FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Gene Witkin Joins Ross Hart’s Mediation Team at AMCC

March 01, 2021 — Arbitration Mediation Conciliation Center (AMCC)
AMCC is pleased to announce Gene Witkin joining Ross Hart’s mediation team effective March 1 this year. Prior to joining our esteemed roster of neutrals, Mr. Witkin was active in complex litigation, insurance disputes, and conflict resolution in numerous different states and venues throughout the United States for more than thirty years. In 2000, he co-founded the law firm Menter & Witkin LLP that focused in large part on risk sharing and funding of large lawsuits, which gave him the diverse experience of representing both plaintiffs and defendants, as well as third-party defendants and insurance companies. Mr. Witkin completed mediator training at National Conflict Resolution Center in 2017, and is an AV Rated “Preeminent Attorney” by Martindale-Hubbell (highest rating) and “Super Lawyer” every year since 2015. He may be contacted at g.witkin@amccenter.com or through AMCC at (800) 645-4874. Reprinted courtesy of Arbitration Mediation Conciliation Center (AMCC) Read the court decision
Read the full story...
Reprinted courtesy of

---

Around the State

March 27, 2019 — Richard Glucksman & Chelsea Zwart – Construction Claims Magazine
In late 2018, Governor Jerry Brown signed two potentially impactful Senate bills relating to the construction of apartment buildings. These bills, discussed further below, were introduced, in part, in response to the Berkeley balcony collapse in June 2015, which was determined by the California Contractors State License Board to have been caused by the failure of severely rotted structural support joists—the repairs of which were deferred by the property manager despite indications of water damage. In addition, 2018 saw the passage of California’s updated 2019 Building Energy Efficiency Standards. The new standards, which take effect in 2020, require, in part, the installation of solar systems on certain homes. The goal of the standards is to significantly decrease the energy usage in new homes while contributing to California’s greenhouse gas emissions reduction plans. Relatedly, new legislation, effective in 2019, aims to increase consumer protections for homeowners purchasing solar energy systems. Reprinted courtesy of Richard H. Glucksman, Chapman, Glucksman, Dean, Roeb & Barger and Chelsea Zwart, Chapman, Glucksman, Dean, Roeb & Barger Mr. Glucksman may be contacted at rglucksman@cgdrblaw.com Ms. Zwart may be contacted at czwart@cgdrblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Not So Fast, My Friend: Pacing and Concurrent Delay

April 25, 2022 — William E. Underwood - ConsensusDocs
When critical path activities are delayed by the owner (or another party), contractors will sometimes “pace,” or slow down, other activities to match the owner-caused delay. After all, why should the contractor hurry up and wait? But paced activities can often appear as concurrent delays on a project’s overall schedule. And all too often, contractors fail to contemporaneously document their efforts to pace work. Not only can this create avoidable disputes with owners and other contractors, but it can also create future roadblocks to the recovery of delay damages. This article examines the interplay between pacing and concurrent delay[1] and what contractors should do to minimize risk and preserve their rights to obtain more than a simple time extension for project delays. Pacing versus Concurrent Delay As a basic matter, most contracts allocate responsibility/liability for a schedule delay to the party that caused the delay. For example, if an owner is contractually required to provide equipment for a contractor to install, then the owner likely bears responsibility for any delays caused if the equipment is delivered late. If, however, the contractor was also behind schedule on other activities during this time and the project would have been delayed regardless of the owner’s late deliveries, then the delay is probably concurrent. And the contractor will generally be entitled to only an extension of time, and no other monetary relief. Read the court decision
Read the full story...
Reprinted courtesy of William E. Underwood, Jones Walker LLP (ConsensusDocs)
Mr. Underwood may be contacted at wunderwood@joneswalker.com

---

Florida Legislative Change Extends Completed Operations Tail for Condominium Projects

December 10, 2024 — Holly A. Rice - Saxe Doernberger & Vita, P.C.
The Florida Legislature recently passed House Bill 1021 which amended Florida Statute § 718.124. The July 1, 2024 amendment changes Florida’s statute of repose (“SOR”) trigger date for condominium projects. Now, the SOR trigger for existing condominium projects will be governed by Florida Statute §718.124, not Florida Statute § 95.11. Most critically, Florida Statute § 718.124 changes the trigger events for when the “clock” starts running and impacts how long the SOR runs. Notably, Florida Statute § 718.124 already governed the trigger event for the statute of limitations (“SOR”) for condominium projects. One important overarching takeaway for contractors to carefully assess is that the change in the “trigger” event may result in the SOR concluding at a later date than originally planned – affecting time on the risk and, critically, the availability of insurance. The standard approach of using a static 10-year completed operations tail on a condominium construction insurance program may now be insufficient in certain circumstances. Read the court decision
Read the full story...
Reprinted courtesy of Holly A. Rice, Saxe Doernberger & Vita, P.C.
Ms. Rice may be contacted at HRice@sdvlaw.com

---

EPA Looks to Reduce Embodied Carbon in Materials With $160M in Grants

August 19, 2024 — James Leggate - Engineering News-Record
The U.S. Environmental Protection Agency estimates that construction materials used for buildings and built infrastructure account for more than 15% of global greenhouse gas emissions. The agency now hopes to boost adoption of materials with lower embodied emissions by offering $160 million in grants to better track and ultimately reduce climate pollution associated with those materials. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

From ‘Cuckoo’s Egg’ to Today’s Cyber Threat Landscape

September 02, 2024 — Aarni Heiskanen - AEC Business
In 1990, I read an exciting book titled The Cuckoo’s Egg: Tracking a Spy Through the Maze of Computer Espionage. The author, astronomer Clifford Stoll, managed computers at Lawrence Berkeley National Laboratory (LBNL) in California. He was tasked with resolving an accounting error of 75 cents in the computer usage accounts. The tedious process eventually led him to disclose a German hacker who had gained access to U.S. military secrets through LBNL’s computers. He had been selling information to the KGB for years. Today’s threat landscape in construction The LBNL incident was one of the first—if not the first—documented cases of a computer break-in. Fast-forward to today and cyber-attacks are an everyday phenomenon that occurs more often in construction. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

---

Hawaii Bill Preserves Insurance Coverage in Lava Zones

May 20, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The Hawaii legislature passed a bill in its recently concluded session to protect homeowners and businesses affected by lava flows from losing coverage. The Puna district on the Big Island was severely impacted by the Pu`u O`o lava flow as it crept closer to homes, businesses, schools and populated areas. Problems were created by the imposition of a moratorium on the sale of new policies in certain areas of the Puna district. SB 589 grants relief to homeowners who have had continuous insurance in lava zone areas that are declared to be in a state of emergency. The bill (1) allows the homeowners to have their policies renewed, (2) permits continued coverage for homeowners who wish to sell their homes, (3) grants coverage for new buyers of an insured property, and (4) allows homeowners who have not previously had insurance to purchase coverage from the Hawaii Property Insurance Association. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Unit Owners Have No Standing to Sue under Condominium Association’s Policy

February 10, 2012 — Tred R. Eyerly - Insurance Law Hawaii

If a condominium owner suffers damage caused by a leak from another unit, may it sue the insurer for the Association of Apartment Owner (AOAO) for coverage? The federal district court for Hawaii said "no" in a decision by Judge Mollway. See Peters v. Lexington Ins. Co., 2011 U.S. Dist. LEXIS 148734 (D. Haw. December 27, 2011).



Two cases were consolidated. In each case, Plaintiffs owned condominium units at the Watercrest Resort on Molokai. Water leaking from another unit damaged Plaintiffs’ units.



Watercrest Resort was insured by Lexington pursuant to a policy maintained by the AOAO. Plaintiffs filed claims with Lexington. Lexington hired an adjustor.



Unhappy with the adjustment of their claims, Plaintiffs sued Lexington and the adjustor.

Read the full story…



Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

---