Cambridge Massachusetts Building Expert Directory

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Vacant Property and the Right of Redemption in Pennsylvania

April 06, 2016 — Suzanne Prybella – White and Williams LLP
In Pennsylvania, pursuant to the Municipal Claims and Tax Liens Act (53 P.S. §7293(a)) (the Act), the owner of a property sold under a tax or municipal claim may redeem the sold property at any time within nine months after the date of acknowledgment of the sheriff's deed by, in general, paying the amount of the debt. However, there is a caveat contained in the Act with respect to vacant property, which states that “there shall be no redemption of vacant property by any person after the date of the acknowledgment of the sheriff's deed.” (53 P.S. §7293(c)). In Brentwood Borough School District v. HSBC Bank USA, N.A., 111 A.3d 807 (Pa. Commw. Ct. 2015), a case of first impression before the Commonwealth Court of Pennsylvania, the court addressed the definition of “vacant property” under the Act and the timing of a petitioner to invoke the right of redemption with respect to vacant property. Read the court decision
Read the full story...
Reprinted courtesy of Suzanne Prybella, White and Williams LLP
Ms. Prybella may be contacted at prybellas@whiteandwilliams.com

Amazon Urged to Review Emergency Plans in Wake of Deadly Tornado

June 20, 2022 — Spencer Soper - Bloomberg
Amazon.com Inc. should better prepare workers for extreme weather events, according to federal regulators who investigated a deadly tornado strike on a company warehouse in Edwardsville, Illinois. The storm ripped through the facility in December, killing six workers and injuring several others, prompting the Occupational Safety and Health Administration to launch a probe. At the time, Amazon said the facility complied with all construction regulations and that proper safety procedures were followed when the tornado struck. But several workers told Bloomberg that training for such events was minimal and mostly entailed pointing out emergency exits and assembly points. An OSHA report released on Tuesday echoed those concerns. The agency said a bullhorn that was supposed to be used to tell workers to take cover was locked up in a cage and inaccessible. In interviews with investigators, some employees couldn’t recall ever participating in emergency drills and said they mistakenly took shelter in a bathroom on the south side of the building rather than in designated restrooms on the north side. Read the court decision
Read the full story...
Reprinted courtesy of Spencer Soper, Bloomberg

Managing Infrastructure Projects with Infrakit – Interview with Teemu Kivimäki

June 09, 2016 — Aarni Heiskanen – AEC Business
Finland has been in the vanguard in adopting building information modeling (BIM) for infrastructure construction. In this interview I discuss with Teemu Kivimäki, CEO of DCS Finland, how Infrakit helps in projects that use BIM. Can you say a few words about the background of your company and how Infrakit came about? The background of DCS Finland (short for Digital Construction Solutions Finland) is in research done in University of Oulu where I worked as a research scientist on construction automation from 2007 to 2010. We were doing research with big infrastructure construction companies, exploring ways to improve worksite management and data flow. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aarni@aepartners.fi

Expert Medical Science Causation Testimony Improperly Excluded under Daubert; ID of Sole Cause of Medical Condition Not Required

April 15, 2014 — R. Bryan Martin & Whitney L. Stefko - Haight Brown & Bonesteel LLP
On April 4, 2014, in Messick v. Novartis Pharmaceuticals Corp., the United States Court of Appeals for the Ninth Circuit reversed the district court's summary judgment in favor of Defendant Pharmaceutical Corporation because the district court improperly excluded expert testimony. The three-judge panel held that the district court erred by excluding causation testimony offered by Plaintiff's expert it found to be irrelevant and unreliable. Plaintiff was diagnosed with breast cancer in 2000. In response to her development of osteoporosis after chemotherapy, Plaintiff treated with the drug Zometa for several months in 2002. Zometa is a bisphosphonate, a class of drug commonly used to treat multiple myeloma. Such drugs are generally used to reduce or eliminate the possibility of skeletal-related degeneration and injuries to which cancer patients are particularly susceptible. Novartis Pharmaceuticals Corporation produces Zometa, which was approved by the FDA in 2001 and 2002. In 2005 after encountering issues with her jaw, it was discovered that Plaintiff had osteonecrosis near three of her teeth. The oral specialists treating Plaintiff did so under the assumption that she was suffering from bisphosphonate-related osteonecrosis of the jaw ("BRONJ"), a condition recognized by the American Association of Oral and Maxillofacial Surgeons ("AAOMS"). Plaintiff's BRONJ healed in 2008 - three years after beginning treatment. Thereafter, Plaintiff brought suit against Novartis for strict products liability, negligent manufacture, negligent failure to warn, breach of express and implied warranty, and loss of consortium. In support of her claims, Plaintiff offered her expert's testimony on ONJ and BRONJ, and on the causal link between plaintiff's bisphosphonate treatment and later development of BRONJ. Novartis filed a Daubert motion to exclude the specific causation testimony of Plaintiff's experts and a motion seeking summary judgment. The district court granted both motions on the basis that Plaintiff's expert testimony was irrelevant and unreliable. Reprinted courtesy of R. Bryan Martin, Haight Brown & Bonesteel LLP and Whitney L. Stefko, Haight Brown & Bonesteel LLP Mr. Martin may be contacted at bmartin@hbblaw.com; Ms. Stefko may be contacted at wstefko@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Nine ACS Lawyers Recognized as Super Lawyers – Two Recognized as Rising Stars

August 26, 2024 — Ahlers Cressman & Sleight PLLC
Going outside the norm of our blogs, which usually discuss construction related issues, Ahlers, Cressman, & Sleight is pleased to announce that nine members of our firm have been selected to the 2024 Washington Super Lawyers list. Each year, a rigorous process that involves a nomination by peers and a third-party verification of honors, awards, verdicts, settlements, and other criteria relating to their work as an attorney, aims to select no more than five percent of the lawyers in Washington state from no more than seventy practice areas for this distinction. As mentioned, the first step in the process is to be evaluated on their work as an attorney, next candidates are evaluated by their peers and given ratings based on the information known about their work. Finally, candidates are grouped into four firm-size categories and final selections are made. The grouping process is done so that candidates are compared fairly to their peers by firm size, eliminating the potential unfairness that comes with comparing large and small firm outcomes and attorney practices. The Rising Star list involves an even narrower criteria than the Super Lawyers list. The initial process is the same, however, candidates for the Rising Stars list must be under the age of forty or have less than ten years of experience. For this category less the two and a half percent of lawyers in Washington are selected, making this quite a feat for those who have accomplished the honor. Read the court decision
Read the full story...
Reprinted courtesy of Ahlers Cressman & Sleight PLLC

Procedural Matters Matter!

December 10, 2024 — Suzanne M. Nicholson - Wilke Fleury
As an appellate practitioner, I am keenly aware that sometimes, a procedural matter can doom what would otherwise be a meritorious issue for appeal. Trial attorneys are well-advised to check and double-check procedural rules and case law governing the issues in their cases. Here’s a few recent developments to be aware of. The record on appeal: electronic recordings now available in Santa Clara County. It should not be news to anyone that it is the appellant’s burden to produce an adequate record for appeal. That includes not just the written submissions to the trial court, but also reporter’s transcripts of all proceedings that could have a substantive impact on your case. If you do not have a court reporter present for your hearing, you will be struck trying your best to get an agreed statement or a settled statement should the case go up on appeal. Believe me, that can be a serious challenge. Any omissions or deficiencies are going to result in presumptions made against the appellant. Read the court decision
Read the full story...
Reprinted courtesy of Suzanne M. Nicholson, Wilke Fleury
Ms. Nicholson may be contacted at snicholson@wilkefleury.com

Insurer's Attempt to Limit Additional Insured Status Fails

December 01, 2017 — Tred R. Eyerly - Insurance Law Hawaii
The court disagreed with the insurer's attempt to limit additional insured status based upon the contract between the parties. Mays v. In re All C-Dive LLC, 2017 U.S. Dist. LEXIS 185874 (E.D. La. Nov. 9, 2017). Five employees of C-Dive LLC filed a lawsuit after belng injured in a pipeline explosion aboard a vessel servicing a pipeline owned by Gulf South Pipeline Company. During the work, there was a release of gas that caused an explosion and injured the employees. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES