms comply with lien procedures.” Wolfe “saw construction companies hiring small operators, in what he called ‘a very manual, service business,’ to track liens in different states, running the process inconsistently or failing to collect on some liens at all.” Wolfe has entered zlien into “New Orleans Entrepreneur Week on March 28 for the Coulter IDEAPitch, a business competition in front of what The Idea Village organizers describe as an invitation-only audience of ‘world-class investors’ focused on ventures with high growth prospects.” Wolfe told The Times-Picayune that “not getting paid is a central problem in construction. That is something that really strains the construction industry." Read the court decision
Read the full story...
Reprinted courtesy of

Governmental Action Exclusion Bars Claim for Damage to Insured's Building

November 27, 2023 — Tred R. Eyerly - Insurance Law Hawaii
The lower court's decision finding no coverage based upon the governmental action exclusion was affirmed by the Appellate Court of Illinois. McCann Plumbing, Heating & Cooling v. Pekin Ins. Co., 2023 Ill.App. LEXIS 300 (Ill. App. Ct. Aug. 23, 2023). McCann purchased a building to use for its heating, ventilation, and air conditioning business. The building was surrounded by two unihhabited properties which often flooded. The city determined that a building on the adjacent property had to be demolished. In the course of destruction, the McCann's building was damaged, leaving a portion of their building open to the elements. McCann sought coverage from Pekin for damage incurred in the demolition. The policy provided coverage for "direct physical loss of or damage to" the covered property. Pekin denied coverage under the policy's governmental action exclusion, which provided,

We will not pay for loss or damage caused directly or indirectly by any of the following: . . . c. Governmental Action Seizure or destruction of property by order of governmental authority . . .

Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Persimmon Offers to Fix Risky Homes as Cladding Crisis Grows

February 22, 2021 — Olivia Konotey-Ahulu - Bloomberg
Persimmon Plc, the U.K.’s biggest homebuilder, has offered to pay for work on potentially unsafe buildings in the wake of the cladding scandal that arose from London’s Grenfell Tower fire. The firm has made a provision of 75 million pounds ($104 million) in its 2020 results for any necessary repair work on 26 buildings it developed that may be affected by the issue, it said in a statement Wednesday. It no longer owns the properties and said it would provide support where owners failed to accept their legal responsibilities. “The concern around now banned cladding is affecting many thousands of homeowners who live in high-rise buildings right across the country,” Chairman Roger Devlin said in the statement. “We believe we have a clear duty to act to address this issue.” Read the court decision
Read the full story...
Reprinted courtesy of Olivia Konotey-Ahulu, Bloomberg

Ruling Dealing with Constructive Changes, Constructive Suspension, and the Implied Covenant of Good Faith and Fair Dealing

January 22, 2024 — David Adelstein - Florida Construction Legal Updates
A dispute pending in the Armed Services Board of Contract Appeals (ASBCA) dealt with interesting legal issues on a motion to dismiss. See Appeals of McCarthy Hitt-Next NGA West JV, ASBCA No. 63571, 2023 WL 9179193 (ASBCA 2023). The dispute involves a contractor passing through subcontractor claims due to impacts caused by the COVID-19 pandemic and the government’s response to the pandemic. More particularly, the claim centers on the premise that the government “failed to work with [the contractor] in good faith to develop a collaborative and cooperative approach to manage and mitigate the impacts and delays arising from the COVID-19 pandemic.” See Appeals of McCarthy Hitt. The contractor (again, submitting pass through claims from subcontractors) claimed: (a) constructive changes to the contract entitling it to an equitable adjustment under the Changes clause of Federal Acquisition Regulation (F.A.R.) 52.243-4; (b) construction suspensions of the contractor’s work entitling it to an equitable adjustment under the Suspensions of Work clause of F.A.R. 52-242-14; and (c) the government breached the implied covenant of good faith and fair dealing. Each of these legal issues and theories will be discussed below because they are need-to-know legal issues. Keep these legal issues in mind, and the ASBCA’s ruling on the motion to dismiss as its analysis may demonstrate fruitful in other applications. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

New Homes in Palo Alto to Be Electric-Car Ready

October 01, 2013 — CDJ STAFF
Electric cars are still fairly rare, but if you buy a new home in Palo Alto, you’ll have a place to charge it. The Palo Alto City Council has been enthusiastic about a measure that would require new homes to come wired for car chargers. The hope of the council is that the measure will make owning an electric car “convenient, easy and economical.” If added to the construction process, the wiring adds about $200 to the cost of the home, far less than the cost of adding it to an existing home. In addition to considering changes in the building code, the city also considered measures that would allow for the operation of public charging stations. Read the court decision
Read the full story...
Reprinted courtesy of

U.S. Stocks Fall as Small Shares Tumble Amid Home Sales

September 24, 2014 — Joseph Ciolli and Callie Bost – Bloomberg
U.S. stocks fell, led by a plunge among small companies, as sales of existing homes unexpectedly dropped and China’s finance minister damped stimulus hopes. The Russell 2000 Index of small-cap stocks sank 1.6 percent, the most since July. Yahoo! Inc. (YHOO) dropped 2.3 percent to lead the Dow Jones Internet Composite Index to a one-month low. Alibaba Group Holding Ltd. slid 2.1 percent after surging in its trading debut Sept. 19. The Standard & Poor’s 500 Index dropped 0.7 percent to 1,997.37 at 11:24 a.m. in New York, after closing at a record Sept. 18. The benchmark gauge hasn’t had a four-day slide this year and hasn’t fallen 10 percent in three years. The Dow Jones Industrial Average slid 58.40 points, or 0.3 percent, to 17,221.34. Mr. Ciolli may be contacted at jciolli@bloomberg.net; Ms. Bost may be contacted at cbost2@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Joseph Ciolli and Callie Bost, Bloomberg

Don’t Get Caught Holding the Bag: Hold the State Liable When General Contractor Fails to Pay on a Public Project.

January 31, 2018 — Sean Minahan – Construction Contract Advisor
According to a quick Google search the term “holding the bag” comes from the mid eighteenth century and means be left with the onus of what was originally another’s responsibility. Nobody wants to be left holding the bag. But that is the situation our client (subcontractor) found themselves in when upon completion of a public project the general contractor went out of business before paying the remaining amount due and owing to our client. Under Nebraska law, liens are not allowed against public projects. Instead the subcontractor is to make a claim on the payment and performance bond secured by the general contractor at the start of the project. In our case, the general contractor never secured a bond on which to make a claim; consequently, leaving our client holding the bag. Read the court decision
Read the full story...
Reprinted courtesy of Sean Minaham, Lamson, Dugan and Murrary, LLP
Mr. Minahan may be contacted at sminahan@ldmlaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES