Seattle Washington Building Expert Directory

Specification Challenge; Excusable Delay; Type I Differing Site Condition; Superior Knowledge

January 02, 2024 — David Adelstein - Florida Construction Legal Updates
An Armed Services Board of Contract Appeals dispute, Appeal of L.S. Black-Loeffel Civil Constructors JV, ASBCA No. 62402, 2023 WL 5827241 (ASBCA 2023), involved which party bore liability for delay—the federal government or the prime contractor–based on various legal theories. Without detailing the factual details, a number of interesting legal issues were raised in this dispute including (1) a defective specification challenge, (2) excusable delay, (3) Type I differing site condition, and (4) superior knowledge. These legal issues are discussed below. 1. Specification Challenge (Defective Specifications) The contractor claimed that the government’s specifications were defective in regard to a thermal control plan. The government countered that the specifications were not design specifications but performance specifications. The specifications were performance based because they did not tell the contractor how to achieve the performance-based criteria. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Thank You for 14 Consecutive Years of Legal Elite Elections

December 29, 2020 — Christopher G. Hill - Construction Law Musings
Thanks to the Virginia legal community that has continued to elect me to the Virginia Business Legal Elite in the Construction Law Category for 14 years running. The 14 consecutive years of election to the Legal Elite in the Construction Category spans my time as a solo construction attorney. The fact that you all have continued to elect “100%” of the lawyers at The Law Office of Christopher G. Hill, PC for the last 10 years is most gratifying and only confirms that my decision to “go solo” over 10 years ago was a good one. To be included in this list of top construction attorneys is both humbling and gratifying. For the complete list of the Virginia construction lawyers that were elected along with me, see the 2020 Virginia Business Legal Elite in Construction Law. Reprinted courtesy of The Law Office of Christopher G. Hill Mr. Hill may be contacted at chrisghill@constructionlawva.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Federal Court Opinion Has Huge Impact on the Construction Industry

July 06, 2020 — Wally Zimolong - Supplemental Conditions
The United States District Court for the Eastern District of Pennsylvania in Philadelphia recently issued an opinion that should get the attention of any contractor or subcontractor performing work on a federal funded construction project. In U.S. ex rel IBEW Local 98 v. The Fairfield Company, the federal court held that a contractor on a SEPTA project could be held liable under the False Claims Act for failing to pay its workers under the Davis Bacon Act. The court found that liability was appropriate under the FCA even through the contractor did not knowingly violate the Davis Bacon Act. The court awarded the plaintiff over $1,000,000 in damages and an additional over $1,000,000 in attorneys fees. An Extremely Brief Primer on the FCA A full discussion of the FCA is beyond the realm of this blog post and you could write a book on FCA cases. But in a nutshell, the FCA prohibits a contractor from knowingly submitting a claim for payment to the federal government (or an entity receiving funding from the federal government, like SEPTA) that is false. Importantly, knowingly does not equal actual knowledge of the falsity of the claim. Rather, “reckless disregard of the truth or falsity” of the submission is sufficient. As explained below, this standard played an important role in the court’s decision and should give contractors performing work on federally funded projects pause. Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

Third Circuit Holds That Duty to Indemnify "Follows" Duty to Defend

December 27, 2021 — Jeffrey J. Vita - Saxe Doernberger & Vita, P.C.
In a win for policyholders, the Third Circuit Court of Appeals recently affirmed a District Court’s 2018 ruling, which held that the duty to indemnify follows the duty to defend where a settlement precludes a determination on the facts of the case relative to liability and apportionment. In Liberty Mutual Insurance Co. v. Penn National Mutual Casualty Insurance Co.,1 a large concrete panel collapsed and killed a construction worker at a construction site in New Kensington, Pennsylvania. Cost Company (“Cost”), Liberty Mutual’s insured, was a masonry subcontractor on the project and had further subcontracted with Pittsburgh Flexicore Co. (“Flexicore”), Penn National’s insured, for the concrete panels. Cost’s subcontract agreement required Flexicore to name Cost as an additional insured under its general liability policy issued by Penn National. When the construction worker’s widow filed a wrongful death lawsuit against Cost and Flexicore, Cost demanded that Penn National defend and indemnify it as an additional insured under the policy. Penn National refused, arguing that any additional insured status had terminated at the conclusion of Flexicore’s work for Cost. As a result, Liberty Mutual defended Cost in the lawsuit, which was ultimately settled. Read the court decision
Read the full story...
Reprinted courtesy of Jeffrey J. Vita, Saxe Doernberger & Vita, P.C.
Mr. Vita may be contacted at JVita@sdvlaw.com

Tiny Houses Big With U.S. Owners Seeking Economic Freedom

July 16, 2014 — Nina Glinski – Bloomberg
Doug Immel recently completed his custom-built dream home, sparing no expense on details like cherry-wood floors, cathedral ceilings and stained-glass windows -- in just 164 square feet of living space including a loft. The 57-year-old schoolteacher’s tiny house near Providence, Rhode Island, cost $28,000 -- a seventh of the median price of single-family residences in his state. “I wanted to have an edge against career vagaries,” said Immel, a former real estate appraiser. A dwelling with minimal financial burden “gives you a little attitude.” He invests the money he would have spent on a mortgage and related costs in a mutual fund, halving his retirement horizon to 10 years and maybe even as soon as three. “I am infinitely happier.” Dramatic downsizing is gaining interest among Americans, gauging by increased sales of plans and ready-made homes and growing audiences for websites related to the niche. A+E Networks Corp. will air, beginning today, “Tiny House Nation” a series on FYI that “celebrates the exploding movement.” Read the court decision
Read the full story...
Reprinted courtesy of Nina Glinski, Bloomberg
Ms. Glinski may be contacted at nglinski@bloomberg.net

The Road to Rio 2016: Zika, Super Bacteria, and Construction Delays. Sounds Like Everything is Going as Planned

July 28, 2016 — Garret Murai – California Construction Law Blog
Athletes began to arrive at the Olympic Village in Rio de Janeiro on Sunday in anticipation of the 2016 Summer Olympics which begin on August 5th. Perhaps the most closely watched event, however, has already begun; and it has no medals. And that is whether Brazil can successfully pull off the Olympics at all. For a city known for its Carnival the months leading up to the Olympics have been just as crazy and chaotic as the days leading up to Mardi Gras. There’s the Zika virus, the discovery of a “super” bacteria, the impeachment of its President, and Brazil’s worst recession in 100 years. And that’s just a partial list. And then, of course, there’s the construction. Cities bidding to host the Olympics often cite revenue from tourism and long-term capital improvements which will benefit its populace long after the games have ended as economic justification for hosting the Olympics. However, the cost to host the Olympics is often underestimated and Rio is no exception, running an estimated $6 billion over budget. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Real Estate & Construction News Roundup (09/06/23) – Nonprofit Helping Marginalized Groups, Life Sciences Taking over Office Space, and Housing Affordability Hits New Low

October 24, 2023 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, Walmart adds their own generative AI, major airlines reduce their capacity at regional airports, autoworkers prepare for a strike as negotiations continue, and more!

A nonprofit in Philadelphia is helping connect marginalized business owners with construction projects before bids are announced to improve equity in deals. (Kristen Mosbrucker-Garza, WHYY)
While the traditional office space market has been rocky, the life sciences market has taken over, creating more than one out of every four new projects. (Greg Cornfield, Commercial Observer)
Along with JLL, Walmart has joined the growing list of major U.S. companies supplying their own generative AI tools to some of their employees. (Lindsey Wilkinson, Construction Dive)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Connecticut Supreme Court to Review Several Issues in Asbestos Coverage Case

November 08, 2017 — Ciaran Way & Robert F. Walsh – White and Williams LLP
On October 18, 2017, in R.T. Vanderbilt Company v. Hartford Accident & Indemnity Company, the Connecticut Supreme Court certified four issues for appeal, which relate to trigger, allocation, pollution exclusions, and the occupational disease exclusion in the context of asbestos bodily injury claims. This post identifies the issues the Connecticut Supreme Court will decide on appeal and sets forth the Appellate Court’s ruling on each issue. Issue 1: Whether a “continuous trigger” theory of coverage applies to asbestos-related disease claims and whether expert medical testimony on the timing of injury should be precluded The Appellate Court applied a continuous trigger, and found that the trial court properly excluded testimony from medical experts the insurers had proffered to prove that the asbestos disease process did not support a continuous trigger. Reprinted courtesy of Ciaran Way, White and Williams LLP and Robert Walsh, White and Williams LLP Ms. Way may be contacted at wayc@whiteandwilliams.com Mr. Walsh may be contacted at walshr@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES