Fairfield Connecticut Building Expert Directory

The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier

April 11, 2022 — Robert M. Barrack - Gordon & Rees
In United Concrete Prods. v. NJR Constr., LLC, 207 Conn. App. 551, 263 A.3d 823 (2021), the Connecticut Appellate Court has issued a decision that should be of interest to the Connecticut construction industry and the construction bar. The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects. In United Concrete Products, the defendant general contractor, NJR Construction, LLC (“NJR”) was retained by the State of Connecticut Department of Transportation (“DOT”) to replace a bridge over the Hockanum River (“Project”). Id. at 555-58 (2021). The Prime Contract provided that NJR with an eight-week time-frame to perform the work, at which time the road would be closed to traffic. Id. The Prime Contract also provided for a bonus of $3,000 for each day the road was opened to traffic prior to the eight week deadline of August 8, 2016, and for liquidated damages of $3,000 for each day the road remained closed beyond the deadline. Id. NJR subsequently entered into a purchase order (“Subcontract”) with the plaintiff, United Concrete Products, Inc. (“United”), whereby United agreed to provide certain concrete components for the Project, including ten pre-stressed concrete beams. Id. The Subcontract required that United deliver the concrete beams by June 7, 2016, but, NJR did not actually schedule the delivery until June 29, 2016. Id. Nevertheless, even with that schedule NJR could have reopened the road by July 19, 2016, which would have allowed it to receive the full $60,000 incentive bonus. However, United did not deliver the concrete beams until July 26, 2016, which caused NJR to lose the incentive bonus, be assessed liquidated damages by the DOT, and to incur additional delay damages. Id. After deducting the amount of $179,500 in damages that it incurred due to United’s late delivery of the beams, NJR paid United the balance of $66,074.75. Id. Read the court decision
Read the full story...
Reprinted courtesy of Robert M. Barrack, Gordon Rees Scully Mansukhani, LLP
Mr. Barrack may be contacted at rbarrack@grsm.com

The Hazards of Carrier-Specific Manuscript Language: Ohio Casualty's Off-Premises Property Damage and Contractors' E&O Endorsements

October 05, 2020 — Theresa A. Guertin & Eric M. Clarkson - Saxe Doernberger & Vita
Risk transfer in the construction industry depends heavily on industry-standard insurance language. Insurance provisions in subcontracts typically reference ISO standard insurance terminology or endorsements in order to guarantee (or, at least, attempt to secure) coverage for upstream parties. The contract may require, for example, that a subcontractor maintains general liability insurance on a “current ISO occurrence form,” and name upstream parties as additional insureds, and both parties will have a general understanding of what that entails for purposes of risk transfer. Problems arise, however, when insurance companies stray from standard language, especially on issues that go to the heart of construction risk transfer. In some instances, provisions that track ISO language may contain subtle changes that seem to meet the contractual insurance requirements. Upon closer scrutiny, it could significantly change how a policy will respond to a given claim. Given the extent of potential liability arising from construction projects, if the insurance programs intended to back up risk transfer and indemnity agreements do not respond as expected, all the potentially liable parties may be left in the lurch. Reprinted courtesy of Theresa A. Guertin, Saxe Doernberger & Vita and Eric M. Clarkson, Saxe Doernberger & Vita Ms. Guertin may be contacted at tag@sdvlaw.com Mr. Clarkson may be contacted at emc@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Whose Lease Is It Anyway: Physical Occupancy Not Required in Landlord-Tenant Dispute

February 07, 2018 — Afua Akoto – SDV Case Alert
In September 2017, a Texas Federal district judge ruled that that Personal and Advertising Injury coverage in a CGL policy did not require physical occupancy in a landlord-tenant dispute. In the underlying lawsuit, restaurant owner Ziggy Gruber alleged that John Dunn, the landlord of a Houston shopping center, wrongfully interfered with his right of occupancy at the shopping center by failing to complete the negotiation of a lease and preventing his occupancy of the space. Gruber further alleged that he had acquired a direct interest in the premises and became a rightful tenant but as a result of Dunn’s interference, he was never able to open his restaurant. Read the court decision
Read the full story...
Reprinted courtesy of Afua Akoto, Saxe Doernberger & Vita, P.C.
Ms. Akoto may be contacted at asa@sdvlaw.com

The ‘Sole Option’ Arbitration Provision in Construction Contracts

July 16, 2014 — Beverley BevenFlorez-CDJ STAFF
On his Best Practices Construction Law blog, Matthew Devries discussed how the “at its sole option…has the right to demand arbitration” can “be a good provision if you are the party who has that option.” For instance, Devries cites the case Archer Western Contractors, LLC v Holder Construction Company, where “the Georgia Court of Appeals recently affirmed the trial court’s decision to grant a contractor’s motion to compel arbitration with a ‘sole option’ provision.” Devries stated that “it is important to review carefully the disputes clause in your construction contract to fully understand who has the right to demand arbitration and what rules will apply.” Read the court decision
Read the full story...
Reprinted courtesy of

Is the Event You Are Claiming as Unforeseeable Delay Really Unforeseeable?

September 26, 2022 — David Adelstein - Florida Construction Legal Updates
Is the item or event you are claiming as an unforeseeable, excusable delay really unforeseeable? This is not a trick question. Just because your construction contract identifies items or events that constitute unforeseeable, excusable delay does not mean those items can be used as a blanket excuse or crutch for the contractor. That would be unfair. For instance, it is not uncommon for a construction contract to list as unforeseeable, excusable delay the following events or items: “(i) acts of God or of the public enemy, (ii) act of the Government in either its sovereign or contractual capacity, (iii) acts of another Contractor in the performance of a contract with the Government, (iv) fires, (v) floods, (vi) epidemics, (vii) quarantine restrictions, (viii) strikes, (ix) freight embargoes, (x) unusually severe weather, or (xi) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers.” See, e.g., F.A.R. 52.249-10(b)(1). While the itemization of excusable delay may be worded differently, the point is there may be a listing as to what items or events constitute excusable delay. An excusable delay would justify additional time and, potentially, compensation to the contractor. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Vallagio v. Metropolitan Homes: Colorado Supreme Court Upholds Declarant Consent Provision to Amend Arbitration Out of Declarations

June 15, 2017 — Jean Meyer - Colorado Construction Litigation
On June 5, 2017, the Colorado Supreme Court announced the Vallagio at Inverness Residential Con. Ass’n v. Metro. Homes, Inc., No. 15SC508, 2017 CO 69 (Colo. June 5, 2017) decision. In short, the Colorado Supreme Court upheld the validity of declarant “consent-to-amend” provisions and expressly held that claims under the Colorado Consumer Protection Act are arbitrable. By way of background, the Vallagio at Inverness Residential Condominiums were developed by Metro Inverness, LLC, (“Declarant”) which also served as the declarant for its homeowners association. Metropolitan Homes was Metro Inverness’ manager and the general contractor on the project. Greg Krause and Peter Kudla served as declarant-appointed members of the Association’s board during the period of declarant control. When it set up the Association, the Declarant included within the Association’s declaration a mandatory arbitration provision specifically for construction defect claims. This provision stated that it “shall not ever be amended without the written consent of Declarant and without regard to whether Declarant owns any portion of the Real Estate at the time of the amendment.” Read the court decision
Read the full story...
Reprinted courtesy of Jean Meyer, Higgins, Hopkins, McLain & Roswell, LLC
Mr. Meyer may be contacted at meyer@hhmrlaw.com

Key Legal Issues to Consider Before and After Natural Disasters

November 25, 2024 — Patrick Kelly - Construction Executive
While legal considerations are often the last thing on the minds of project owners and contractors during an emergency, construction industry stakeholders should bear in mind the impact of natural disasters on their legal rights, remedies and potential exposure to claims. For all stakeholders, two of the most pressing considerations are: (1) what provisions in their contracts are impacted by a natural disaster and (2) do they have any potential exposure to price-gouging claims? Reprinted courtesy of Patrick Kelly, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Kelly may be contacted at pkelly@grayreed.com

US Attorney Alleges ADA Violations in Chicago Cubs Stadium Renovation

August 07, 2022 — Annemarie Mannion - Engineering News-Record
The friendly confines of Wrigley Field are not so friendly to wheelchair users, according to federal prosecutors who filed a civil lawsuit July 14 alleging that the Chicago Cubs’ multi-year renovation of the baseball stadium eliminated prime wheelchair seating and did not include other accessible features required under the Americans with Disabilities Act. Reprinted courtesy of Annemarie Mannion, Engineering News-Record Ms. Mannion may be contacted at manniona@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES