Fairfield Connecticut Building Expert Directory

Connecticut Reverses Course for Construction Managers on School Projects

August 05, 2024 — Anand Gupta - Construction Law Zone Blog
On June 6, 2024, Connecticut Governor Ned Lamont signed into law Public Act 24-151 (H.B. 5524) (Bill 5524). Bill 5524 authorized and adjusted bonds of the state and provisions related to state and municipal tax administration, as well as addressed school building projects. Notably, Bill 5524 removed the ban on construction managers self-performing work on public school construction projects, effective July 1, 2024. Allowing construction managers to self-perform certain portions of the work, such as general trades, subject to the standard bidding requirements, is a common industry practice that, theoretically, reduces total project costs by reducing the amount of subcontracted work. However, proponents of banning self-performance argue that construction managers have too much information to bid fairly and competitively. Reprinted courtesy of Anand Gupta, Robinson+Cole Mr. Gupta may be contacted at agupta@rc.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Sacramento’s Commercial Construction Market Heats Up

September 10, 2014 — Garret Murai – California Construction Law Blog
One reason I changed law firms from the Bay Area to Sacramento was I felt that Sacramento’s construction market, which was one of the areas hardest hit in California following the Real Estate Bubble Burst, was poised for a comeback. And as with past real estate cycles, residential construction has led the growth, and is now being followed by commercial construction. Indeed, according to data compiled by Engineering News-Record, commercial and institutional projects are propelling Sacramento’s construction market[.] Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Kronick Moskovitz Tiedemann & Girard
Mr. Murai may be contacted at gmurai@kmtg.com

Triable Issue of Fact Exists as to Insurer’s Obligation to Provide Coverage Under Occurrence Policy

March 08, 2021 — Valerie A. Moore & Kathleen E.M. Moriarty – Haight Brown & Bonesteel LLP
In Guastello v. AIG Specialty Ins. Co. (No. G057714. filed 2/19/21 ord. pub. 2/23/21), a California appeals court held that triable issues of material fact exist which precluded summary judgment for an insurer seeking to disclaim coverage on the basis that the “occurrence” pre-dated the policy period where a dispute exists as to the timing of the subject “occurrence.” In Guastello, a subcontractor built retaining walls from 2003 to 2004 for a housing development in Dana Point, California. In 2010, one of these retaining walls collapsed causing damage to a residential lot owned by Thomas Guastello. Reprinted courtesy of Valerie A. Moore, Haight Brown & Bonesteel LLP and Kathleen E.M. Moriarty, Haight Brown & Bonesteel LLP Ms. Moore may be contacted at vmoore@hbblaw.com Ms. Moriarty may be contacted at kemoriarty@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Coverage for Construction Defects Barred By Exclusion j (5)

April 15, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The Texas Court Appeal reversed a trial court judgment which found coverage in favor of the contractor based upon exclusion j(5). Dallas Nat'l Ins. Co. v. Calitex Corp., 2015 Tex. App. LEXIS 2002 (Tex. Ct. App. March 3, 2015). Turnkey Residential Group, Inc., was the contractor to construct a twelve-unit townhome complex in Dallas. The owner of the project was Calitex Corporation. Construction began on November 2006. The project was to be completed by Turnkey by October 27, 2007. Calitex filed suit against Turnkey and some of its subcontractors in February 2008. Calitex alleged problems with Turnkey's work included: (1) the stone exterior was not properly treated and leaked, and some areas were left uncovered with stone; and (2) windows leaked. It was further alleged that the quality of materials, labor and craftsmanship did not meet the standards of the contract and resulted in damages. Turnkey submitted a notice of claim to its insurer, Dallas National Insurance Company (DNIC). Coverage was denied. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

County Sovereign Immunity Invokes Change-Order Ordinance

December 20, 2017 — Lizbeth Dison - AHC Contruction Law Blog
The recent case of Fulton County v. Soco Contracting Company, Inc. addresses two very interesting questions for local government attorneys. First, can a county ordinance bolster a defense of sovereign immunity against a contractor’s claims? Second, can a county waive sovereign immunity by failing to respond to Requests for Admission? Facts: County hired Contractor to construct a facility near the airport. The contract provided that change orders must satisfy a county ordinance, which required approval by the Board of Commissioners. But in emergency situations, the County Manager could approve change orders, as long as the contractor executes a proposed modification and the purchasing agent approves it. The project suffered substantial delays, which Contractor attributed to weather, design delays, delays by the County in providing decisions on changes, and delays in obtaining permits during the federal government’s shutdown. As a result of these issues, Contractor comes County changed the scope of the contract. Contractor asserted claims against County for the delays and the changes to the work. The appellate opinion addresses the change order claims. Read the court decision
Read the full story...
Reprinted courtesy of Lizbeth Dison, Autry Hall & Cook, LLP

Senate Overwhelmingly Passes Water Infrastructure Bill

November 06, 2018 — Tom Ichniowski – Engineering News-Record
Congress has approved major water infrastructure legislation that authorizes $3.7 billion for new Army Corps of Engineers civil-works projects and $4.4 billion for the Environmental Protection Agency drinking-water program. Read the court decision
Read the full story...
Reprinted courtesy of Tom Ichniowski, ENR
Mr. Ichniowski may be contacted at ichniowskit@enr.com

New Illinois Supreme Court Trigger Rule for CGL Personal Injury “Offenses” Could Have Costly Consequences for Policyholders

March 09, 2020 — Michael S. Levine & Kevin V. Small - Hunton Insurance Recovery Blog
The Illinois Supreme Court’s recent decision in Sanders v. Illinois Union Insurance Co., 2019 IL 124565 (2019), announced the standard for triggering general liability coverage for malicious prosecution claims under Illinois law. In its decision, the court construed what appears to be a policy ambiguity against the policyholder in spite of the longstanding rule of contra proferentem, limiting coverage to policies in place at the time of the wrongful prosecution, and not the policies in effect when the final element of the tort of malicious prosecution occurred (i.e. the exoneration of the plaintiff). The net result of the court’s ruling for policyholders susceptible to such claims is that coverage for jury verdicts for malicious prosecution – awarded in today’s dollars – is limited to the coverage procured at the time of the wrongful prosecution, which may (as in this case) be decades old. Such a scenario can have costly consequences for policyholders given that the limits procured decades ago are often inadequate due to the ever-increasing awards by juries as well as inflation. Moreover, it may be difficult to locate the legacy policies and the insurers that issued such policies may no longer be solvent or even exist. A copy of the decision can be found here. The Sanders case arose out of the wrongful conviction of Rodell Sanders in 1994 by the City of Chicago Heights (the “City”). Mr. Sanders sought recompense for, among other things, malicious prosecution through a federal civil rights action against the City. In September 2016, Mr. Sanders obtained a consent judgment for $15 Million; however, at the time of the wrongful conviction, seventeen years earlier, the City’s only applicable insurance policy provided just $3 million in coverage. The City contributed another $2 million towards the judgment and, in exchange for Mr. Sanders’s agreement not to seek the $10 million balance from the City, assigned its rights under the policies for the 2012 to 2014 period. Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth and Kevin V. Small, Hunton Andrews Kurth Mr. Levine may be contacted at mlevine@HuntonAK.com Mr. Small may be contacted at ksmall@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Pollution Created by Business Does Not Deprive Insured of Coverage

November 26, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The federal district court determined that coverage was properly denied under the pollution exclusion of the policies. Headwaters Resources, Inc. v. Illinois Union Ins. Co., 2014 U.S. App. LEXIS 20060 (10th Cir. Oct. 20, 2014). Over 400 residents of Chesapeake, Virginia, filed two lawsuits against the insured, Headwaters, alleged property damage and bodily injury due to pollution generated in connection with the development of a golf course. The complaints alleged that between 2002 and 2007, the defendants used 1.5 million tons of toxic fly ash during construction of a golf course. The insured allegedly transported the fly ash to an open pit adjacent to residential neighborhoods. The chemicals from the fly ash leached into the ground water, damaging the private wells. The fly ash pit also released airborne contaminants that produced a strong smell of ammonia. As a result of the alleged contamination, the property values of plaintiffs' homes depreciated and members of the community faced increased risk of serious bodily injuries caused by exposure to the fly ash. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES