Seattle Washington Building Expert Directory

Second Circuit Affirms Win for General Contractor on No Damages for Delay Provision

September 02, 2024 — Bill Wilson - Construction Law Zone
In NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The Court enforced a typical no-damages-for-delay provision to bar the subcontractor’s breach of contract claim. The no-damages-for-delay provision in the subcontract at issue provided:

NO DAMAGE FOR DELAY. Except as otherwise provided …, Subcontractor agrees that it shall have no Claim against Contractor for any loss or damage it may sustain through delay, disruption, suspension, stoppage, interference, interruption, compression, or acceleration of Subcontractor’s Work (‘Delay Damages’) caused or directed by Contractor for any reason, and that all such Claims shall be fully compensated for by Contractor’s granting Subcontractor such time extensions as it is entitled to as a result of any of the foregoing.

Read the court decision
Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

“Freelance Isn’t Free” New Regulations Adopted in New York City Requiring Written Contracts with Independent Contractors

June 15, 2017 — Kevin J. O'Connor - Peckar & Abramson. P.C.
Attacks on employers for alleged misclassification of workers—particularly independent contractors—are continuing unabated, and the risk of liability for employers operating in New York City just increased. New York City has just adopted sweeping regulations requiring written contracts with certain freelancers and independent contractors. Anyone doing business in that jurisdiction should take notice and take action to comply with the law. New York City’s “Freelance Isn’t Free Act,” N.Y.C. Administrative Code §§ 20-927 et seq. (“FIFA”) went into effect on May 15, 2017. This new law substantially regulates the relationship between a business and an independent contractor or “freelancer” working in New York City. Read the court decision
Read the full story...
Reprinted courtesy of Kevin J. O'Connor, Peckar & Abramson. P.C.
Mr. O'Connor may be contacted at koconnor@pecklaw.com

Quick Note: Do Your Homework When it Comes to Selecting Your Arbitrator

July 26, 2017 — David Adelstein - Florida Construction Legal Updates
Many construction contracts contain arbitration provisions. Instead of litigating a dispute arising out of the contract, the parties will arbitrate the dispute per the arbitration provision. There are advantages to arbitration and certain disputes bode well for arbitration. The key is you want to make sure you select the RIGHT arbitrator or arbitrators. Do your homework regarding the arbitrator list presented to you by, say, the American Arbitration Association. Strike out those on the list that either do not have the requisite experience you need to decide the dispute or you believe they are not going to be impartial. For instance, if you want an arbitrator that you think will specifically follow the letter of the law or the precise terms of a contract, select those on the list that meet this requirement; strike out others that do not. The same philosophy would apply if you want an arbitrator to have specific factual knowledge or a factual understanding regarding a driving issue in the dispute. Do not neglect the homework required to select –or try to select — the arbitrator you believe is the most qualified to understand the issues. Now, why is this important? It is important because you need to arbitrate a dispute with the understanding that the arbitrator’s award (decision) is FINAL. There are no appellate rights. None. Vacating an arbitrator’s award is very challenging and the bases to vacate an award are limited and, most of the time, will NOT apply. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at Dadelstein@gmail.com

Carroll Brock of Larchmont Homes Dies at Age 88

November 05, 2014 — Beverley BevenFlorez-CDJ STAFF
Homebuilder Carroll Brock, "whose family-owned company built thousands of Larchmont Homes in the Sacramento region, died Oct. 31 of natural causes in his sleep, his son Steve said," according to the obituary in the Sacramento Bee. "Under Mr. Brock, who was named Sacramento general manager in 1967, Larchmont Homes built nearly 15,000 houses in more than 30 subdivisions of modest ranch-style homes aimed mostly at first-time buyers." Mr. Brock served on the board of the National Association of Home Builders, was past president of the North State Building Industry Association, and had been appointed to the California state Board Standards Commission. Furthermore, he was inducted into the California Building Industry Association Hall of Fame in 1991. Mr. Brock served the community through his work in the Sacramento Area Commerce and Trade Commission as well as the Sacramento Metropolitan Chamber of Commerce. He volunteered his time to the Salvation Army as well as offering construction assistance and expertise to the Fair Oaks Presbyterian Church. “My dad was a humble leader,” his son told the Sacramento Bee. “As successful as he was at building homes, he felt just as strongly about serving others.” Read the court decision
Read the full story...
Reprinted courtesy of

BHA Attending the Construction Law Conference in San Antonio, Texas

February 24, 2016 — CDJ STAFF
Bert L. Howe & Associates, Inc. (BHA), will once again be joining with the State Bar of Texas, Construction Law Section as a sponsor and exhibit at the event on March 3 & 4, 2016, and is excited to announce that they will be sponsoring a raffle for a $100 Outdoor World gift card to be given away at the conference. Just stop by the BHA booth, and drop your card in the bowl for a chance to win. With offices in San Antonio and Houston, BHA offers the experience of over 20 years of service to carriers, defense counsel, and insurance professionals as designated experts in over 5,500 cases. BHA’s staff encompasses a broad range of licensed and credentialed experts in the areas of general contracting and specialty trades, as well as architects, civil and structural engineers, and has provided services on behalf of developers, general contractors and subcontractors across the state of Texas. BHA’s experience covers the full range of construction defect litigation, including single and multi-family residential properties (including high-rise), institutional buildings (schools, hospitals and government), commercial, and industrial claims. BHA also specializes in coverage, exposure, and delay claim analysis. Download the seminar brochure and register... Read the court decision
Read the full story...
Reprinted courtesy of

California Case Adds Difficulties for Contractors & Material Suppliers

August 20, 2014 — Beverley BevenFlorez-CDJ STAFF
Garret Murai in his California Law Blog declared that “things just got a lot tougher for contractors and material suppliers in the Golden State.” In his blog, Murai analyzed the recent case Golden State Boring & Pipe Jacking, Inc. v. Eastern Municipal Water District, Case No. E054618 (July 23, 2014), in which “the California Court of Appeals for the Fourth Appellate District found that a subcontractor’s public works payment bond claim was time barred because its stop payment notice was served ‘before’ a notice of completion was recorded.” Murai explained the importance of the ruling and how it changed the status quo: “Whereas before, it was commonly understood that you could serve a stop payment notice ‘during’ construction (after all, that was the point wasn’t it, to stop construction funds before they are paid out), now you may have only have a 30 day window (probably less) to serve a stop notice within 30 days after a notice of completion or notice of cessation is recorded.” Read the court decision
Read the full story...
Reprinted courtesy of

Kentucky Supreme Court Creates New “Goldilocks Zone” to Limit Opinions of Biomechanical Experts

July 24, 2023 — Aimee E. Muller - Lewis Brisbois
Lexington, Ky. (June 26, 2023) – In a recent decision, the Kentucky Supreme Court placed stricter limitations on the opinions that biomechanical engineers may offer at trials in Kentucky courts. Specifically, the published opinion issued in Renot v. Securea, Supreme Ins. Co., 2023 Ky. LEXIS 163, recognizes a new space for the testimony of biomechanics experts – “The Goldilocks Zone.” Where is the Goldilocks Zone? The Goldilocks Zone is a perfect place in which the proffered testimony is neither too specific such that it wanders into the realm of medical causation, nor too general such that it fails to help a lay jury. Specifically, a biomechanical engineer’s expert testimony must be limited to the forces generated by the subject collision, the generally anticipated responses of a hypothetical person’s body to those forces, and the range of typical injuries resulting from such forces. Moreover, following Renot, a biomechanical engineer’s proffered opinions no longer may enter into the realm of diagnosing a specific medical condition associated with a traumatic injury. Instead, the question of whether a trauma actually caused or exacerbated a plaintiff’s injuries falls solely within the purview of a medical doctor. Read the court decision
Read the full story...
Reprinted courtesy of Aimee E. Muller, Lewis Brisbois
Ms. Muller may be contacted at Aimee.Muller@lewisbrisbois.com

Developer Africa Israel Wins a Round in New York Condominium Battle

March 12, 2014 — Beverley BevenFlorez-CDJ STAFF
In Manhattan, New York, a “Supreme Court judge partially granted a temporary restraining order to Africa Israel,” which “means the developer does not at this time have to cede control of the Downtown Condominium board to unit owners, following a February lawsuit against the developers by state Attorney General Eric Schneiderman,” according to The Real Deal. The condominium battle began after Schneiderman filed suit against the developers, claiming that they did not fix construction defects, which in turn caused them to fail to obtain a certificate of occupancy, reported The Real Deal. The attorney general “also alleged that the pair misappropriated more than $9 million placed in an escrow account to finance those repairs.” However, according to The Real Deal, Africa Israel has claimed not to be a sponsor of the building. “Attorney Aaron Abraham, representing both Africa Israel and the sponsor of 15 Broad, claimed …that Africa Israel, an Israeli development firm led by billionaire Lev Leviev, never signed any documents claiming to be a sponsor of the building, noting that the sponsor principals were Boymelgreen and Pinchas Cohen.” Steve Sladkus, attorney for the condominium unit owners, told The Real Deal, “They partnered up with Boymelgreen — they need to deal with the fallout of that.” Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES