Fairfield Connecticut Building Expert Directory

Not So Fast, My Friend: Pacing and Concurrent Delay

April 25, 2022 — William E. Underwood - ConsensusDocs
When critical path activities are delayed by the owner (or another party), contractors will sometimes “pace,” or slow down, other activities to match the owner-caused delay. After all, why should the contractor hurry up and wait? But paced activities can often appear as concurrent delays on a project’s overall schedule. And all too often, contractors fail to contemporaneously document their efforts to pace work. Not only can this create avoidable disputes with owners and other contractors, but it can also create future roadblocks to the recovery of delay damages. This article examines the interplay between pacing and concurrent delay[1] and what contractors should do to minimize risk and preserve their rights to obtain more than a simple time extension for project delays. Pacing versus Concurrent Delay As a basic matter, most contracts allocate responsibility/liability for a schedule delay to the party that caused the delay. For example, if an owner is contractually required to provide equipment for a contractor to install, then the owner likely bears responsibility for any delays caused if the equipment is delivered late. If, however, the contractor was also behind schedule on other activities during this time and the project would have been delayed regardless of the owner’s late deliveries, then the delay is probably concurrent. And the contractor will generally be entitled to only an extension of time, and no other monetary relief. Read the court decision
Read the full story...
Reprinted courtesy of William E. Underwood, Jones Walker LLP (ConsensusDocs)
Mr. Underwood may be contacted at wunderwood@joneswalker.com

Boston Catwalk Collapse Injures Three Workers

May 10, 2022 — Scott Van Voorhis - Engineering News-Record
The collapse of a catwalk in a defunct, 124-year-old power plant building in Boston on May 4 injured three workers in the latest in a spate of serious construction accidents in the city and its environs. Reprinted courtesy of Scott Van Voorhis, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Some Construction Contract Basics- Necessities and Pitfalls

January 03, 2022 — Christopher G. Hill - Construction Law Musings
Recently, I’ve been on an “advising” kick here at Construction Law Musings. My last two posts have been about communication and trusting your gut when it comes to a smooth construction project. This post will be the third in the trilogy (and who knows maybe I’ll have a 4th and 5th like the Hitchhiker’s Guide to the Galaxy “trilogy”). While all construction contractors should use their communication skills and instincts to assure a smooth and hopefully profitable project, all of the gut following and great communication will not help you if your contract is not up to snuff. In the spirit of giving you a few basics things to look at, here’s my list of three basics that you need in your contract and a three things to be on the lookout for in others’ contracts. First, the good stuff that needs to be there:

Attorney Fees Clause– without it, a Virginia court (and most other courts) will not award you a judgment for any attorney fees spent to protect your rights.
Dispute Resolution– whether the specified resolution is through the litigation process, ADR or some combination, such a clause or paragraph will only help define the parameters of what happens with a claim.
Detailed scope of work– Without the proper detail in the scope of work, the parties cannot properly set expectations and know what happens when things change.

Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

BIOHM Seeks to Turn Plastic Waste into Insulation Material with Mushrooms

July 27, 2020 — Aarni Heiskanen - AEC Business
BIOHM is a research and development led UK start-up that aims to revolutionize the construction industry with its bio-based materials. Among their products are insulation panels made from mycelium, the root formations of fungi. Recently, the company discovered that certain fungal species can consume plastic as a food source. This invention could bring about new construction materials that originate from plastic waste. “Evolving from eating leaf matter and the odd bit of tree bark, to eating plastic might seem like a huge jump, but for certain fungi, it can actually happen very quickly. The inhabitants of the microbial world are far more genetically flexible than humans, able to evolve and adapt to their environment within a generation, constantly modifying and improving upon their genome to maximize their productivity,” says Samantha G.R. Jenkins, Lead Biotechnology Engineer. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Wildfire Smoke Threatens to Wipe Out Decades of Air Pollution Progress

August 28, 2023 — Linda Poon & Immanual John Milton - Bloomberg
The US is on track to experience its worst year for smoke exposure in decades, after wildfires in Canada sent toxic plumes drifting across the border to the Midwest and the East Coast earlier this summer. In June and July, New York and Chicago saw more “very unhealthy” and “hazardous” air quality days for fine particle pollution (PM2.5) than in the same months every year since the Environmental Protection Agency began tracking PM2.5 nationally in 2000, a Bloomberg CityLab analysis of federal data found. In Washington, DC, the number of “very unhealthy” days reached the highest in over a decade. On the EPA’s air quality index scale, these days correspond with the highest levels of public health concern. Extensive exposure to PM2.5 particles, the main pollutant found in smoke, can increase the risk of a variety of problems, including heart and respiratory disease, as well as premature death. Reprinted courtesy of Linda Poon, Bloomberg and Immanual John Milton, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

Kahana & Feld P.C. Enhances Client Offerings, Expands Litigation Firm Leadership

March 22, 2017 — Kahana & Feld, P.C.
SANTA ANA, Calif., March 9, 2017 – Celebrating 10 successful years of practice, Managing Partner Amir M. Kahana, Esq. , of Kahana & Feld P.C. (formally Kahana Law), is pleased to announce he has added as name partner Jason Daniel Feld, Esq., expanding client offerings to include insurance defense and bolstering its construction defect and real estate law practice. Feld joins the AV Preeminent firm that for the past decade has become known for its prowess in general business litigation matters, including cases involving employment, construction, real estate and intellectual property law. The firm is home to a group of proven trial attorneys who are among Southern California’s top rated counsel. Feld brings 18 years of experience, with his practice focusing on defending homebuilders, contractors and developers in Arizona, Texas and California. He primarily chooses to represent smaller, family-owned and operated clients, providing the unique opportunity to also assist with overall best practices and risk prevention. In addition, Feld serves on several prominent insurance carrier panels, allowing him to cultivate valuable relationships with the builder and contactor community. A resident of Tustin Ranch, Feld received his juris doctor cum laude from Whittier Law School and a bachelor’s degree from University of Houston. “Jason’s breadth of experience, leadership and work ethic are qualities I have admired throughout the many years of our friendship. He embodies the integrity and admirable character that are at the core of our firm’s fabric,” said Kahana, a resident of Irvine. “I am thrilled to have Jason join forces with our firm as we enter our second decade and are poised for significant growth. Our clients will benefit from our expanded areas of practice, allowing us to provide counsel and litigation support in a variety of areas.” Under Kahana’s leadership, the firm has become known for holding its client relationships in the highest regard while providing premier quality legal services and sound risk assessment at a reasonable cost. With integrity always coming first, the firm’s record of success extends well beyond the office as each associate is proudly involved in his or her community, donating time and resources to a variety of worthy community organizations. “I feel honored to join Amir and this talented and energetic firm,” said Feld. “I feel fortunate to have found a new home with partners and associates who share the same values and commitment to serving the community. I look forward to helping grow the firm in the years ahead.” About Kahana & Feld, P.C. Kahana & Feld, P. C. focuses on general business litigation and insurance defense, with particular emphasis on employment, real estate, construction defect and intellectual property litigation. The AV Preeminent firm is led by attorneys who have been named among Southern California’s Top Rated. The firm was founded with the goal of providing high-quality legal services at fair and reasonable rates. The firm believes that what defines attorneys is not their billing rates, but their record of success, and Kahana & Feld’s track record speaks for itself. For more information, please visit: http://www.kahanafeld.com Read the court decision
Read the full story...
Reprinted courtesy of

St. Petersburg Florida’s Tallest Condo Tower Allegedly Riddled with Construction Defects

October 15, 2014 — Beverley BevenFlorez-CDJ STAFF
In a new lawsuit, the Signature Place Condominium Association claims "it is spending ‘large sums' of money to repair problems ranging from cracks in exterior walls to improper fire wall installation to excessive noise from air-conditioning and heating systems,” according to the Tampa Bay Times. The lawsuit also stated that “some of the alleged defects were hidden by building components and finishes and thus were not discovered by owners "until after the purchase and occupancy of the unit,” reported the Tampa Bay Times. The association “seeks damages in excess of $15,000, cites more than 100 other alleged construction and design defects.” Read the court decision
Read the full story...
Reprinted courtesy of

Yes, Virginia, Contract Terms Do Matter: Financing Term Offers Owner an Escape Hatch

November 25, 2024 — Christopher G. Hill - Construction Law Musings
For this week’s Guest Post Friday, Musings welcomes Timothy R. Hughes, Esq., LEED AP. Tim (@vaconstruction on Twitter) is Of Counsel to the Arlington, Virginia firm of Bean, Kinney & Korman, P.C. In his practice as a business, corporate, and construction law attorney, Tim served as the previous Chair of the Construction Law and Public Contracts Section of the Virginia State Bar. He has served in numerous volunteer, board and leadership roles with such organizations as the Arlington Chamber of Commerce, the Northern Virginia Building Industry Association, Vanguard Services Unlimited, Leadership Arlington, Associated Builders & Contractors (Metro DC and Virginia), and numerous other volunteer and construction trade association activities. A regular speaker and writer, Tim is the lead editor of his firm blog, Virginia Real Estate, Land Use and Construction Law. A recent Virginia case once again demonstrates that contract terms matter. An unusual financing term allowed the owner of a project a complete escape from any liability on a project despite significant work being performed. The opinion from the Circuit Court of Norfolk involved five separate cases consolidated together, four claims by subcontractors and one by the general contractor Turner. All five cases hinged on an unusual financing clause in Turner’s contract with the other. That provision stated: Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES