FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Common Construction Contract Provisions: No-Damages-for-Delay Clause

March 16, 2017 — David Cook & Chadd Reynolds - Autry, Hanrahan, Hall & Cook, LLP Blog
In continuing our series on common contract provisions found in construction contracts, this post highlights no-damages-for-delay clauses. Parties to a contract – particularly a construction contract – may agree that the performance of the contract must occur within a set amount of time. When a party is delayed in performing a contract, it may incur additional costs due to the delay. In most circumstances, unless the parties agree otherwise, the delayed party would be entitled to an extension of time to perform the contract. But it may also seek to recover the additional costs resulting from the delay. A no-damages-for-delay clause attempts to prevent the delayed party from recovering those additional costs. In construction contracts, an upstream party, such as an owner or prime contractor, typically relies on a no-damages-for-delay clause when presented with a delay claim by a downstream party, such as a subcontractor. Reprinted courtesy of David Cook, Autry, Hanrahan, Hall & Cook, LLP and Chadd Reynolds, Autry, Hanrahan, Hall & Cook, LLP Mr. Cook may be contacted at cook@ahclaw.com Mr. Reynolds may be contacted at reynolds@ahclaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

No Damage for Delay? No Problem: Exceptions to the Enforceability of No Damage for Delay Clauses

October 18, 2021 — Chris Broughton, Jones Walker LLP - ConsensusDocs
Introduction: Under a no-damage-for-delay clause, the owner is not liable for any monetary damages resulting from delays on the project. In lieu of monetary recovery, the contractor’s remaining remedy is a non-compensatory time extension. These clauses are common at the contractor-subcontractor interface as well. While no-damage-for-delay clauses are enforced in most jurisdictions, some states, either by statute or case law, have limited the enforceability of no-damage-for-delay clauses. Other states have also limited the enforceability of these clauses on state government contracts, and a select few have outlawed them on all projects regardless if they are publicly or privately owned. Additionally, for subcontractors on federal projects, the Miller Act may provide a way to avoid no-damage-for-delay and recover against the general contractor’s payment bond. This article provides an overview of no-damage-for-delay clauses and the exceptions to enforcement of these clauses. However, due to the consequences of a no-damage-for-delay clause, it is important to know the terms of your contract and the law that governs your project. Read the court decision
Read the full story...
Reprinted courtesy of Chris Broughton, Jones Walker LLP
Mr. Broughton may be contacted at cbroughton@joneswalker.com

---

Assessments Underway After Hurricane Milton Rips Off Stadium Roof, Snaps Crane Boom in Florida

November 05, 2024 — James Leggate - Engineering News-Record
Hurricane Milton and tornados it spurred killed at least five people and knocked out power to 4 million homes and businesses in Florida after making landfall Oct. 9 near Siesta Key in Sarasota County. With assessments and rescues still underway, state officials say the damage was not as bad as it could have been. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

After Elections, Infrastructure Talk Stirs Again

December 04, 2018 — Tom Ichniowski - Engineering News-Record
In the wake of Democrats’ House takeover and Republicans widening their Senate majority in the midterm elections, talk has quickly revived about taking on infrastructure legislation in the new Congress. Construction industry officials welcome the pro-infrastructure rhetoric from congressional leaders and President Trump. But it remains to be seen whether the words will spark a bill that can make it through a divided 116th Congress. Funding the package remains the high hurdle. Read the court decision
Read the full story...
Reprinted courtesy of Tom Ichniowski, ENR
Mr. Ichniowski may be contacted at ichniowskit@enr.com

---

Deadline Nears for “Green Performance Bond” Implementation

December 03, 2024 — Christopher G. Hill - Construction Law Musings
For this weeks Guest Post Friday at Musings, we welcome Surety Bonds.com, a leading online surety provider. SuretyBonds.com specializes in educating current and prospective business owners about local surety requirements. To keep up with surety bond trends, follow and Surety Bonds Insider blog and @suretybond on Twitter. Professionals who work in the construction industry know the laws that regulate the market change constantly. Unfortunately, even government agencies are flawed, which means they sometimes establish nonsensical, arbitrary regulations that leave construction professionals even more confused as to how they’re expected to do their jobs. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

Business Solutions Alert: Homeowners' Complaint for Breach of Loan Modification Agreement Can Proceed Past Pleading Stage

October 08, 2014 — Krsto Mijanovic, Annette Mijanovic, Blythe Golay - Haight Brown & Bonesteel LLP
In Fleet v. Bank of America, N.A. (No. G050049, published 9/23/14, filed 8/25/14), a California Court of Appeal held that the trial court erred in sustaining the demurrer of a lender, where the homeowners had adequately alleged causes of action for breach of contract, fraud, and promissory estoppel. The homeowners alleged that they made timely payments during the trial period plan under the modification program, but before the last payment was due, the lender foreclosed and their house was sold. The homeowners had applied for a loan modification and were approved for a trial period plan under the modification program. They were required to make three monthly payments and verify financial hardship to permanently modify their loan. The homeowners made two payments and were told that foreclosure proceedings had been suspended. But before the third payment was due, the lender foreclosed. The trial court found that the trial period plan was not a binding loan modification agreement, so the homeowners had no right to any guaranteed loan modification. Reprinted courtesy of Haight Brown & Bonesteel LLP attorneys Krsto Mijanovic, Annette Mijanovic and Blythe Golay Mr. Mijanovic may be contacted at kmijanovic@hbblaw.com Ms. Mijanovic may be contacted at amijanovic@hbblaw.com Ms. Golay may be contacted at bgolay@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

The “Your Work” Exclusion—Is there a Trend against Coverage?

September 10, 2014 — Craig Martin – Construction Contractor Advisor
Two more courts have weighed in on the “your work” exclusion in commercial general liability (CGL) policies, finding that contractors did not have coverage for work performed improperly. These cases highlight that whether you have coverage for poor workmanship will depend on the state’s law applied. It now appears that if you are in South Carolina or Massachusetts, you will not have coverage. The South Carolina case, Precision Walls, Inc. v. Liberty Mutual Fire Insurance Company, involved a subcontractor hired to tape insulation. After taping the insulation, a brick veneer was installed on the exterior. During the brick installation, the mason reported that the tape was losing its adhesion and the subcontractor was instructed to repair the problem. In order to access the tape, portions of the brick veneer had to be removed and re-installed. The subcontractor then sought coverage for the costs associated with repairing the tape. The insurer denied coverage and the subcontractor sued its insurer. The court ruled in favor of the insurer, finding that the defective tape was “your work” because it was “material furnished in connection” with the subcontractor’s work. The policy specifically excluded from coverage damage to property caused by “your work”. Thus, there was no coverage for the subcontractor. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

---

Subcontractor Exception to "Your Work" Exclusion Does Not Apply to Coverage Under Subcontractor's Policy

January 26, 2017 — Tred R. Eyerly – Insurance Law Hawaii
The Arizona Court of Appeals overturned the trial court's determination that the general contractor was entitled to coverage under the subcontractor's exception to the "Your Work" exclusion. Double AA Builders v. Preferred Contrs. Ins. Co., 2016 Ariz. App. LEXIS 294 (Ariz. Ct. App. Dec. 30, 2016). Harkins Theatres hired Double AA Builders, Ltd. to serve as general contractor to build a theater complex. Double AA subcontracted with Anchor Roofing, Inc. to install the roof. Anchor was the "Named Insured" under a policy issued by Preferred Contractors Insurance Company, LLC. Double AA was an "Additional Insured" under the Preferred policy. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---