FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Not So Fast, My Friend: Pacing and Concurrent Delay

April 25, 2022 — William E. Underwood - ConsensusDocs
When critical path activities are delayed by the owner (or another party), contractors will sometimes “pace,” or slow down, other activities to match the owner-caused delay. After all, why should the contractor hurry up and wait? But paced activities can often appear as concurrent delays on a project’s overall schedule. And all too often, contractors fail to contemporaneously document their efforts to pace work. Not only can this create avoidable disputes with owners and other contractors, but it can also create future roadblocks to the recovery of delay damages. This article examines the interplay between pacing and concurrent delay[1] and what contractors should do to minimize risk and preserve their rights to obtain more than a simple time extension for project delays. Pacing versus Concurrent Delay As a basic matter, most contracts allocate responsibility/liability for a schedule delay to the party that caused the delay. For example, if an owner is contractually required to provide equipment for a contractor to install, then the owner likely bears responsibility for any delays caused if the equipment is delivered late. If, however, the contractor was also behind schedule on other activities during this time and the project would have been delayed regardless of the owner’s late deliveries, then the delay is probably concurrent. And the contractor will generally be entitled to only an extension of time, and no other monetary relief. Read the court decision
Read the full story...
Reprinted courtesy of William E. Underwood, Jones Walker LLP (ConsensusDocs)
Mr. Underwood may be contacted at wunderwood@joneswalker.com

---

Construction Defect Risks Shifted to Insurers in 2013

December 11, 2013 — CDJ STAFF
Recent court decisions have tended to view construction defects as covered under insurance policies, “allowing construction companies to shift the costs of their faulty workmanship to their insurers, thereby reversing the previous public policy trend against coverage for such claims.” John Husmann and Adam Fleischer of Bates Carey Nicolaides review some of the 2013 decisions that reversed “the previous public policy trend against coverage for such claims.” They note that “for some time, courts have recognized that there is a public policy against allowing construction companies to get paid to perform faulty workmanship, and then force their insurers to be the financers for the repair and replacement costs.” But in 2013, the courts “strayed from those public policy considerations upon which previous decisions relied.” With reference to specific cases and decisions, they discuss three ways in which the courts have change course. The first is whether faulty workmanship is an “occurrence.” The next is if faulty workmanship is covered when it damages non-faulty work of the same project. And finally, whether exclusions for particular parts of the property extend to the work done in that area. Read the court decision
Read the full story...
Reprinted courtesy of

---

Meet the Forum's ADR Neutrals: LESLIE KING O'NEAL

January 29, 2024 — Marissa L. Downs - The Dispute Resolver
Company: JAMS Office Location: Orlando, FL Email: lkoneal1117@gmail.com Website: https://www.jamsadr.com/oneal/ Law School: University of Florida, J.D. (1977) Types of ADR services offered: Mediation, arbitration, neutral evaluation Geographic area served: Nationwide Q: Describe the path you took to becoming an ADR neutral. A: Florida was one of the first states to allow judges to send civil cases to mediation. When I was an advocate, nearly all my cases went to mediation at least once—sometimes more than once! I became a firm believer in the value of mediation and other ADR methods. I became a Florida certified circuit court mediator in 2021 and I joined JAMS in 2022, after retiring as in-house counsel with Brasfield & Gorrie, a large commercial general contractor. I am also an adjunct professor at Pepperdine Law School, teaching arbitration theory and practice in its master of dispute resolution and master of laws programs. Read the court decision
Read the full story...
Reprinted courtesy of Marissa L. Downs, Laurie & Brennan, LLP
Ms. Downs may be contacted at mdowns@lauriebrennan.com

---

Construction Site Blamed for Flooding

November 08, 2013 — CDJ STAFF
A neighborhood in Pflugerville, Texas was during some recent heavy rains, and the residents blame the nearby construction of a new elementary school. During the rains, a retention wall around the site collapsed, leading to the water discharging to their neighborhood. One resident noted that he had about $16,000 worth of damage to his home and it has also cost him work. “I fix computers for a living, but I don’t have internet right now, and a lot of my stuff is wet,” said Erik Goeser, one of the Shallow Creek neighborhood residents. The county is looking into the situation but notes that “the construction site in question had recently been inspected and met all Travis County expectations, requirements and codes.” Read the court decision
Read the full story...
Reprinted courtesy of

---

The Right to Repair Act Means What it Says and Says What it Means

December 18, 2022 — Garret Murai - California Construction Law Blog
A rather short case for a short week. In Gerlach v. K. Hovnanian’s Four Seasons at Beaumont, LLC, 82 Cal.App.5th 303 (2022), the 4th District Court of appeals examined provisions of the Right to Repair Act (Civ. Code §§895 et. seq), also known as “SB 800” after its original bill number, as it applies to roofs. The Gerlach Case Lynn Gerlach and Lola Seals are homeowners who purchased their homes in the Four Seasons at Beaumont adult community, for those 55 year old and older, located in Beaumont, California. Gerlach purchased her home when it was built in 2006. Seals purchased her home from the original owners in 2015. In 2015 and 2016, Gerlach and Seals served the developer, K. Hovnanian’s Four Seasons at Beaumont, LLC, with claim notices under the Right to Repair Act. The Right to Repair Act, as its name implies, provides notice requirements and repair rights by developers of new single-family homes. The Right to Repair Act also includes construction standards, the violation of which, provides homeowners with a statutory basis for bringing construction defect claims. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---

Ninth Circuit Issues Pro-Contractor Licensing Ruling

July 18, 2018 — Amy L. Pierce – Gravel2Gavel Construction & Real Estate Law Blog
On July 10, the U.S. Court of Appeals for the Ninth Circuit issued its much anticipated and a pro-contractor ruling in MP Nexlevel of California, Inc. v. CVIN LLC. The appeal arose from a dispute over the scope of a California specialty contractor’s license and, more particular, involved whether the subcontractor’s performance of certain work was outside the scope of its license constituting a breach of contract and resulting in the contractor not being entitled to payment for its work (Cal. Bus. & Prof. Code § 7031(a)). In an unpublished opinion, the Ninth Circuit reversed and remanded the matter, finding that “Nexlevel’s work here was ‘incidental and supplemental’ to the installation of these fiberoptic systems,” as contemplated by Cal. Code Regs. Tit. 16, § 831. Read the court decision
Read the full story...
Reprinted courtesy of Amy L. Pierce, Pillsbury Winthrop Shaw Pittman LLP
Ms. Pierce may be contacted at amy.pierce@pillsburylaw.com

---

Insurers in New Jersey Secure a Victory on Water Damage Claims, But How Big a Victory Likely Remains to be Seen

April 03, 2019 — Kevin Sullivan - TLSS Insurance Law Blog
Property insurance policies commonly cover water damage caused by an accidental discharge or leakage of water from an on-site plumbing system and commonly exclude water damage caused by a sewer backup. So it’s not surprising that the cause of water damage is a common battleground between policyholders and insurers. In Salil v. Ohio Security Insurance Co., 2018 WL 6272930 (N.J. App. Div. Dec. 3, 2018), insurers scored a victory when the court held that the release of water and sewage into a restaurant was subject to a $25,000 sublimit for water damage caused by a sewer backup. But claims adjusters and policyholders confronted with water damage claims in New Jersey will no doubt continue to do battle over whether the Salil decision was a decisive victory for insurers or a limited one. In Salil, the insured landlord leased its building to a restaurant operator. After the insured’s tenant reported water and odor at the restaurant, the insured contacted a plumber, who informed the insured that a clog in the restaurant’s toilet caused Category 3 water to flow into the restaurant. The insured allegedly sustained approximately $160,000 in restoration costs and loss of business income. The plumber used a snake to clear the sewer line to remedy the issue. The restoration company confirmed the cause of the loss was a sewer back up. On this basis, the insurer determined that the cause of loss was a sewer backup. The policy excluded coverage for water damage caused by a sewer back-up, but an endorsement restored that coverage, subject to a $25,000 sub-limit for “direct physical loss or damaged caused by water… which backs up into a building or structure through sewers or drains which are directly connected to a sanitary sewer or septic system.” Pursuant to this endorsement, the insurer paid its $25,000 sublimit. Read the court decision
Read the full story...
Reprinted courtesy of Kevin Sullivan, Traub Lieberman
Mr. Sullivan may be contacted at ksullivan@tlsslaw.com

---

Homeowners Must Comply with Arbitration over Construction Defects

January 06, 2012 — CDJ STAFF

The California Court of Appeals has upheld a decision by the Superior Court of Kern County that homeowners must comply with arbitration procedures in their construction defect claim. The California Court of Appeals ruled on December 14 in the case of Baeza v. Superior Court of Kern County, denying the plaintiff’s petition that the trial court vacate its order.

The plaintiffs in the case are homeowners in various developments built by Castle & Cook. The homes were sold with a contract that provided for “nonadversarial prelitigation procedures, including mediation, and judicial reference.” The homeowners made defect claims and argued that Castle & Cooke failed to comply with statutory disclosure requirements and that some of the contracts violate related statutes.

The appeals court found that there was no ground for appeal of the lower court’s order to continue with prelitigation procedures. The court noted that the plaintiffs could not seek a review of the mediation until a judgment was issued, but that then the issue would be moot. The court felt that there were issues presented that needed clarification, and so they reviewed this case. This was cleared for publication.

The court considered the intent of the legislature in passing the Right to Repair Act, noting that “under the statutory scheme, the builder has the option of contracting for an alternative nonadversarial prelitigation procedure,” as established in Chapter 4. The court noted that Chapter 4 “contains no specifics regarding what provisions the alternative nonadversarial contractual provisions may or must include.”

The plaintiffs contended that the builder was in violation of the standards set out in Section 912, however the court responded that these sections set out one set of procedures, but they concluded that “if the Legislature had intended the section 912 disclosure provisions…it could have made the requirements applicable to all builders by locating them in a section outside Chapter 4.”

Read the court’s decision…

Read the court decision
Read the full story...
Reprinted courtesy of

---