Fairfield Connecticut Building Expert Directory

U.S. Supreme Court Limits the Powers of the Nation’s Bankruptcy Courts

June 11, 2014 — Earl Forte – White and Williams LLP
On June 9, 2014, the Supreme Court of the United States issued its much-awaited decision in Executive Benefits Insurance Agency v. Arkison, Chapter 7 Trustee of Estate of Bellingham Insurance Agency, Inc., Case No. 12-1200, in which the court confirmed that the power of the nation’s bankruptcy courts to hear and decide cases involving state-created private rights in which the bankruptcy proof of claim process has not been directly invoked, is severely limited by Article III of the Constitution of the United States. The decision in Executive Benefits, while providing some clarity to practitioners and the public following the Court’s June 2011 decision in Stern v. Marshall, 131 S. Ct. 2594 (2011), nevertheless will make a substantial portion of bankruptcy litigation matters more cumbersome and potentially more expensive to guide through the bankruptcy system. Clients and practitioners are best advised to hire knowledgeable counsel to help navigate the more complex procedural waters created by this decision. Although the Court in Executive Benefits did resolve a pending procedural question that had dogged practitioners since Stern was decided in 2011, the Court’s decision in Executive Benefits now makes it abundantly clear that many disputes that were previously heard and decided in the nation’s bankruptcy courts can no longer be decided there and must be submitted to the district courts for full de novo review and entry of a final judgment or order. It is difficult to see how this decision will not make bankruptcy litigation more cumbersome and expensive by adding an additional layer of judicial involvement to many matters, notably to fraudulent transfer and other avoidance “claw back” actions that historically have been decided in the bankruptcy courts and used famously in Madoff and other cases as an efficient device for creating value for creditors. Read the court decision
Read the full story...
Reprinted courtesy of Earl Forte, White and Williams LLP
Mr. Forte may be contacted at fortee@whiteandwilliams.com

A Discussion on Home Affordability

April 08, 2014 — Beverley BevenFlorez-CDJ STAFF
Krishna Rao, in the online publication Zillow Real Estate Research, analyzed statistics on home price affordability across the United States. Rao found that “[a]cross the United States, strong home price affordability has been recently eroded by a combination of rising home prices and mortgage rates. Some areas, particularly on the West Coast, have begun to look unaffordable compared to their historic norms, forcing some household to look to the periphery of urban areas in search of affordable homes.” However, John McManus in Big Builder said a more helpful term when looking at the new home market would be “relative affordability (which inheres both payment power and access to credit).” “Little attention has been given to the fact that many builders' mix--first- and second-time move-up and higher end homes.” McManus wrote that this “has skewed pricing conversations. When the buyer is ‘discretionary,’ has access to cash and no impediment of another property to sell in order to trigger a purchase--then both base price and price elasticity can be greater.” Read the full story, Zillow... Read the full story, Big Builder... Read the court decision
Read the full story...
Reprinted courtesy of

Baltimore Bridge Collapse Occurred After Ship Lost Power Multiple Times

May 28, 2024 — Allyson Versprille - Bloomberg
The container ship that rammed into Baltimore’s Francis Scott Key Bridge in March lost power multiple times on both the day of the fatal accident and the day before, according to a preliminary report. The Dali, which sails under the flag of Singapore, lost power twice on March 26 before hitting the bridge and causing it to collapse, killing six construction workers who were on the structure at the time. The first blackout was caused when electrical breakers powering most of the vessel’s equipment and lighting unexpectedly tripped, the National Transportation Safety Board said in a report Tuesday. The crew eventually was able to restore electrical power, but then a second blackout occurred only 0.2 miles from the bridge. They regained power, but the ship lacked the propulsion needed to avoid striking the bridge, safety inspectors found. Read the court decision
Read the full story...
Reprinted courtesy of Allyson Versprille, Bloomberg

How Does Your Construction Contract Treat Float

November 08, 2017 — David Adelstein - Florida Construction Legal Updates
Although there are different types of construction schedule float and more technical definitions, the definition that makes sense to me is that float is the amount of time a particular activity can be delayed without that activity delaying the project’s completion date (substantial completion date). In looking at a construction schedule, this determination is made from looking at the difference between the early start date for an activity and the late start date for that activity or the difference between the early finish date for that activity and the late finish date for that activity in your CPM schedule (which should be the same amount of time). This is often referred to as “total float” and is the float that I usually focus on since it may pertain to a delay to the substantial completion date of the project and can trigger either the assessment of liquidated damages and/or the contractor’s extended general conditions, whatever the case may be. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at Dadelstein@gmail.com

California Statutes Authorizing Public-Private Partnership Contracting

February 01, 2022 — Robert A. James & Shade Oladetimi - Gravel2Gavel Construction & Real Estate Law Blog
Public-private partnerships are often cited as a key pathway to restoring and enhancing the nation’s infrastructure. They can be challenging arrangements to structure. (As a result of the pandemic, they have even suffered the indignity of having their “PPP” acronym coopted by the Paycheck Protection Program. With apologies to Small Business Administration practitioners, we use “PPP” in this article to refer to the infrastructure tool.) One gating condition to setting up a PPP is identifying the authority for a public entity to use a contracting method that does not run afoul of the general requirements that (i) works of improvement be let to the lowest responsive bid by a responsible bidder and (ii) design services be awarded through a qualifications-based selection process. Integrated forms of project delivery that vest in a single concessionaire multiple design, construction, financing, operation, maintenance and entrepreneurial roles must find an exception to any applicable background rules. Reprinted courtesy of Robert A. James, Pillsbury and Shade Oladetimi, Pillsbury Mr. James may be contacted at rob.james@pillsburylaw.com Ms. Oladetimi may be contacted at shade.oladetimi@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Health Care Construction Requires Compassion, Attention to Detail and Flexibility

July 01, 2019 — Coker Barton - Construction Executive
When it comes to renovating and expanding hospitals, there is one principle that everyone can agree on: patients, family and hospital staff must be placed at the forefront of every stage of the job, ultimately dictating the project’s timeline. For a health care project to be a success, a general contractor needs to have industry-specific experience, must emphasize communication and scheduling and—most importantly—have a passion for the industry. Capably and safely work in a health care environment Health care requires a level of detail and understanding of the industry that is not found in other construction sectors. Builders must focus on infection control and interim life safety measures to protect patients, visitors and staff. There is accountability involved that goes beyond completing a project right on schedule. For example, the expansion of The Studer Family Children’s Hospital at Sacred Heart in Pensacola, Fla., included a new 175,000-square-foot tower in addition to building out space above the Neonatal Intensive Care Unit. Anytime the contractor is building next to or over patients, especially those who are most vulnerable, it is on alert. It sets up containment areas, which help maintain the negative pressure in the construction area by pulling air in versus blowing dirty air out, as well as keep dust and other contaminants inside the construction area. There is no room for mistakes, which is why these techniques require more training and experience to properly execute. Reprinted courtesy of Coker Barton, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Surfside Condo Collapse Investigators Uncover More Pool Deck Deviations

September 12, 2023 — James Leggate - Engineering News-Record
The investigation into the 2021 collapse of the Champlain Towers South condominium in Surfside, Fla., has uncovered more deviations between the as-built conditions of the pool deck and the building’s design. But investigators emphasize their data are still preliminary as they continue to gather and test evidence from the collapse that killed 98 people. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES