Triple Points to the English Court of Appeal for Clarifying the Law on LDs
July 01, 2019 —
Vincent C. Zabielski & Julia Kalinina Belcher - Gravel2GavelCan an employer recover liquidated damages (LDs) from a contractor if the contract terminates before the contractor completes the work?
Surprisingly, heretofore, English law provided no clear answer to this seemingly straightforward question, and inconsistent case law over the past century has left a trail of confusion. Given the widespread use of English law in international construction contracts, this uncertainty had gone on far too long.
The good news is that drafters of construction contracts throughout the world can now have a well-deserved good night’s sleep courtesy of the English Court of Appeal’s March 2019 decision in Triple Point Technology, Inc. v PTT Public Company Ltd [2019] EWCA Civ 230.
The Triple Point case concerned the delayed supply by Triple Point (the “Contractor”) of a new software system to employer PTT. The contract provided for payments upon achievement of milestones, however order forms incorporated into the contract set out the calendar dates on which fixed amounts were payable by PTT, resulting in an apparently contradictory requirements on when payment was due. Triple Point achieved completion (149 days late) of a portion of the work milestones, and were paid for that work. Triple Point then sought payment for the work which was not yet completed, relying on the calendar dates in the order forms rather than achievement of milestone payments. Things got progressively worse as PTT refused payment, Triple Point suspended the work for PTT’s failure to pay, PTT terminated the contract and then appointed a new contractor to complete the work.
Reprinted courtesy of
Vincent C. Zabielski, Pillsbury and
Julia Kalinina Belcher, Pillsbury
Mr. Zabielski may be contacted at vincent.zabielski@pillsburylaw.com
Ms. Belcher may be contacted at julia.belcher@pillsburylaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Court Finds That Split in Underground Storage Tank is Not a Covered Collapse
July 13, 2017 —
Christopher Kendrick & Valerie A. Moore – Haight Brown & Bonesteel LLPIn Tustin Field Gas & Food v. Mid-Century Ins. Co. (No. B268850, filed 7/3/17), a California appeals court ruled that a split in an underground storage tank, caused by the tank sitting on a rock for years, was not a covered “collapse” as a matter of law.
Tustin Field owned a gas station in Palm Springs. The installer of the underground storage tanks did not follow the manufacturer’s instructions to bury them in pea gravel or crushed rock. Instead, the installer just dug a hole, placed the tanks into that hole, and then covered them with “native soil” containing rocks, boulders and other debris.
The tanks were double-walled, steel with a fiberglass sheath. Sixteen years after installation, testing revealed that the fiberglass sheath on one tank was no longer intact. The tank was excavated and the fiberglass sheath was found to be cracked from the tank sitting on a nine-inch boulder. The insured paid to have the crack repaired and made a claim for the cost of excavating and repairing the tank.
Reprinted courtesy of
Christopher Kendrick, Haight Brown & Bonesteel LLP and
Valerie A. Moore, Haight Brown & Bonesteel LLP
Mr. Kendrick may be contacted at ckendrick@hbblaw.com
Ms. Moore may be contacted at vmoore@hbblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
New York Appellate Division Reverses Denial of Landlord’s Additional Insured Tender
December 07, 2020 —
Eric D. Suben - Traub LiebermanIn Wesco Insurance Co. v. Travelers Property & Cas. Co. of America, 2020 WL 6572489 (1st Dep’t Nov. 10, 2020), the New York Appellate Division found that a commercial landlord was owed additional insured coverage in connection with an incident in which a plaintiff slipped and fell on the sidewalk while exiting the leased premises.
The tenant, Capital One, was the named insured in a CGL policy issued by Travelers. The policy added the landlord as an additional insured, but “only with respect to liability arising out of the ownership, maintenance or use of that part of the premises leased to [Capital One] and shown in the Schedule.” The lease defined the demised premises to include the building and “all appurtenances.”
Travelers denied the landlord’s tender on the basis that the sidewalk did not constitute “that part of the premises leased to” Capital One. In the ensuing declaratory judgment action brought by Wesco (the landlord’s insurer), the court granted Travelers’ motion for summary judgment on this ground.
Read the court decisionRead the full story...Reprinted courtesy of
Eric D. Suben, Traub LiebermanMr. Suben may be contacted at
esuben@tlsslaw.com
General Contractor’s Professional Malpractice/Negligence Claim Against Design Professional
November 30, 2017 —
David Adelstein - Florida Construction Legal UpdatesA recent case supports a professional malpractice (negligence) claim by a general contractor against a design professional by reversing a trial court’s entry of summary judgment in favor of the design professional and finding a question of fact remained as to an architect’s role in the renovation of a public construction project. By the appellate court finding that a question of fact remained, the appellate court was finding that it was a triable issue, which is exactly what the general contractor wanted in this case. Getting this issue and the facts to the jury is the leverage the general contractor presumably wanted.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Florida Construction Legal UpdatesMr. Adelstein may be contacted at
dadelstein@gmail.com
Thinking About a Daubert Motion to Challenge an Expert Opinion?
February 06, 2023 —
David Adelstein - Florida Construction Legal UpdatesWhen you receive an expert opinion, one of the first things you are considering is whether it is worth filing a Daubert motion / challenge. A Daubert motion is a generally a pretrial motion you are using to challenge the admissibility of the expert opinion. Keep in mind this deals with the admissibility, not the credibility, of the expert opinion. A Daubert motion is based on three prongs that must be answered: 1) is the witness qualified to render the expert opinion?; 2) is the expert’s opinion reliable?; and 3) is the expert’s opinion relevant?.
A Daubert motion is premised after Federal Rule of Evidence 702 that provides:
A witness who is qualified as an expert by knowledge, skill, experience, training, or education may testify in the form of an opinion or otherwise if:
- the expert’s scientific, technical, or other specialized knowledge will help the trier of fact to understand the evidence or to determine a fact in issue;
- the testimony is based on sufficient facts or data;
- the testimony is the product of reliable principles and methods; and
- the expert has reliably applied the principles and methods to the facts of the case.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Congratulations to Partner Alex Giannetto for Being Named to San Diego Business Journal’s Top 100 Leaders in Law List
December 03, 2024 —
Dolores Montoya - Bremer Whyte Brown & O'Meara LLPCongratulations to Partner Alexander Giannetto for being selected as a “2024 Leaders of Influence in Law” by the San Diego Business Journal! To read and download the SDBJ publication, please click
here.
Alex Giannetto is a managing partner with Bremer, Whyte, Brown & O’Meara LLP’s San Diego office. He has extensive experience in all aspects of civil litigation handling liability matters including slip and falls, catastrophic injuries, wrongful death, traumatic brain injuries, landslides, and construction claims. He has obtained favorable trial results defending clients on personal injury and premises matters in San Diego and Los Angeles. He also has appellate experience. He is an AV-rated attorney by Martindale-Hubbell who has been voted Best of the Bar in San Diego as well as a Top Lawyer in San Diego.
Read the court decisionRead the full story...Reprinted courtesy of
Dolores Montoya, Bremer Whyte Brown & O'Meara LLP
Surplus Lines Carriers Cannot Compel Arbitration in Louisiana
May 29, 2023 —
Tred R. Eyerly - Insurance Law HawaiiThe court denied the surplus lines insurer's motion to compel arbitration based on Lousiana's law prohibiting arbitrations of coverage disputes. Fairway Village Condominiums v. Independent Spec. Ins. Co., 2023 U.S. Dist. LEXIS 62135 (E.D. La. April 20, 2023).
The plaintiff's condominium complex was damaged by Hurricane Ida. A claim was filed with the insurer. The insurer made an initial advance payment of $200,000. Three additional payments were made bringing the total to $951,462.49, which was less than half of the proof of loss amounts submitted by plaintiff.
Plaintiff sued the insurer for breach of contract and bad faith. The insurer filed a motion to compel arbitration based upon an arbitration provision in the policy. Recognizing that Louisiana law prohibited enforcement of a policy's arbitration clause, the insurer argued it did not apply because it was a surplus lines carrier.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Look Up And Look Out: Increased Antitrust Enforcement Of Horizontal No-Poach Agreements Signals Heightened Scrutiny Of Vertical Agreements May Be Next
November 28, 2022 —
John F. Finnegan, III & Dominick Weinkam - ConsensusDocsIn the current regulatory environment, it is important for contractors to remain vigilant of heightened anti-competitive enforcement in the construction and procurement spheres by the United States Department of Justice (DOJ). Such vigilance should include, among other things, regular review of applicable laws and implementation of related updates to compliance policies, as well as careful evaluation of joint venture (JV), subcontractor, and teaming agreements.
Recent DOJ Activity Opens The Door To Broader Antitrust Exposure For Contractors
Many contractors include exclusivity and non-compete clauses in their vertical agreements, including subcontractor agreements and certain types of JV and teaming agreements. In fact, many widely available “checklists” for drafting these agreements recommend including such provisions; however, under U.S. antitrust law, particularly as enforced by the DOJ in the last 1-2 years, exclusivity and non-compete clauses may be construed as unduly competition-restricting. Although no court has yet held that exclusivity and non-compete clauses in vertical agreements violate antitrust laws, recent aggressive enforcement activity by the DOJ with regard to horizontal no-poach agreements suggests that the investigatory headwinds may be blowing in that direction.
Reprinted courtesy of
John F. Finnegan, III, Watt, Tieder, Hoffar, & Fitzgerald, LLP (ConsensusDocs) and
Dominick Weinkam, Watt, Tieder, Hoffar, & Fitzgerald, LLP (ConsensusDocs)
Mr. Finnegan may be contacted at jfinnegan@watttieder.com
Mr. Weinkam may be contacted at dweinkam@watttieder.com
Read the court decisionRead the full story...Reprinted courtesy of