Seattle Washington Building Expert Directory

Quick Note: COVID-19 Claim – Proving Causation

August 03, 2020 — David Adelstein - Florida Construction Legal Updates
In certain jurisdictions, the number of people testing positive for COVID-19 is on the rise. As this occurs, there is the possibility that a construction project will have to deal with one or more workers testing positive. That is the current reality. If the dialogue has not occurred before, now is the time to discuss any enhanced measures—above OSHA guidelines—that could be implemented to address this reality and mitigate the risk. Part of the reality, though, is that regardless of the enhanced measures and mitigation, it is impossible to truly prevent this risk. No one disputes COVID-19. There may be a dispute as to whether COVID-19 constitutes a force majeure event or some other event, however, before you start labeling it, you still NEED TO PROVE the impact caused by COVID-19. There needs to be a cause-and-effect relationship so you can address (i) how this impacted the critical path of your schedule and/or (ii) how this impacted labor productivity. In other words, you need to prove causation. Stating there was a delay or loss of productivity without establishing the cause-and-effect relationship (i.e, causation) provides no value because it does not support the production impact or time extension and, without either, there is no basis for additional compensation (even if you establish it should be deemed an excusable, compensable delay). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Business Insurance Names Rachel Hudgins Among 2024 Break Out Award Winners

April 22, 2024 — Hunton Insurance Recovery Blog
We are pleased to announce that counsel Rachel E. Hudgins has been recognized as one of Business Insurance’s 2024 Break Out Award winners. The magazine’s Break Out Awards honor 40 top professionals each year from a competitive field of nominees who have under 15 years’ experience in the insurance and risk management sector and are “on track to be the next leaders in the risk management and property/casualty insurance field.” Clients describe Rachel as their “chief contact for high-exposure coverage work.” She meets clients where they are with a curiosity and interest in their business strategies, as well as an ability to distill complex insurance concepts into digestible terms. Rachel also has depth of experience in coverage litigation. She has litigated hundreds of insurance coverage and bad faith claims in state and federal courts across the country and US territories. Read the court decision
Read the full story...
Reprinted courtesy of Hunton Andrews Kurth LLP

Expect the Unexpected (Your Design Contracts in a Post-COVID World)

April 18, 2023 — Melissa Dewey Brumback - Construction Law in North Carolina
Have you adapted your post-COVID practice to better plan for the “unexpected” ? In particular, have you looked at–and revised– your professional services contracts to give yourself a little more breathing room for unaccounted issues that may arise? If not, no time like the present. Don’t like that saying? How about ” a stitch in time saves nine?” No? Still nothing? What about a picture of something so completely unexpected it shocks you– say, a fireman commuting home, in fire-fighting regalia, on a tricycle? Okay, here you go… Now that I have your attention– you should make it a practice to regularly review and update your professional services agreements, and you should consider issues such as:

Does your agreement provide for extra compensation if you have to spend more time or a longer period providing construction administration services for material delays or labor shortages? If not, it should.
Does your agreement have a well-written “act of God” provision– one that includes pandemic/epidemics as part of the “act of God” conditions in which a term may become void? If not, add it now!

Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Ragsdale Liggett
Ms. Brumback may be contacted at mbrumback@rl-law.com

Federal Court Sets High Bar for Pleading Products Liability Cases in New Jersey

November 11, 2024 — Lian Skaf - The Subrogation Strategist
Products liability is an area of law that both sides of the aisle vigorously litigate. Like in most litigation, products liability claims provide subrogation attorneys with an important means of prosecuting cases against manufacturers, sellers, and other entities in the stream of commerce. Of course, these claims also come with numerous “buyer beware” requirements. New Jersey allows products liability claims and the United States District Court for the District of New Jersey (District Court) clarified how such claims should be plead in Cambridge Mut. Fire Ins. Co. a/s/o David Krug vs. Stihl, Inc., No. 22-05893, 2024 U.S. Dist. LEXIS 178804 (D. N.J.). After becoming subrogated to the rights of its insured, Cambridge Mutual Fire Insurance Company (Cambridge) filed suit against Stihl, Inc. (Stihl) in the Superior Court of New Jersey, Morris County, Law Division. Stihl then removed the case to federal court. Once in federal court, Stihl filed a motion to dismiss the action. The District Court granted the motion, doing so in part with prejudice and in part without prejudice. Read the court decision
Read the full story...
Reprinted courtesy of Lian Skaf, White and Williams LLP
Mr. Skaf may be contacted at skafl@whiteandwilliams.com

How the Science of Infection Can Make Cities Stronger

November 13, 2023 — Carlo Ratti & Michael Baick - Bloomberg
Earlier this year, a group of European researchers published a study with a scorching conclusion: As climate change makes heat waves more prevalent across the continent, the city most vulnerable to excess heat deaths is not a warm southern metropolis, but the relatively cool city of Paris. Why? In part, the reason is that historically hotter cities have developed adaptations for dealing with extreme heat, from the shady architecture of Palermo to the siestas of Madrid. That leaves Paris at the bottom of a deadly learning curve. This is just one urgent example of why cities need to talk. The world has an incredible stockpile of effective urban policies, but the best ideas are not being adopted quickly or widely enough. Covid-19 taught us all how to slow the spread of viruses: wear masks, avoid large gatherings and take vaccines. To speed the spread of good ideas, we need to take the opposite tack by making urban solutions go viral. Reprinted courtesy of Carlo Ratti, Bloomberg and Michael Baick, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

Eye on Housing Examines Costs of Green Features

July 09, 2014 — Beverley BevenFlorez-CDJ STAFF
The National Association of Home Builders’ Eye on Housing reported that it costs more to build a green home, however, builder’s experience with green techniques reduces costs. According to McGraw Hill Construction survey data (as quoted by Eye on Housing), “the incremental cost for builders to construct green homes was 8% in 2013. For remodelers, green projects raised costs by 9% on average.” Furthermore, “McGraw Hill’s analysis found that the cost to build green varied to some degree by the amount of green construction undertaken.” Read the court decision
Read the full story...
Reprinted courtesy of

World’s Biggest Crane Gets to Work at British Nuclear Plant

October 07, 2019 — Jeremy Hodges - Bloomberg
The world’s largest crane is getting ready to hoist more than 700 of the heaviest pieces of the first new nuclear plant being built in Britain in decades. The machine, affectionately known as “Big Carl” after an executive at Belgian owner Sarens NV, is in place at Electricite de France SA’s 19.6 billion-pound ($24.1 billion) Hinkley Point C project in southwest England. It can carry as much as 5,000 tons, or the same weight as 1,600 cars, in a single lift and arrived on 280 truck loads from Belgium. It has taken about three months to build. Nuclear power makes up about a fifth of Britain’s electricity. Most of those plants are near the end of their lives and will close in the next decade. Replacing them won’t be easy—as the scale of the project shows. Earlier this year, EDF poured 9,000 cubic meters of cement, the biggest single biggest pour of concrete ever recorded in Britain. It was reinforced by 5,000 tons of steel built into a nest 4 meters high that’ll serve as the base of the first new reactor in the U.K. since 1995. Read the court decision
Read the full story...
Reprinted courtesy of Jeremy Hodges, Bloomberg

The Vallagio HOA Appeals the Decision from the Colorado Court of Appeals

August 04, 2015 — David M. McLain – Colorado Construction Litigation
As highlighted in our most recent post, the Colorado Court of Appeals’ Vallagio decision upheld a declaration provision that prohibited the amendment of a mandatory arbitration clause without the consent of the developer/declarant. Vallagio at Inverness Residential Condominium Association, Inc. v. Metropolitan Homes, Inc., et al., 2015COA65 (Colo. App. May 7, 2015). This case protects a developer/declarant’s ability to arbitrate construction defect claims with a well-crafted declaration that requires declarant consent in order to amend the mandatory arbitration provisions for construction defect actions. However, the Vallagio ruling still hangs in the balance while the Colorado Supreme Court considers the condominium association’s petition for certiorari review, filed June 18, 2015. In its petition, the association argues that the declarant consent requirement violates public policy and four separate sections of the Colorado Common Interest Act (“CCIOA”). For instance, the association argued in the courts below that a declarant consent requirement violates section 217 of CCIOA, which governs unit owners’ voting percentage requirements and provides that declarations may not require more than 67% affirmative vote for amendments. The Court of Appeals rejected this argument, reasoning that other provisions of section 217 contemplate consent requirements by parties other than unit owners, such as first mortgagees. Read the court decision
Read the full story...
Reprinted courtesy of David M. McLain, Higgins, Hopkins, McLain & Roswell, LLC
Mr. McLain may be contacted at mclain@hhmrlaw.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES