FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

---

Incorporation, Indemnity and Statutes of Limitations, Oh My!

January 19, 2017 — Christopher G. Hill – Construction Law Musings
We all know that the contract is king in Virginia. We also know that Virginia will allow for a so called “incorporation” clause that will allow for “flow down” of certain prime contract provisions in a way that will make those provisions applicable to subcontractors. We also know that a claim for breach of contract or other contractual claim does not last forever due to certain statutes of limitation found in the Code of Virginia. What happens when all of these elements crash together in one place leading to litigation? Well, a relatively recent case from the Virginia Supreme Court gives at least a partial answer. In Hensel Phelps Construction Company v Thompson Masonry Contractor, Inc, the Virginia Supreme Court considered a claim that arose from construction at Virginia Tech by Hensel Phelps. The construction concluded in 1998 (remember that date). The Prime Contract included language concerning a one year “Guarantee of Work” as well as fairly typical Warranty of Workmanship” language. However the Prime Contract also stated that the one year guaranty term did nothing to affect any other limitations period for any other action pursuant to the Prime Contract (this is important as well because Virginia Tech was not subject to any statute of limitations due to its status as an agency of the Commonwealth of Virginia). Final payment was made to Hensel Phelps and subsequently to the subcontractors in 1999. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

Useful Life: A Valuable Theory for Reducing Damages

March 29, 2017 — Brooke E. Beebe, Esq. - Florida Construction Law News
The situation is one all too familiar to construction defect litigants. A homeowner contracts with a roofing contractor to install a new roof with a life expectancy of ten years.[1] After only five years, the homeowner brings a claim for construction defects in the roof alleging that the roof requires complete replacement due to water intrusion. The homeowner seeks damages for the full replacement cost of the roof. However, under a “useful life” theory, the homeowner would not be entitled to damages for the full amount of the replacement cost. Instead, the homeowner would be entitled to one-half of the cost of the replacement roof, taking into account the fact that he or she had been deprived of only five, rather than ten, years of use. “Useful life” is best understood as the expected length of time that a newly built construction element can be reasonably anticipated to last, subject to routine maintenance and ordinary wear and tear. The “useful life” theory holds that granting the homeowner damages for the full replacement cost of the roof would result in unjust enrichment to the homeowner, who had contracted for a roof with a ten-year, rather than a fifteen-year, useful life. Read the court decision
Read the full story...
Reprinted courtesy of Brooke E. Beebe, Cole, Scott & Kissane, P.A.
Ms. Beebe may be contacted at brooke.beebe@csklegal.com

---

Haight has been named a Metropolitan Los Angeles Tier 1 “Best Law Firm” and Tier 2 for Orange County by U.S. News – Best Lawyers® “Best Law Firms” in 2023

November 21, 2022 — Haight Brown & Bonesteel
Haight Brown & Bonesteel LLP is listed in the U.S. News – Best Lawyers® (2023 Edition) “Best Law Firms” list with metro rankings in the following areas: Los Angeles

• Metropolitan Tier 1
• Insurance Law
• Product Liability Litigation – Defendants

Orange County

• Metropolitan Tier 2
• Product Liability Litigation – Defendants

Read the court decision
Read the full story...
Reprinted courtesy of Haight Brown & Bonesteel

---

Seventh Circuit Remands “Waters of the United States” Case to Corps of Engineers to Determine Whether there is a “Significant Nexus”

July 10, 2018 — Anthony B. Cavender - Gravel2Gavel Construction & Real Estate Law Blog
On June 27, the U.S. Court of Appeals for the Seventh Circuit decided the case of Orchard Hill Building Co. v. U.S. Army Corps of Engineers. The Court of Appeals vacated the decision of the District Court granting the U.S. Army Corps of Engineers’ (Corps) motion for summary judgment dismissing the Orchard Hill Building Company’s (Orchard) complaint that the Corps’ jurisdictional determination erroneously found that the waters at issue were “jurisdictional waters” under the Clean Water Act (CWA) subject to the Corps’ jurisdiction. Acknowledging that the Corps and EPA had promulgated a new rule re-defining “waters of the United States” in 2015—which is now being challenged in the courts—the Court of Appeals noted that this case is controlled by the pre-2015 definition of “waters of the United States.” The Court of Appeals remanded the case to the Corps, directing it to determine if there was a significant nexus, as required. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury Winthrop Shaw Pittman LLP
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

---

Homebuilders Opposed to Potential Change to Interest on Construction Defect Expenses

January 22, 2013 — CDJ STAFF
In 2008, the Colorado Supreme Court concluded that in calculating interest on the expense of repairing construction defects would start at the time that the defect was repaired. In 2009, the Colorado State Legislature introduced a bill that would have made homeowners eligible for interest back to the purchase date of their homes. The Colorado Springs Business Journal notes that the Colorado Springs Housing and Building Association is concerned that the legislature might take up the issue again, in which case, the HBA would oppose it. Read the court decision
Read the full story...
Reprinted courtesy of

---

Solar and Wind Just Passed Another Big Turning Point

October 21, 2015 — Tom Randall – Bloomberg
Wind power is now the cheapest electricity to produce in both Germany and the U.K., even without government subsidies, according to a new analysis by Bloomberg New Energy Finance (BNEF). It's the first time that threshold has been crossed by a G7 economy.1increase click area But that's less interesting than what just happened in the U.S. To appreciate what's going on there, you need to understand the capacity factor. That's the percentage of a power plant's maximum potential that's actually achieved over time. Consider a solar project. The sun doesn't shine at night and, even during the day, varies in brightness with the weather and the seasons. So a project that can crank out 100 megawatt hours of electricity during the sunniest part of the day might produce just 20 percent of that when averaged out over a year. That gives it a 20 percent capacity factor. One of the major strengths of fossil fuel power plants is that they can command very high and predictable capacity factors. The average U.S. natural gas plant, for example, might produce about 70 percent of its potential (falling short of 100 percent because of seasonal demand and maintenance). But that's what's changing, and it's a big deal. Read the court decision
Read the full story...
Reprinted courtesy of Tom Randall, Bloomberg

---

Efficient Proximate Cause Doctrine Bars Coverage for Collapse of Building

July 31, 2013 — Tred Eyerly, Insurance Law Hawaii
The court rejected the insured's argument that there was coverage for the collapse of a building caused by water leakage (a covered peril) and landslide (an uncovered peril). Stor/Gard, Inc. v. Strathmore Ins. Co., 2013 U.S. LEXIS App. 11015 (1st Cir. May 31, 2013). A severe rain storm caused soil to slide down a hill and over a retaining wall, thereby damaging a building owned by the insured. Investigators hired by Strathmore Insurance Company determined that rain had soaked into the soil, causing the landslide. Although the investigators found some water leakage, they determined the leakage was not a cause or contributing factor, and was negligible compared to the rain amount. The insured's policy with Strathmore was an all-risk policy. Loss caused by a landslide was excluded. Further, loss caused by collapse was excluded from coverage except as set forth in the policy's "additional coverage for collapse" section. This section provided coverage for a collapse caused by water damage or a leakage of water. Another exclusion barred coverage for loss caused by weather conditions. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

---