Fairfield Connecticut Building Expert Directory

Christopher Leise Recognized by US News – Best Lawyers 2022 "Lawyer of the Year"

September 06, 2021 — Christopher Leise - White and Williams LLP
White and Williams is proud to announce that Christopher Leise has been named Best Lawyers® 2022 "Lawyer of the Year" in Cherry Hill, NJ for his work in Litigation - Insurance. Chris focuses his practice on complex insurance and commercial litigation, including the representation of licensed insurance agents and brokers in professional liability claims and agency contract disputes. He also has extensive experience litigating complex insurance coverage, insurance bad faith, RICO and insurance fraud claims, fire damage claims, and ERISA disputes. Chris works with regional and national brokerage firms defending professional liability claims and handling disputes with insurance companies throughout the mid-Atlantic region, as well as with commercial insurance carriers defending allegations of bad faith. Read the court decision
Read the full story...
Reprinted courtesy of Christopher Leise, White and Williams LLP
Mr. Leise may be contacted at leisec@whiteandwilliams.com

Insurer Rejects Claim on Dolphin Towers

July 22, 2011 — CDJ STAFF

A year after residents were forced to leave Dolphin Towers in Sarasota, Florida because of concrete problems, some residents are defaulting on their obligations, abandoning their units. In June, the building’s insurer, Great American, rejected a claim, arguing that the building’s problems were due to latent defects, not covered under the policy. Repair estimates, previously put at $8.2 million, have now risen to $11.5 million. If homeowners cover this cost, it would require an assessment of about $100,000 for each unit.

About thirty owners are in arrears on dues and fees. Charlotte Ryan, the president of the Dolphin Tower board, wrote to owners, that “the board will have no choice but to lien your property and pursue foreclosure if you do nothing to bring your delinquencies up to date.” However, as homeowners default, the funding for repairs is imperiled. The board has already spent more than $500,000 on shoring up the building and hiring consultants. Their lawyers, on the other hand, are working on a contingency basis.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

Pennsylvania Sues Firms to Recoup Harrisburg Incinerator Losses

June 06, 2018 — Jonathan Barnes - Engineering News-Record
The state of Pennsylvania continues to try to recover funds from professional firms involved in the city of Harrisburg’s disastrous incinerator project in the early 2000’s and has named, Buchart Horn, Inc., an engineering, architecture and planning firm based in York, Pa. as a defendant. Read the court decision
Read the full story...
Reprinted courtesy of Jonathan Barnes, ENR
ENR staff may be contacted at ENR.com@bnpmedia.com

Death of Subcontractor’s Unjust Enrichment Claim Against Project Owner

April 12, 2021 — David Adelstein - Florida Construction Legal Updates
In a previous article, I discussed a subcontractor’s unjust enrichment claim against a project’s owner and the death of this equitable claim if the owner fully paid the general contractor or paid the general contractor for the subcontractor’s work. This can be best summarized from a very short 1995 opinion out of the Fourth District Court of Appeal: “Unjust enrichment is equitable in nature and cannot exist where payment has been made for the benefit conferred. [Owner] paid [General Contractor] the full amount of its contract for the construction project. Accordingly, there can be no unjust enrichment claim to support [Subcontractor’s] claim.” Gene B. Glick Co., Inc. v. Sunshine Ready Concrete Co., Inc., 651 So.2d 90 (Fla. 4th DCA 1995). Reprinted courtesy of David Adelstein, Kirwin Norris, P.A. Mr. Adelstein may be contacted at dma@kirwinnorris.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

The Construction Project is Late—Allocation of Delay

November 17, 2016 — David Adelstein – Florida Construction Legal Updates
The construction project is late. Very late. The owner is upset and notifies the contractor that it is assessing liquidated damages. The contractor, in turn, claims that the project is late because of excusable, compensable delays and, perhaps, excusable, noncompensable delays. This is a common and unfortunate story between an owner and contractor on any late construction project. Now the fun begins regarding the allocation of the delay! Through previous articles, I discussed that in this scenario the burden really falls on the contractor to establish that the liquidated damages were improperly assessed against it and, thus, it is entitled to additional time and/or extended general conditions as a result of excusable delays. Naturally, this requires the contractor to develop a critical path analysis (time impact analysis) allocating the impacts / delays (and the reasons for the impacts/ delays) to the project completion date. The reason the burden really falls on the contractor is because the owner’s burden is relatively easy – the project was not complete on time pursuant to the contract and any approved changed orders. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.
Mr. Adelstein may be contacted at dma@katzbarron.com

Sixth Circuit Affirms Liability Insurer's Broad Duty to Defend and Binds Insurer to Judgment Against Landlord

September 07, 2020 — Michael V. Pepe & Janie Reilly Eddy - Saxe Doernberger & Vita
In a victory for policyholders, the Sixth Circuit affirmed that a landlord’s insurer owed a duty to defend the landlord in a bodily injury claim arising out of a fire that killed three and injured one. The Court held that the insurer breached its duty to defend and was bound to the insured’s $3 million consented judgment. Transition Investments LLC, an owner of three properties in the Detroit area, purchased a general liability insurance policy with Hamilton Specialty Insurance Company to insure its properties. At one of the properties, a faulty stove started a fire, destroying the building, injuring one person and killing three others. The estates of the deceased and the injured party sued Transition in Michigan state court. In their complaint, the plaintiffs contended that Transition failed to provide a habitable premise and neglected to maintain the property’s stove, which allegedly caused the fire. The plaintiffs argued that Transition’s negligent maintenance of the property led to the fire and the resulting injuries. Transition subsequently tendered the claim to Hamilton. Hamilton claimed that the insurance policy did not cover the fire’s damages and refused to participate in the state court litigation. Ultimately, Transitions entered into a consent judgment with the plaintiffs for $3 million. Reprinted courtesy of Michael V. Pepe, Saxe Doernberger & Vita and Janie Reilly Eddy, Saxe Doernberger & Vita Mr. Pepe may be contacted at mvp@sdvlaw.com Ms. Eddy may be contacted at jre@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

North Carolina, Tennessee Prepare to Start Repairing Helene-damaged Interstates

October 07, 2024 — Derek Lacey - Engineering News-Record
Damage from Hurricane Helene to interstates between North Carolina and Tennessee includes washed-out roads and bridges, landslides and extensive flooding—creating a long list of repair work needed for state transportation agencies as they prepare to rebuilding critical highways across the Appalachian Mountains. Reprinted courtesy of Derek Lacey, Engineering News-Record Mr. Lacey may be contacted at laceyd@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

How BIM Helps Make Buildings Safer

July 01, 2019 — Aarni Heiskanen - AEC Business
There are many uses for building information models that are yet to be discovered. One Finnish team collaborated with a city and fire & rescue authority to explore how BIM would help make buildings safer. “Imagine a fire inspector in a building with an AR headset. He can retrieve data from the building’s digital model and hence get an x-ray view of the pipes and cables behind the lowered ceiling.” That’s a scenario that Timo Lehtoviita pictured when we discussed the experimentation project which he led at Saimia, Saimaa University of Applied Sciences. Saimia, the city of Lappeenranta and their real estate company LATO, and the Rescue Department of South Karelia partnered in 2018 to explore the possibilities of using BIM to make buildings safer. The project, titled “Enhancing building safety using information models,” formed part of the national KIRA-digi built environment digitalization program. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES