FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Unpredictable Opinion Regarding Construction Lien (Reinstatement??)

January 17, 2023 — David Adelstein - Florida Construction Legal Updates
Here comes the discussion of an appeal I was intimately involved in dealing with a construction lien. See Suntech Plumbing and Mechanical Corp. v. Bella Isla, LLC, 2022 WL 14672765 (Fla. 3d DCA 2022). Unfortunately, it was a losing result on my end but not a losing result to the issue at-hand. You should ask what in the world does this mean. I will tell you. Here is the fact pattern. A subcontractor files a construction lien foreclosure lawsuit against an owner for unpaid contract balance. In the same lawsuit, the subcontractor sues the general contractor for breach of contract and unjust enrichment associated with an approximate three-year delay on a construction project. The project was scheduled to be completed in 2019. It was not. The project was pushed into COVID and into 2022. (The subcontractor did not sue the general contractor for amounts subject to the lien foreclosure claim.) The general contractor, assuming the defense of the owner, moved to stay the lawsuit pending the outcome of arbitration based on an arbitration provision in the subcontract. The subcontractor did not dispute the arbitration provision, but argued that arbitration provision should not extend to the owner that was (a) not bound by the subcontract, (b) would not be a party to the arbitration, and (c) the amounts pled against the general contractor did not include the amounts subject of the lien foreclosure lawsuit. At a minimum, the lawsuit should be stayed, not dismissed. Nevertheless, the trial court dismissed the entire lawsuit in an order that states that it is a final order with language that the lien may be “reinstated” after the outcome of the arbitration (that the owner is not a party to). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Part of the Whole: Idaho District Court Holds Economic Loss Rule Bars Tort Claims Related to Water Supply Line that was Part of Home Purchase

October 03, 2022 — Gus Sara - The Subrogation Strategist
In Safeco Ins. Co. of Ill. v. LSP Prods. Grp., 2022 U.S. Dist. LEXIS 139566, the United States District Court for the District of Idaho (District Court) considered whether the plaintiff’s tort claims against the manufacturer of an allegedly defective toilet water supply line were barred by the economic loss rule. The defendant filed a motion for summary judgment arguing that, since the supply line was a part of the home when the plaintiff’s insureds purchased it, the plaintiff was barred by the economic loss rule from bringing tort claims against the manufacturer. The District Court granted the defendant’s summary judgment motion, ruling that the supply line was a part of the home, which was the subject of the transaction, at the time it was purchased. Thus, the District Court held that the economic loss rule barred the plaintiff’s tort claims. In 2012, Melissa Norris and Richard Meyers (collectively, the Homeowners) purchased a newly built home in Eagle, Idaho. In 2016, a toilet supply line in one of the bathrooms began leaking, causing water damage to the home as well as to window blinds, an oven and dishwasher. The Homeowners also incurred a loss of rental income. The Homeowners submitted a claim to Safeco Insurance Company (Insurer), their property insurance carrier, who ultimately covered the Homeowners’ losses. Read the court decision
Read the full story...
Reprinted courtesy of Gus Sara, White and Williams
Mr. Sara may be contacted at sarag@whiteandwilliams.com

---

Defective Concrete Blocks Spell Problems for Donegal Homeowners

October 30, 2013 — CDJ STAFF
A number of recently built homes in Donegal, Ireland are suffering from crumbing cement blocks used in the construction. This was previously seen in homes in the Leinster Region, and seems to be more widespread than previously thought. Damien McKay, an engineer who specializes in building litigation noted that the blocks started cracking about five years after the homes were constructed. In some cases, “the actual concrete blocks beneath the plaster can be easily broken and in some occasions with as little effort as rubbing with your fingers.” Read the court decision
Read the full story...
Reprinted courtesy of

---

San Diego Appellate Team Prevails in Premises Liability Appeal

December 06, 2021 — Corinne Bertsche, Jeffry Miller & Tracy Forbath - Lewis Brisbois
San Diego, Calif. (October 28, 2021) - San Diego Appellate Practice Partners Jeffry A. Miller and Corinne C. Bertsche, along with Associate Tracy D. Forbath, recently obtained a win on appeal when California's Court of Appeal for the Second Appellate District, Division Four affirmed the trial court’s grant of a client homeowners association’s motion for summary judgment. In the underlying matter, the plaintiff alleged claims for premises liability and negligence for injuries he sustained when tripping over an uplift of two misaligned adjacent slabs of concrete sidewalk, measuring 1.25 inches and located next to a condominium complex. The appellate court agreed that the defect in question was a trivial defect as a matter of law, despite the plaintiff’s arguments that there was a triable issue of material fact as to whether the uplift’s dangerousness was exacerbated by the presence of aggravating factors. The appellate court found that the plaintiff’s expert declaration did not support the alleged aggravating factors with admissible evidence, and that the trial court did not abuse its discretion in excluding it. Reprinted courtesy of Corinne Bertsche, Lewis Brisbois, Jeffry Miller, Lewis Brisbois and Tracy Forbath, Lewis Brisbois Ms. Bertsche may be contacted at Corinne.Bertsche@lewisbrisbois.com Mr. Miller may be contacted at Jeff.Miller@lewisbrisbois.com Ms. Forbath may be contacted at Tracy.Forbath@lewisbrisbois.com Read the court decision
Read the full story...
Reprinted courtesy of

---

How Data Drives the Future of Design

April 11, 2022 — Marcin Kosicki - AEC Business
Data has become the currency of modern society. It is the most abundantly generated product of the 21st century. Every action in our lives, from asking for directions using Google Maps to liking a post on social media, produces data that is being mined in a variety of imaginative and profitable ways. If our daily actions generate an avalanche of information, how much data could the design, construction, and operation of a building produce? Sketches and drawings, simulations and building analyses, BIM models, construction logistics and procurement, post-occupancy data gathered by sensors, and 3D scans all produce an abundance of data. It is, therefore, unfortunate that the adoption of Big Data and Cloud Computing in the building industry is substantially less developed than in other fields. Read the court decision
Read the full story...
Reprinted courtesy of Marcin Kosicki, AEC Business

---

Is Performance Bond Liable for Delay Damages?

October 20, 2016 — David Adelstein – Florida Construction Legal Updates
There is an argument that a performance bond is not liable for delay damages UNLESS the bond specifically allows for the recovery of such damages. Keep this in mind when requiring a performance bond so that the bond covers the associated risks (and damages) you contemplate when requiring the bond. This argument is supported by the Florida Supreme Court’s 1992 decision in American Home Assur. Co. v. Larkin General Hosp., Ltd., 593 So.2d 195, 198 (Fla. 1992):

The language in the performance bond, construed together with the purpose of the bond, clearly explains that the performance bond merely guaranteed the completion of the construction contract and nothing more. Upon default, the terms of the performance bond required American [performance bond surety] to step in and either complete construction or pay Larkin [obligee] the reasonable costs of completion. Because the terms of the performance bond control the liability of the surety, American’s liability will not be extended beyond the terms of the performance bond. Therefore, American cannot be held liable for delay damages.

However, the Eleventh Circuit in National Fire Ins. Co. of Hartford v. Fortune Const. Co., 320 F.3d 1260(11th Cir. 2003), also analyzing an issue relating to the recoverability of delay-type damages against a performance bond, did not narrowly interpret the Florida Supreme Court’s decision in Larkin General Hospital. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.
Mr. Adelstein may be contacted at dma@katzbarron.com

---

Texas Supreme Court Holds Stipulated Extrinsic Evidence May Be Considered in Determining Duty to Defend

May 10, 2022 — Tred R. Eyerly - Insurance Law Hawaii
Responding to certified questions from the Fifth Circuit, the Texas Supreme Court held that in limited circumstances, extrinsic evidence may be considered in determining the duty to defend. Monroe Guar. Ins. Co. v. Bitco Gen. Ins. Corp., 2022 Tex. LEXIS 148 (Tex. Feb. 11, 2022). The two insurers each provided CGL coverage to the insured, 5D Drilling & Pump Service, Inc., at different times. BIitco provided two consecutive one-year CGL policies covering October 2013 to October 2015. Monroe's CGL policy covered 5D from October 2015 to October 2016. 5D was sued by David Jones for breach of contract and negligence, seeking damage allegedly resulting from 5D's drilling operations on Jones's property. Jones contracted with 5D in the summer of 2014 to drill a 3600-foot irrigation well on his farmland. The complaint did not detail when 5D's purportedly negligent acts occurred or even when 5D began or stopped the work. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Legislative Update – The CSLB’s Study Under SB465

March 22, 2018 — John Castro - Construction Law Blog
Following the tragic Berkeley balcony collapse in 2015, the Legislature enacted California Senate Bill 465 which commissioned the Contractors State License Board (“CSLB” or “Board”) to perform a study regarding the efficacy of having contractors report settlements to the Board. In December 2017 the CSLB released their findings in a report. The ultimate conclusion of the report is to recommend to the Legislature that the ability of the CSLB to protect the public “would be enhanced by regulations requiring licensees to report judgments, arbitration awards, or settlement payments of construction defect claims for rental residential units.” Senator Jerry Hill authored SB465, and his office is presently now drafting legislation on settlement reporting based in part on this study. The most troubling concern about the study is transparency. The report references nine exhibits, all of which have been withheld from publication under purposes of confidentiality. Therefore, much of the CSLB’s study must be taken at face value because much of the data they rely on to formulate their conclusions cannot be independently verified. One of the factors that the CSLB undertook in its study was to determine criteria for when a settlement was “nuisance value,” and therefore less important for reporting purposes. The CSLB acknowledged there was no industry-wide definition for “nuisance value,” whether it be in the insurance industry, construction industry, or otherwise. Insurer survey respondents reached a general consensus on aspects of what can constitute a “nuisance value” settlement, including the amount of the settlement and the size of the case. However, the response rate to the insurer survey was only 3.3 percent. In general, the concern with using settlement amount and size of the case as indicative factors is the fact that a large settlement size, for instance, may still constitute a “nuisance value” settlement. One example would be a large settlement figure in a case involving hundreds of homes in multiple subdivisions. Read the court decision
Read the full story...
Reprinted courtesy of John Castro, Gordon Rees Scully Mansukhani LLP
Mr. Castro may be contacted at jcastro@grsm.com

---