Fairfield Connecticut Building Expert Directory

Insurer Has Duty to Defend Additional Insured in Construction Defect Case

January 07, 2015 — Tred R. Eyerly- Insurance Law Hawaii
The court denied the insurer's motion for summary judgment, holding that the insurer had a duty to defend the additional insured against claims for construction defects. Centex Homes v. Lexington Ins. Co., 2014 U.S. Dist. LEXIS 164472 (C.D. Cal. Nov. 24, 2014). Centex contracted with Gateway Concrete, Inc. to install concrete foundations for a housing development. Gateway was required to purchase insurance with an endorsement naming Centex as an additional insured. Gateway obtained the policy from Lexington. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Best Practices: Commercial Lockouts in Arizona

April 10, 2023 — Patrick Tighe - Snell & Wilmer Real Estate Litigation Blog
If a tenant defaults under a commercial lease, Arizona law permits the landlord to re-take possession of the premises by locking out the defaulting tenant. However, if the landlord’s lockout is wrongful, the landlord may be liable for the damages the tenant sustains because of the wrongful lockout. To minimize such liability, here are some general best practices to follow when locking out a defaulting tenant:

Do Not Breach the Peace. It is vital when performing a lockout to not breach the peace. What constitutes a “breach of the peace” depends on the particular circumstances at hand. For example, if a tenant arrives during the lockout and becomes angry or threatens violence, the landlord should stop performing the lockout and return at a later time. As a general rule of thumb, it is best to perform lockouts in the early morning hours or in the late evening hours when the landlord is less likely to encounter the tenant.
Provide A Notice of Default. Many commercial leases require the landlord to provide a notice of default before the landlord can lock out a defaulting tenant. Check, double check, and triple check that the landlord followed the lease’s notice of default provisions correctly, including that the landlord sent the notices to all required parties in accordance with the time requirements set forth in the lease.

Read the court decision
Read the full story...
Reprinted courtesy of Patrick Tighe, Snell & Wilmer
Mr. Tighe may be contacted at ptighe@swlaw.com

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

New Green Standards; Same Green Warnings for Architects & Engineers (law note)

January 13, 2014 — Melissa Dewey Brumback - Construction Law in North Carolina
The newest version of the LEED ratings system, LEED v4, has officially been released. For a comparison of the major changes between LEED 2009 and LEEDv4, check out this downloadable form from the USGBC. As the folks at Schinnerer’s pointed out, there is one major change that is fraught with peril for design professionals– the requirement for increased transparency concerning the composition and performance requirements of composition materials. Notes the insurance carrier: “While design firms always had a level of responsibility for ongoing product research, the lack of standardized, affirmative industry data made it difficult for design firms and project owners to assess the impact of building materials on human health. “As with many aspects of sustainability in design and construction, the danger to design firms is likely to come from self-inflicted perils. When a firm accepts responsibility to ‘ensure that a project meets its goals by using the best products that align with project requirements,’ it is essentially giving the project owner a guarantee that is both beyond the firm’s control and uninsurable by any insurance carried by a firm.” Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback
Ms. Brumback can be contacted at mbrumback@rl-law.com

Summarizing Changes to NEPA in the Fiscal Responsibility Act (P.L. 118-5)

September 05, 2023 — Anthony B. Cavender & Marcus Manca - Gravel2Gavel Construction & Real Estate Law Blog
The National Environmental Policy Act (NEPA) was signed into law on January 1, 1970, and it has rarely been amended or revised since then. NEPA is basically a procedural statute which requires Federal permitting authorities, before a major federal project is approved, to carefully consider the significant environmental consequences of the proposed federal action. NEPA has been employed to conduct a probing review of wide variety of federal projects and actions, and the President’s Council on Environmental Quality (CEQ) has promulgated a comprehensive set of rules and guidance documents that must be followed or consulted. (See 40 CFR Section 1500 et seq.) The first set of NEPA rules was issued in 1978, and very little was done to bring the rules up to date until 2020. The first phase of this review has been completed, and a second and final phase will soon be underway. The NEPA review process includes the use of “categorical exclusions,” environmental assessments and environmental impact statements to measure the environmental impact of a proposed project. Over time, the rules and their implementation and judicial interpretation have become ever more complex, and an enormous body of NEPA case law has resulted. The recent Congressional debt limit deliberations provided an opportunity to revise some of these procedures, and the Fiscal Responsibility Act, signed into law on June 3, 2023, included at Title III, a section devoted to “Permitting Reform.” Reprinted courtesy of Anthony B. Cavender, Pillsbury and Marcus Manca, Pillsbury Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

California insured’s duty to cooperate and insurer’s right to select defense counsel

April 14, 2011 — CDCoverage.com

In Travelers Property Casualty Co. v. Centex Homes, No. C 10-02757 (N.D. Cal. April 1, 2011), general contractor Centex was sued by homeowners for construction defects. Centex tendered its defense to Travelers as an additional insured under policies issued by Travelers to two Centex subcontractors. Travelers agreed to defend Centex under a reservation of rights and selected defense counsel to defend Centex. Centex refused to accept the defense, asserting that it was entitled to select defense counsel. Travelers filed suit against Centex seeking a declaratory judgment that Centex had breached the duty to cooperate condition in the Travelers’ policy.

Read the full story...

Reprinted courtesy of CDCoverage.com

Read the court decision
Read the full story...
Reprinted courtesy of

Hawaii Appellate Court Finds Duty to Defend Group Builders Case

May 10, 2013 — Tred Eyerly
On May 19, 2010, the Hawaii Intermediate Court of Appeals determined construction defect claims did not constitute an occurrence under a CGL policy.Group Builders, Inc. v. Admiral Ins. Co., 123 Haw. 142, 231 P.3d 67 (Haw. Ct. App. 2010) ("Group Builders I"). The appeal in Group Builders I, however, only addressed the duty to indemnify. The ICA has now issued a second decision (unpublished), holding that there is was duty to defend Group Builders on the construction defect claims under Hawaii law, based upon the policy language and the allegations in the underlying complaint. Group Builders, Inc. v. Admiral Ins. Co., 2013 Haw.App. LEXIS 207 (Haw. Ct. App. April 15, 2013). The underlying suit involved allegations by Hilton Hotels Corp. that Group Builders, a subcontractor working on an addition to the hotel, was responsible for mold found after completion of the project. Hilton alleged that the "design, construction, installation, and/or selection of the . . . building exterior wall finish . . . did not provide an adequate air and/or moisture barriers." The counts alleged against Group Builders included breach of contract and negligence. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Mr. Eyerly can be contacted at te@hawaiilawyer.com

Cost of Materials Holding Back Housing Industry

June 28, 2013 — CDJ STAFF
As home building makes its recovery, there’s another hurdle to overcome: the cost of building materials. The Toledo Blade reports that the rise in the costs of materials makes homes built this year several thousands of dollars more expensive than those built last year. One builder, James Moline, said that he “ended up eating some of the lumber prices on a deal this spring because lumber prices went up so much.” The cost of framing lumber has increased by about two-thirds, while the cost of strand board has more than doubled. Happily, material costs seem to have hit their high and in recent months have started to lower. The rise, according to Robert Denk, a senior economist at the National Association of Home Builders, is due to suppliers cutting back on capacity when demand dwindled, and despite the increase in building starts, suppliers have yet to bring that capacity back. Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES