FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Pennsylvania Supreme Court’s Ruling On Certificates Of Merit And “Gist Of Action” May Make It More Difficult For An Architect Or Engineer To Seek An Early Dismissal

January 07, 2015 — Jerrold P. Anders and Michael W. Jervis - White and Williams LLP
In Bruno v. Erie Ins. Co., the Pennsylvania Supreme Court clarified the gist of the action doctrine that distinguishes between tort and contract claims. In doing this, the Court also ruled that a Certificate of Merit in a professional liability claim is necessary only if the plaintiff is in a direct client relationship with the licensed professional. This clarification of the Certificate of Merit requirement may limit the ability of architects and engineers to obtain an early dismissal in lawsuits. Bruno v. Erie Ins. Co. involves a common scenario. The Brunos filed a claim with their homeowners’ insurer after discovering mold in their home during remodeling. The policy included an endorsement providing coverage for mold. As part of the claim adjustment, Erie hired an engineer to inspect the mold and to provide an opinion on its severity to determine the extent of remediation required. The engineer hired by Erie reported to Mr. Bruno that the mold was harmless, that concern over health problems due to mold was merely a “media frenzy,” and that the Brunos should continue with their renovations. Reprinted courtesy of Jerrold P. Anders, White and Williams LLP and Michael W. Jervis, White and Williams LLP Mr. Anders may be contacted at andersj@whiteandwilliams.com Mr. Jervis may be contacted at jervism@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

---

A New Hope - You Now May Have Coverage for Punitive Damages in Connecticut

February 15, 2018 — Stella Szantova Giordano – SDV Blog

On December 19, 2017, the Connecticut Supreme Court released its decision in Nationwide Mutual Ins. Co. v. Pasiak. The decision is significant for two reasons: 1) it clarifies the amount of proof an insurer needs to determine whether an exclusion to coverage applies; and 2) it found that where an insurance policy expressly provides coverage for an intentional act such as false imprisonment, common-law punitive damages are also covered.

Underlying action

The underlying action proves that real life is often stranger than fiction. Ms. S worked as an office help for a construction company owned by Mr. P, which operated out of his home. Ms. S was working alone in the home office, when an armed, masked intruder entered the office, tied her hands, gagged and blindfolded her and, pointing a gun to her head, threatened to kill her family if she did not give him the combination to a safe in the home. As this was happening, Mr. P entered the office, unmasked the intruder, and discovered it was his lifelong friend. After Ms. S was untied, she asked to leave, but Mr. P told her to stay. She was not allowed to leave for several hours as Mr. P made her accompany him to an errand. Ms. S sued Mr. P for false imprisonment, among other things. The trial court awarded her compensatory and punitive damages. Insurance coverage for the underlying judgment is at the heart of the Pasiak case.

Read the court decision
Read the full story...
Reprinted courtesy of Stella Szantova Giordano, Saxe Doernberger & Vita, P.C.
Ms. Szantova Giordano may be contacted at ssg@sdvlaw.com

---

Insured's Claim for Water Damage Dismissed with Leave to Amend

August 12, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The court granted the insurer's motion to dismiss the insured's claim for water damage under a homeowners' policy, but granted leave to amend. Thompson v. State Farm Gen. Ins. Co., 2024 U.S. Dist. LEXIS 98486 (C.D. Cal. June 3, 2024). The insureds' first amended complaint alleged they "suffered a sudden and accidental water loss below their slab in their home." A plumber hired by the insureds discovered "a copper pipe burst inside a structural concrete footing between a manifold in the living room and the water heater." The insureds notified their insurer, State Farm. Claim adjuster Andrea Acevedo conducted a visual inspection. The complaint alleged she did not "inspect or view the pipe, or have a testing conducted on the pipe." Acevedo sent a letter denying the insureds' claim based upon her finding that "because the loss was caused by a slab leak, there is no coverage available for the loss." The letter explained that the hot water supply line under the home failed due to wear, tear, deterioration and/or electrolysis. The predominant cause of loss to the failed pipe was due to one or a combination of rust, electrolysis, corrosion, wear, tear and/or deterioration. The policy did not cover water damage caused by water from below the surface of the ground. Further coverage for wear, tear, deterioration, rot, mold, maintenance, water from below the surface of the ground and a continuous or repeated seepage or leakage of water was excluded. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Pollution Exclusion Bars Coverage for Damage Caused by Tar Escaping From Roof

October 27, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The insurer prevailed on summary judgment establishing it had no duty to defend the insured roofing contractor for damage caused by tar escaping from a roof. Mesa Underwriters Spec. Ins. Co. v. Myers, 2016 U.S. Dist. LEXIS 108444 (W.D. Ohio Aug. 16, 2016). Myers contracted to do roofing work for Sireco III LLC. Myers removed stones from the roof, patched all bad sections, and sealed the roof. To seal the roof, Myers used a roofing-tar sealant. The substance was a skin irritant and harmful or fatal if swallowed. Myers expected the sealant to harden within twenty-four hours. When rain hit the area eleven days later, however, it washed the sealant off the roof and into the downspouts. It then flowed into the city's sewer system and eventually into Lake Erie. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Capitol View-Corridor Restrictions Affect Massing of Austin’s Tallest Tower

October 17, 2023 — David M. Brown - Engineering News-Record
The stepped-back profile of a 66-story skyscraper in Austin, which will be the state capital’s tallest building when completed this fall, is a consequence of the city's height and massing limits to keep the view corridor to the capitol's dome unblocked. Reprinted courtesy of David M. Brown, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

Want to Make Your Jobsite Safer? Look to the Skies.

October 10, 2022 — Rory San Miguel - Construction Executive
New York Gov. Kathy Hochul is set to sign Carlos’ Law for worker protection. The law would set a national precedent for construction site safety, substantially raising the minimum fines for construction companies found liable for onsite injuries. Worksites are very complex, and many factors go into creating a safe space. Following suit, innovative operators are looking at advanced technologies to boost onsite safety, including drone data visualization, which involves flying a drone over a site to capture a highly accurate 3D model of current conditions in close to real time. Using drones can't solve every problem, but it can help not only protect workers but also encourage new ones to join your team. How drone surveying improves jobsite safety 3D mapping a worksite with a drone keeps workers out of harm’s way, helping surveyors avoid potentially dangerous areas filled with constantly moving heavy equipment and machinery. Drone mapping also means surveyors can stay out of the heat, avoiding the risk of excess sun exposure by sending the drone out in their stead to traverse the terrains and slopes of the site. Reprinted courtesy of Rory San Miguel, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

---

Connecticut Appellate Court Breaks New Ground on Policy Exhaustion

April 26, 2021 — Eric B. Hermanson & Austin D. Moody - White and Williams
The Connecticut Appellate Court recently issued a wide-ranging opinion, Continental Casualty Co. v. Rohr, Inc.,[1] which significantly extended the current restrictive view on when a general liability policy can be considered exhausted so as to trigger overlying excess coverage. The case marks a further step away from Judge Augustus Hand’s almost-century-old ruling in Zeig v. Massachusetts Bonding & Ins. Co.,[2] which held that an underlying policy could be “exhausted” by a below-limits settlement as long as the insured was willing to “fill the gap” between the settlement amount and the limits of the policy.[3] In recent years, courts in California and elsewhere have increasingly walked back Zeig’s broad ruling – holding in Qualcomm v. Certain Underwriters,[4] for example, that an insured’s below-limits settlement with primary carriers does not exhaust the limits of primary coverage, or allow the insured to access overlying excess coverage.[5] Reprinted courtesy of Eric B. Hermanson, White and Williams and Austin D. Moody, White and Williams Mr. Hermanson may be contacted at hermansone@whiteandwilliams.com Mr. Moody may be contacted at moodya@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

---