Seattle Washington Building Expert Directory

Application Of Two Construction Contract Provisions: No-Damages-For-Delay And Liquidated Damages

February 14, 2022 — David Adelstein - Florida Construction Legal Updates
A recent Florida opinion between a prime contractor and a Florida public body touches upon two important issues: (1) the application of a no-damage-for-delay provision; and (2) the application of a liquidated damages provision. Both provisions find there way into many construction contracts. Unfortunately, the opinion is sparse on facts. Nevertheless, the application of these provisions is worthy of consideration. In this opinion, Sarasota County v. Southern Underground Industries, Inc., 2022 WL 162977 (Fla. 2d DCA 2022), a county hired a contractor to install sanitary and water piping underneath a waterway. During construction, a nearby homeowner complained that vibration from the drilling caused damage to his home. As a result, the county stopped the contractor’s work to address a potential safety issue, as it was contractually entitled to do. The contractor hired a structural engineer to inspect the house and the engineer issued a report determining that any alleged damage was cosmetic and that there was sufficient monitoring of the vibrations to prevent future damage. The contractor also had an insurance policy to cover any homeowner claim for damage. However, upon receipt of the engineer’s report, the county did not lift its stop work order. Rather, the stop work order remained in place for an additional 71 days. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

NYC’s First Five-Star Hotel in Decade Seen at One57 Tower

July 02, 2014 — Heather Perlberg – Bloomberg
Hyatt Hotels Corp. (H) is seeking to make its Park Hyatt New York, opening next month at the base of the ultra-luxury One57 condominium tower, Manhattan’s first new five-star hotel in more than a decade. The 25-floor property is making its debut on West 57th Street in the area known as Billionaires Row for its residential skyscrapers with apartments costing tens of millions of dollars. Plans for the Park Hyatt call for 210 guest rooms starting at $795 a night, spa-treatment suites with private balconies, and amenities such as an indoor pool with underwater speakers that pipe in music from neighboring Carnegie Hall. Hyatt is seeking a competitive edge in Manhattan, where it already operates seven properties, none rated five stars, said Steve Haggerty, global head of real estate and capital strategy for the Chicago-based company. The new Park Hyatt would be the city’s first hotel with the coveted distinction since 2003, when the Mandarin Oriental opened in the nearby Time Warner Center. Since then, most growth in the city’s lodging market has been in the select-service category, hotels that offer few amenities and cost less to operate. Read the court decision
Read the full story...
Reprinted courtesy of Heather Perlberg, Bloomberg
Ms. Perlberg may be contacted at hperlberg@bloomberg.net

A Funny Thing Happened to My Ground Lease in Bankruptcy Court

November 25, 2024 — Christopher F. Graham & Morgan A. Goldstein - White and Williams LLP
EXECUTIVE SUMMARY Ground leases are an important – if somewhat unusual – part of the real estate finance industry. Because they typically cover large expensive properties like Rockefeller Center and The Empire State Building, to name two, and last a long time (99 years and up to start) the likelihood of something unexpected or unintended happening is high. This likelihood increases dramatically if, as highlighted below, one or both of the lease parties’ files for bankruptcy. Accordingly, real estate professionals should take note and take care when entering into any transaction involving a ground lease. Reprinted courtesy of Christopher F. Graham, White and Williams LLP and Morgan A. Goldstein, White and Williams LLP Mr. Graham may be contacted at grahamc@whiteandwilliams.com Ms. Goldstein may be contacted at goldsteinm@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

No Bad Faith in Insurer's Denial of Collapse Claim

July 15, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The Tenth Circuit affirmed the district court's grant of summary judgment to the insurer on the insured's claims for collapse and bad faith. Christopher M. Wolpert Saddletree Holding, LLC v. Evanston Ins. Co., 2024 U.S. App. LEXIS 10377 (10th Cir. April 30, 2024). On May 7, 2019, Saddletree filed a claim with Evanston for damages sustained to its building which was used as a community events center. After a winter of heavy snowfall, Saddletree discovered that the building's steel support columns had buckled two or more inches and the roof had deflected downward approximately six inches. Evanston retained an engineer to inspect the building. The engineer determined that the damage was the result of the building's inadequate "design and/or construction." Evanston disclaimed coverage under the policy's exclusion for damage caused by "hidden or latent defects" or "any quality in property that causes it to damage or destroy itself." Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Board of Directors Guidance When Addressing Emergency Circumstances Occasioned by the COVID-19 Pandemic

May 11, 2020 — Marc Casarino, Lori Smith & Gwenn Barney - White and Williams LLP
The COVID-19 pandemic has sent massive shockwaves throughout the global economy. This crises requires business leaders to confront a host of deleterious effects on an emergency basis – the likes of which many companies have never experienced. Boards of directors must remain cognizant of their oversight responsibilities in these trying times. This post offers guidance to directors of Delaware companies for addressing emergency circumstances occasioned by the COVID-19 pandemic. Board Oversight – Lessons from Marchand V. Barnhill Directors should consider the lessons learned from the recent Delaware Supreme Court case Marchand v. Barnhill, a ruling we addressed in a previous blog post, when considering board oversight during the COVID-19 pandemic. Marchand centered on a lawsuit brought by shareholders in an ice cream manufacturing company against the company’s board of directors. The shareholders claimed that the directors violated their duty of loyalty[1] to the company when they failed to provide sufficient oversight and compliance-monitoring during a listeria outbreak that led the company to recall all products, temporarily cease product production at all plants and lay off more than one-third of the company’s workforce. Reprinted courtesy of White and Williams LLP attorneys Marc Casarino, Lori Smith and Gwenn Barney Mr. Casarino may be contacted at casarinom@whiteandwilliams.com Ms. Smith may be contacted at smithl@whiteandwilliams.com Ms. Barney may be contacted at Barneyg@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Construction Contract Basics: Indemnity

October 30, 2023 — Christopher G. Hill - Construction Law Musings
I’m back after a welcome change of offices from a Regus location to a separate and more customer-friendly local shared office space location. I thought I’d jump back into posting with a series of construction contract-related posts, the first of which relates to indemnification clauses. An indemnification clause in a contract obligates one party (the Indemnitor) to take on liability (read pay for) any damages to another party (the Indemnitee) under certain circumstances. In a construction context, this type of arrangement can arise in a bonding context with a general indemnity obligation to the surety among other contexts outside of the four corners of any prime or subcontract. I will not be discussing those other contexts and will focus on the typical indemnity clause found in most if not all, construction contracts. These clauses most often state that the “downstream” party is to indemnify all of the upstream parties for any and all damages incurred by the indemnitees due to any action of the downstream party, its employees, subcontractors, sub-subcontractors, etc. The clauses are often not limited in scope and generally include attorney fee provisions and generally require indemnity for breaches of contract by their terms. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Five Issues to Consider in Government Contracting (Or Any Contracting!)

September 02, 2024 — David Adelstein - Florida Construction Legal Updates
The appeal of Appeals of – Konecranes Nuclear Equipment & Services, LLC, ASBCA 62797, 2024 WL 2698011 (May 7, 2024) raises interesting, but important, issues that should be considered. In this case, the government (in a supply contract) procured four portal cranes from the claimant. After an initial test of one of the cranes failed, the government refused to accept delivery even after the issue was addressed by the claimant. The government did not accept the manner in which the claimant addressed the issue and would only accept cranes if the claimant employed “an unnecessary alternative solution [that] caused further delay and increased [claimant’s] costs.” On appeal, it was determined the government’s decision to delay delivery based on its demand for the alternative solution was not justified, i.e., constituted a breach of contract. Below are five issues of consideration in government contracting, or, for that matter, any contracting. Issue #1- Patently Ambiguous Specifications The government argued that the specifications were patently ambiguous and because the claimant failed to inquire regarding the ambiguous specifications prior to performance, its interpretation of the ambiguous specifications should govern. The contractor countered that the specifications were unambiguous and it met the specifications. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

A Few Green Building Notes

April 03, 2019 — Christopher G. Hill - Construction Law Musings
This past week, the blogosphere (if that’s even the word these days) has been abuzz about green building and the value that green can add to a project. Three items in particular (among many) got my attention. The first of these was the fact that a new private sustainability rating system is ready for launch. The Institute for Sustainable Infrastructure (or ISI) is seeking public comment on its proposed envISIon. This new system (aptly dubbed Version 1.0) will go “live” in July for comment. Why mention this new system? First of all, ISI’s founding members are the American Society of Civil Engineers (ASCE), the American Public Works Association (APWA) and the American Council of Engineering Companies (ACEC). This trio gives the new program some fairly heavy weight backing. Second, while there are rating systems aside from the ever present LEED, none have taken hold in any real way to compete with LEED. I am curious to see if the envISIon system has any better luck. Finally, this shows that sustainable building is of interest to more than the USGBC and those of us that discuss LEED on a daily basis. I find this to be a great thing that could lead to more societal acceptance of sustainable practices as a standard practice rather than a goal. Hopefully such efforts will offset the other two notes that caught my eye recently. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES