Fairfield Connecticut Building Expert Directory

Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor

September 09, 2024 — David Adelstein - Florida Construction Legal Updates
A recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project. In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Demonstrating A Fraudulent Inducement Claim Or Defense

May 18, 2020 — David Adelstein - Florida Construction Legal Updates
In a recent case, Florida’s Fourth District Court of Appeal reversed a trial court’s denial of a motion for a temporary injunction sought by an employer due to an independent contractor’s violation of a non-compete and non-solicitation provision in an employment / independent contractor agreement (“employment agreement”). You can find more on this case and the enforcement of the non-compete and non-solicitation clause here. A worthy discussion in this case centers on the independent contractor’s fraudulent inducement defense. Specifically, the independent contractor, as a defense to the injunction, claimed that he was fraudulently induced into entering into the employment agreement because the employer promised he would make a certain amount of money and he would work predominantly in one geographic location. The employment agreement contained NO such representations. Instead, the employment agreement contained a fee and services schedule and the independent contractor would be compensated based on that schedule. It stated nothing as to the independent contractor only having to work, or predominantly working, in one geographic location, or that the independent contractor would be guaranteed “X” amount of money working in that location. Why is this important? Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Equipment Costs? It’s a Steal!

July 08, 2011 — CDJ STAFF

KCBD reports on the problems of a Lubbock, Texas contractor. It’s hard to do the job when your tools keep getting stolen. Corey Meadows, owner of Top Cut Interiors, told KCBD that he had chained an air compressor to a table saw. Since the thieves couldn’t cut the chain, they cut the table saw “and just took the air compressor and the chain.” Meadows estimates the thieves cost him $2,000 in damaged or stolen equipment and time lost.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

Landlord Duties of Repair and Covenant of Quiet Enjoyment

February 10, 2020 — Lawrence S. Glosser - Ahlers Cressman & Sleight PLLC
A recent case from Division I Washington Court of Appeals addressed both a landlord’s duties of repair and maintenance and the Covenant of Quiet Enjoyment in commercial leases. Votiv, Inc. v. Bay Vista Owner LLC, No. 78289-4-I, 2019 WL 4419446 (Wash. Ct. App., Sept. 16, 2019). The Plaintiff in that case leased an office space in a mixed-use residential/office/commercial building in Seattle. Although the ownership groups of the various portions of the building were each separate, the entire building was managed by defendant Bay Vista Owner LLC (“BVO”), that was also the Plaintiff’s landlord. There was a need to replace a deteriorating roof membrane to repair water intrusion into the building. The work involved significant demolition on the roof surface over the premises that Votiv, Inc. (“Votiv”), a music/media company, leased on the top floor. The repair work was done primarily during business hours causing significant disturbance to Votiv’s business operations. Votiv sued BVO and other defendants for, among other things, nuisance, breach of lease, constructive eviction, and breach of the covenant of quiet enjoyment. The trial court denied Votiv’s claim for injunctive relief and granted summary judgment to the Defendants. Read the court decision
Read the full story...
Reprinted courtesy of Lawrence S. Glosser, Ahlers Cressman & Sleight PLLC
Mr. Glosser may be contacted at larry.glosser@acslawyers.com

White and Williams Recognized by BTI Consulting Group for Client Service

April 12, 2021 — White and Williams LLP
White and Williams is proud to be included in BTI Consulting Group’s report of “The 70 Law Firms Improving Client Service Performance More Than All Others." The pandemic forced law firms to navigate and respond instinctively as new client situations popped up daily and weekly. White and Williams was quick to establish a Covid-19 team and resource center to help clients navigate the rapidly developing business and legal issues brought on by the pandemic and provide timely and practical advice. This recognition is a testament to the firm’s commitment to provide clients with best-in-class service and the trust that clients have instilled in the firm. Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP

U.S. Stocks Fall as Small Shares Tumble Amid Home Sales

September 24, 2014 — Joseph Ciolli and Callie Bost – Bloomberg
U.S. stocks fell, led by a plunge among small companies, as sales of existing homes unexpectedly dropped and China’s finance minister damped stimulus hopes. The Russell 2000 Index of small-cap stocks sank 1.6 percent, the most since July. Yahoo! Inc. (YHOO) dropped 2.3 percent to lead the Dow Jones Internet Composite Index to a one-month low. Alibaba Group Holding Ltd. slid 2.1 percent after surging in its trading debut Sept. 19. The Standard & Poor’s 500 Index dropped 0.7 percent to 1,997.37 at 11:24 a.m. in New York, after closing at a record Sept. 18. The benchmark gauge hasn’t had a four-day slide this year and hasn’t fallen 10 percent in three years. The Dow Jones Industrial Average slid 58.40 points, or 0.3 percent, to 17,221.34. Mr. Ciolli may be contacted at jciolli@bloomberg.net; Ms. Bost may be contacted at cbost2@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Joseph Ciolli and Callie Bost, Bloomberg

Mass Timber Reduces Construction’s Carbon Footprint, But Introduces New Risk Scenarios

March 04, 2024 — Michael Bruch & Franck Fumat - Allianz Commercial
Mass timber has the potential to be a critical building component for the cities of the near future given the need for the construction sector to reduce its reliance on concrete and steel to lower its Co2 emissions. However, as this market grows and mass timber buildings evolve to greater heights, the construction risk landscape will also be transformed, bringing risk management challenges for companies, according to the new Emerging Risk Trend Talk report from Allianz Commercial. “The emergence of mass timber as a sustainable construction alternative represents a significant opportunity for the building sector to reduce its carbon footprint while also satisfying a demand for a material that is more cost-efficient but as durable as steel and concrete,” says Michael Bruch, Global Head of Risk Advisory Services at Allianz Commercial. “However, in any industry, deployment of new materials or processes can result in new risk scenarios, potential defects, or unexpected safety consequences, as well as bringing benefits, and mass timber is no different. Given this market’s expected future growth, companies should do all they can to develop a greater understanding of their exposures including fire, water damage, repetitive loss scenarios and even termite infestation, and ensure they have robust loss prevention measures in place to combat these.” The need for mass timber The building and construction sector is among the largest contributors to Co2 emissions, accounting for over 34% of energy demand and around 37% of energy and process related Co2 emissions in 2021 [1]. Given emissions reduction is essential to meet climate change commitments around the world, the need for more sustainable solutions in the built environment has become increasingly important, driven by growing investor and consumer concerns, and legislation, regulation and reporting requirements evolving quickly in many jurisdictions around the world. Read the court decision
Read the full story...
Reprinted courtesy of Allianz Commercial

Safety Officials Investigating Death From Fall

September 09, 2011 — CDJ STAFF

California safety officials are looking into the circumstances surrounding the death of a construction worker who fell from a roof in Tiburon, California. Another worker found Gabriel Vasquez unconscious at the site. Vasquez was later pronounced dead. The State Division of Occupational Safety and Health are trying to determine how Vasquez fell.