Cambridge Massachusetts Building Expert Directory

Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season

January 13, 2020 — David Adelstein - Florida Construction Legal Updates
There are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be. For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:

[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season. Meridian Engineering, 2019 WL at *7 (internal citations omitted)

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Traub Lieberman Partners Lenhardt and Smith Obtain Directed Verdict in Broward County Failed Repair Sinkhole Trial

September 03, 2019 — Michael Francis Lenhardt & Burks A. Smith, III - Traub Lieberman
On Tuesday, July 16, 2019, Traub Lieberman Partners Michael Lenhardt and Burks Smith won a Directed Verdict at trial in a dispute over Sinkhole Loss coverage in Broward County Circuit Court. The lawsuit arose out of a claim for Breach of Contract involving an alleged “failed repair” of a 2005 sinkhole at the insureds’ property. The Plaintiffs argued that their Policy Limits did not apply because the carrier allegedly undertook the subsurface repairs, relying on Drew v. Mobile USA Ins. Co., 920 So.2d 832 (Fla. 4thDCA 2006). The Plaintiffs asserted that because the insurance company allegedly hired the below ground repair company, a “new contract” was formed, and the Plaintiffs should be entitled to limitless repairs to their home, notwithstanding the Policy Limits. This argument obviously presented the carrier with very significant exposure. Attorneys Lenhardt and Smith provided a vigorous defense for the insurance company at trial, during which they presented the jury with evidence that the carrier did not, in fact, hire the subsurface repair company. They further established to the jury that the insureds actually signed a contract with the repair company directly, and that the defendant did not invoke the Our Option repair clause of the Policy. After the Plaintiffs rested their case, Mr. Lenhardt and Mr. Smith moved the Court for entry of a directed verdict. The defense argued to the Court that the Plaintiffs could not prove their case to the jury based upon the facts presented as a matter of law, thus entitling the insurance company to a defense verdict. Reprinted courtesy of Michael Francis Lenhardt, Traub Lieberman and Burks A. Smith, III, Traub Lieberman Mr. Lenhardt may be contacted at mlenhardt@tlsslaw.com Mr. Smith may be contacted at bsmith@tlsslaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Contractor Not Liable for Flooding House

October 02, 2013 — CDJ STAFF
Knife River Corp was hired by the town of Post Falls, Idaho to do road and sewer construction work. In the process, they interrupted a 6-inch water supply line, sending the water into a wastewater line. From there, the water flooded a home in Post Fall. The city paid more than $7,800 in damages. Post Falls sued Knife River’s insurer for coverage. The city has lost its lawsuit and is responsible for $18,500 in attorneys’ fees. Despite all this, the city administrator says that the city still has a good working relationship with Knife River. Read the court decision
Read the full story...
Reprinted courtesy of

Are We Headed for a Work Shortage?

June 17, 2015 — Craig Martin – Construction Contractor Advisor
A recent Wall Street Journal article, Worker Shortage Hammers Builders, noted that construction industry employers are facing a tight labor market. “U.S. builders shed more than 2 million jobs during and after the housing bust. Now they say they can’t find enough carpenters, electricians, plumbers and other craftsmen for a growing pipeline of work.” That is certainly consistent with everything that I’ve heard and read about construction companies in the Midwest. Unfortunately, it seems as though the problem is only going to get worse. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Record-Setting Construction in Fargo

November 07, 2012 — CDJ STAFF
Prairie Business reports that Fargo is experiencing the most new construction it has ever seen, totaling $434 million in value, which exceeds the previous high in 2006 of $428 million. Many of the construction starts are for single family homes, although there is also an increase in construction of apartments and townhomes. The Home Builders Association of Fargo-Moorhead also noted that there was also a large of remodeling projects. Terry Becker, the president of the HBA, said that “remodeling is just huge right now.” Read the court decision
Read the full story...
Reprinted courtesy of

Los Angeles Wildfires Will Cause Significant Insured Losses, Ranking Amongst the Most Destructive in California's History

January 14, 2025 — Morningstar DBRS
Wildfires currently burning in the Pacific Palisades, Eaton, Hurst and other Los Angeles neighborhoods will cause significant losses for the insurance industry, in Morningstar DBRS’ view. The fires have already burned more than 1,100 homes and threaten more than 28,000 additional structures, according to local fire officials. Preliminary estimates point to total insured losses in excess of $8 billion depending on the final number of properties being affected by the wildfires. By way of comparison, the 2018 Woolsey Fire, which destroyed 1,643 structures just north of Los Angeles, caused more than $6 billion in property damages at that time. Morningstar DBRS expects the ongoing wildfires to have a negative but manageable impact on major property insurers active in the Californian market, with the impact somewhat mitigated by their use of reinsurance and their high degree of diversification. Similarly, losses should be manageable for the global reinsurance industry and not affect their credit profiles. While leading U.S. property insurers are in good financial condition, the California property insurance market has been challenging because of high wildfire and other natural catastrophe risks combined with regulatory restrictions on coverage and pricing, leading many insurers to re-think their product offering, including an outright exit from the market. For example, market leaders such as State Farm and Allstate started reducing their exposure to the California market beginning 2022-2023. It is therefore possible that a larger than usual portion of the losses caused by the wildfires will be uninsured or may be covered under the California FAIR Plan, which is designed to provide fire coverage up to $3 million per home and spread the risk across the industry when it is not available from traditional carriers. This event reinforces the need for adequate rate increases on home insurance in California, based on forward-looking pricing and catastrophe modelling, as well as for additional fire prevention and mitigation initiatives. However, property insurance affordability is likely to remain a challenge in the state going forward, with many property owners opting to remain uninsured or under-insured because of the high costs. Read the court decision
Read the full story...
Reprinted courtesy of

Tax Increase Pumps $52 Billion Into California Construction

April 20, 2017 — JT Long - Engineering News-Record
The first wave of new road projects could go out at the beginning of 2018 now that the California legislature has approved $52.4 billion over 10 years from a new 12-cent-per-gallon gasoline tax. SB-1 was approved late in the evening on April 6; by April 7, the California Dept. of Transportation was already working on a list of projects that could start construction by summer of 2018. Read the court decision
Read the full story...
Reprinted courtesy of JT Long, ENR
ENR may be contacted at ENR.com@bnpmedia.com

Why Are Developers Still Pouring Billions Into Waterlogged Miami?

November 30, 2016 — James Tarmy – Bloomberg
On Sunday, an ebullient procession of artists, performers, and city residents filled Collins Avenue between Miami Beach’s 32nd and 36th streets to inaugurate the Faena Forum, a 43,000--square-foot, $150 million, performing- and visual-arts space that’s the cultural centerpiece of the Faena District, a $1 billion development comprising luxury hotels, restaurants, and real estate. The complex is the brainchild of Alan Faena, an Argentinian fashion designer-cum-developer known for his all-white outfits, and Len Blavatnik, a Ukrainian born, New York-based billionaire whose net worth is estimated by Bloomberg Billionaires to be $18.6 billion. The parade/carnival/performance was was titled “Side by Tide,” which might be an overly optimistic assessment of Miami Beach's sea level. With "king tides" flooding parking garages and a University of Miami study reporting that Miami Beach has seen a 200 percent increase in flooding in the last decade, the tide isn’t on anyone’s side. It’s already beneath the city, seeping upward, often as not, through the ground’s porous limestone and into buildings’ backlogged storm drains. Aside from ruining the undercarriages of residents’ Porsches, this ground-up flooding has a second, perhaps more deleterious effect on the long-term feasibility of Miami Beach: Normal defenses against a rising ocean—such as sea walls or dykes—are useless. Read the court decision
Read the full story...
Reprinted courtesy of James Tarmy, Bloomberg
Mr. Tarmy may be followed on Twitter @jstarmy

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES