Seattle Washington Building Expert Directory

Ongoing Operations Exclusion Bars Coverage

December 09, 2019 — Tred R. Eyerly - Insurance Law Hawaii
The insurer denied the insured contractor's claim seeking a defense for faulty workmanship based upon the ongoing operations exclusion. PJR Constr. of N.J. v. Valley Forge Ins. Co., 2019 U.S. Dist. LEXIS 127973 (D. N. J. July 31, 2019). PJR Construction was the general contractor to build a swim club and pavilion building for Cambridge Real Property, LLC. PJR began construction on May 29, 2012, and was to complete the construction by March 1, 2013. The project took much longer than anticipated. PJR was denied access to the site on November 13, 2014. Cambridge contended PJR tolerated shoddy workmanship and breached the terms of the contract documents. Cambridge estimated that the project was between 55% and 74.3% complete. PJR and Cambridge went to arbitration. PJR sought a defense from the insurers. Coverage was denied based upon exclusions j (5) and j (6). Exclusion j (5), which the court referred to as the "Ongoing Operations Exclusion," provided the policy did not apply to,

Property Damage to . . . [t]hat particular part of real property on which you or any contractors or subcontractors working directly or indirectly on your behalf are performing operations, if the property damage arises out of those operations.

Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Insurer Defends Denial in Property Coverage Dispute Involving Marijuana Growing Operations

March 14, 2018 — Michael Levine and Geoffrey Fehling - Hunton Insurance Recovery Blog
Last month, we reported on the ongoing insurance coverage dispute between commercial landlord KVP Properties, Inc. and its property insurer, Westfield Insurance Company. The dispute arises from an October 2015 DEA raid on KVG-owned rental units in Novi, Michigan, which uncovered damage to the units related to the tenants’ marijuana growing operations. The arguments raised by KVG on appeal highlight a number of important marijuana-related coverage issues, which Westfield has now addressed in opposition. Reprinted courtesy of Michael Levine, Hunton & Williams LLP and Geoffrey Fehling, Hunton & Williams LLP Mr. Levine may be contacted at mlevine@hunton.com Mr. Fehling may be contacted at gfehling@hunton.com Read the court decision
Read the full story...
Reprinted courtesy of

New World to Demolish Luxury Hong Kong Towers in Major Setback

August 04, 2021 — Shawna Kwan - Bloomberg
New World Development Co. will demolish two towers at Hong Kong’s most popular housing development in decades and compensate buyers after finding unexpected defects, in a major setback for the real estate company. The developer will pull down and rebuild the existing floors of Towers 1 and 8 at its Pavilia Farm III project near Tai Wai station after it found the concrete strength in some areas did not meet design requirements, the Hong Kong-based company said in a statement. Shares of New World fell as much as 4.8% Thursday in Hong Kong, the most in more than seven months, before recovering to close 3.9% lower. Read the court decision
Read the full story...
Reprinted courtesy of Shawna Kwan, Bloomberg

CGL Coverage for Liquidated Damages and the Contractual Liability Exclusion

October 09, 2023 — Stu Richeson - The Dispute Resolver
Liquidated delay damages are common in construction contracts and are generally imposed when a contractor fails to achieve substantial completion within the time required by the contract. While contracts like the AIA A201-2017 have provisions for extending the time to achieve substantial completion when delays are caused by circumstances beyond the contractor’s control, delays can result from factors other than improper management or planning and the like, for which the owner is not required to give the contractor additional time. Courts are split on whether there is ever coverage under a CGL policy for contractually agreed upon liquidated delay damages. Liquidated delay damages are often excluded under the contractual liability exclusion of most CGL policies. The contractual liability exclusion excludes coverage for “liability for which the Insured is obligated to pay damages by reason of the assumption of liability in a contract or agreement.” Courts often find the contractual liability exclusion in a CGL policy precludes coverage for liquidated delay damages, because such damages are contractual in nature and are triggered by the failure to bring the contract to substantial completion by a fixed deadline, regardless of the cause of the delay. However, some courts will look to the cause of the delay and find that there is coverage under a CGL policy for liquidated delay damages that are the result of property damage caused by an accident or occurrence. In Clark Const. Grp., Inc. v. Eagle Amalgamated Serv., Inc., 01-2478-DV, 2005 WL 2092998, at *1 (W.D. Tenn. Aug. 24, 2005) a general contractor entered a contract for the renovation of the convention center in Memphis. Part of the project included the demolition of a structure attached to the convention center. The demolition work was improperly performed by a subcontractor and resulted in damage to the convention center. Read the court decision
Read the full story...
Reprinted courtesy of Stu Richeson, Phelps
Mr. Richeson may be contacted at stuart.richeson@phelps.com

What to Know Before Building a Guesthouse

September 17, 2014 — Cynthia Flash – Bloomberg
Those tiny, often very cute homes that people are adding on their properties seem to be popping up everywhere these days. The tiny buildings can provide extra rental income, offer a less-expensive housing option or provide a home for a relative. Accessory dwelling units, or ADUs, are second dwelling units created on a lot with an existing house or attached house. They’re often referred to as mother-in-law apartments, granny flats or studio apartments. As a homeowner, what are the legal issues to consider before building an ADU of your own? Different cities, different rules First off, different cities have different rules. Before plotting the space for your new tiny house, check with your city’s planning and zoning department to determine what those rules are. You can start online at accessorydwellings.org for a list of regulations by state and city. Read the court decision
Read the full story...
Reprinted courtesy of Cynthia Flash, Bloomberg

New York Court of Appeals Finds a Proximate Cause Standard in Additional Insured Endorsements

June 15, 2017 — Geoffrey Miller - Saxe Doernberger & Vita, P.C.
In The Burlington Insurance Company v. NYC Transit Authority, et al., No. 2016-00096, the New York Court of Appeals issued a landmark decision with regard to the meaning of “caused, in whole or in part, by” in the additional insured context. In a split decision, the court rejected Burlington Insurance Company’s argument that the language implied a “negligence” standard, but held that coverage was provided to the additional insured only where the named insured’s acts or omissions were the proximate cause of the injury:

While we [the majority] agree with the dissent that interpreting the phrases differently does not compel the conclusion that the endorsement incorporates a negligence requirement, it does compel us to interpret ‘caused, in whole or in part’ to mean more than ‘but for’ causation. That interpretation, coupled with the endorsement’s application to acts or omissions that result in liability, supports our conclusion that proximate cause is required here.[1]

Read the court decision
Read the full story...
Reprinted courtesy of Geoffrey Miller, Saxe Doernberger & Vita, P.C.
Mr. Miller may be contacted at gjm@sdvlaw.com

Newmeyer Dillion Named 2021 Best Law Firm in Multiple Practice Areas by U.S. News-Best Lawyers

November 09, 2020 — Newmeyer Dillion
Prominent business and real estate law firm Newmeyer Dillion is pleased to announce that U.S. News-Best Lawyers® has recognized the firm in its 2021 "Best Law Firms" rankings, in six practice areas earning the highest ranking possible - Tier 1 in the Orange County Metro area. The practices recognized include Commercial Litigation, Insurance Law, Real Estate Law, Litigation - Real Estate, Construction Law, and Litigation - Construction. Firms included in the 2021 "Best Law Firms" list have been recognized by their clients and peers for their professional excellence. Firms achieving a Tier 1 ranking have consistently demonstrated a unique combination of quality law practice and breadth of legal expertise. "We are grateful that our relationship-first approach to propel our clients' needs forward has received this recognition," said Managing Partner Paul Tetzloff. "We will continue to show our appreciation through hard work in advocating for our clients and communities." To be eligible for the "Best Law Firms" ranking, a firm must have at least one attorney recognized in the current edition of The Best Lawyers in America for a specific practice area. Best Lawyers recognizes the top 4 percent of practicing attorneys in the U.S., selected through exhaustive peer-review surveys in which leading lawyers confidentially evaluate their professional peers. About Newmeyer Dillion For over 35 years, Newmeyer Dillion has delivered creative and outstanding legal solutions and trial results that achieve client objectives in diverse industries. With over 60 attorneys working as a cohesive team to represent clients in all aspects of business, employment, real estate, environmental/land use, privacy & data security and insurance law, Newmeyer Dillion delivers holistic and integrated legal services tailored to propel each client's operations, growth, and profits. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California and Nevada, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949.854.7000 or visit www.newmeyerdillion.com. Read the court decision
Read the full story...
Reprinted courtesy of

New Jersey Condominium Owners Sue FEMA

June 11, 2014 — Beverley BevenFlorez-CDJ STAFF
Owners of a 230-unit New Jersey Condominium filed suit “against the Federal Emergency Management Agency and insurers and developers, seeking coverage and alleging the building was constructed with defects that led to severe flood damage during Hurricane Sandy.” According to Law 360, “[t]he complaint from 700 Grove Condominium Association Inc. alleges that common elements of the building were damaged and will continue to be damaged from floods because of defects caused by its contractors and architects.” The owners, according to the complaint, alleged that they “made a timely claim to its insurers, but [the insurers] denied coverage.” Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES