Seattle Washington Building Expert Directory

California Supreme Court Allows Claim Under Unfair Competition Statute To Proceed

October 16, 2013 — Tred Eyerly — Insurance Law Hawaii
The California Supreme Court determined that insurance practices violating the state's Unfair Insurance Practices Act (UIPA) could support a claim under the state's unfair competition law (UCL). Zhang v. Superior Court, 57 Cal. 4th 353 (2013). Zhang purchased a CGL policy from California Capital Insurance Company. She sued California Capital in a dispute over coverage for fire damage to her commercial property. The complaint included causes of action for breach of contract, breach of the implied covenant of good faith and fair dealing, and violation of the UCL. In her UCL claim, Zhang alleged that California Capital had "engaged in unfair, deceptive, untrue, and/or misleading advertising" by promising to provide timely coverage in the event of a compensable loss, when it had no intention of paying the true value of the insureds' covered claims. Zhang specifically alleged unreasonable delays causing deterioration of her property; withholding of policy benefits; refusal to consider cost estimates; misinforming her as to the right to an appraisal; and falsely telling her mortgage holder that she did not intend to repair the property, resulting in foreclosure proceedings. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

Hunton Andrews Kurth Promotes Insurance Recovery Lawyer Andrea (Andi) DeField to Partner

April 05, 2021 — Lorelie S. Masters - Hunton Insurance Recovery Blog
Effective April 1, 2021, Hunton Andrews Kurth LLP has promoted insurance recovery lawyer, Andi DeField, and six other attorneys, to partner. “Andi has been a superstar in our practice since the day she arrived,” said insurance recovery practice head, Walter Andrews, adding that “Andi’s promotion reflects the incredible hard work she has contributed to the practice and outstanding results she has achieved for our clients over the years.” A native of Miami, Andi ascended through the ranks at Hunton in its Miami office, joining the firm as a contract lawyer before earning promotions to associate, counsel and, now, partner. But Andi’s rapid ascension did not come without much hard work. Since joining the firm, “Andi has, year after year, consistently knocked the cover off the ball in terms of her tireless work ethic, the superior results she has achieved and her extraordinary aptitude for marketing herself, our practice and the firms many other practices,” said insurance recovery partner, Mike Levine. Levine added, “Andi is an amazing lawyer and a true champion for her clients. I’m proud to now call her my partner.” Read the court decision
Read the full story...
Reprinted courtesy of Lorelie S. Masters, Hunton Andrews Kurth
Ms. Masters may be contacted at lmasters@HuntonAK.com

Property Damage, Occurrences, Delays, Offsets and Fees. California Decision is a Smorgasbord of Construction Insurance Issues

November 21, 2017 — Garret Murai - California Construction Law Blog
Originally published by CDJ on November 15, 2017 I read once that 97 percent of cases never go to trial. However, there are still the ones that do. And, then, there are the ones that do both. The following case, Global Modular, Inc. v. Kadena Pacific, Inc., California Court of Appeals for the Fourth District, Case No. E063551 (September 8, 2017), highlights some of the issues that can arise when portions of cases settle and other portions go to trial, the recovery of delay damages on a construction project through insurance, and the recovery of attorneys’ fees. Global Modular, Inc. v. Kadena Pacific, Inc. The U.S. Department of Veterans Affairs contracted with general contractor Kadena Pacific, Inc. (Kadena) to oversee construction of its Center for Blind Rehabilitation in Menlo Park, California. Kadena, in turn, contracted with subcontractor Global Modular, Inc. (Global) to construct, deliver and install 53 modular units totaling more than 37,000 square feet for a contract price of approximately $3.5 million. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Spa High-Rise Residents Frustrated by Construction Defects

February 07, 2013 — CDJ STAFF
Is this part of the spa treatment? A couple has sued over problems at Miraval Living, a luxury high-rise on the East Side of Manhattan. There was supposed to be ballroom dancing, culinary classes, and yoga. Anthony Argyrides's lawsuit notes that those didn't materialize. What they did get, he claims, was faulty plumbing, crumbling fixtures, and defective floor tiles. Mr. Argyrides claims that his front door "spontaneously fell of its hinges and nearly hit FiOS installation workers." Meanwhile, building management has ended their agreement with Miraval and need to find someone else to operate the building's spa. Argyrides and his fellow building residents might need something more than a few deep calming breaths. He's suing for $5.5 million. Read the court decision
Read the full story...
Reprinted courtesy of

Quick Note: Staying, Not Dismissing, Arbitrable Disputes Under Federal Arbitration Act

July 31, 2024 — David Adelstein - Florida Construction Legal Updates
As you hopefully know from posted articles, arbitration is a creature of contract. Stated differently, there must be a contractual basis to have a dispute resolved through binding arbitration. The Federal Arbitration Act (FAA) applies to transactions involving interstate commerce. Oftentimes, lawsuits are filed despite an arbitration provision in a contract because parties can, if they desire, waive their rights to have their dispute resolved through binding arbitration. In what should not be a shocker, the United States Supreme Court in Smith v. Spizzirri, 144 S.Ct. 1173, 1178 (2024), held that when a federal “district court finds that a lawsuit involves an arbitrable dispute, and a party requests a stay pending arbitration, section 3 of the FAA compels the court to stay the proceeding.” Dismissing the lawsuit should not be the option. Staying the lawsuit should. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Florida Appellate Court Holds Four-Year Statute of Limitations Applicable Irrespective of Contractor Licensure

June 22, 2016 — Clay Whittaker – Florida Construction Law Update
In Brock v. Garner Window & Door Sales, Inc.,[1] Florida’s Fifth District Court of Appeal rejected a novel attempt to circumvent Florida’s well-established four-year statute of limitations for all actions founded on the construction of an improvement to real property. Plaintiff filed a lawsuit alleging breach of contract as a result of water intrusion damage following the installation of windows.[2] It was undisputed that Plaintiff commenced the litigation more than four years following the discovery of the allegedly latent defect in the window installation.[3] Plaintiff’s counsel argued that the window contractor could not rely on the four-year statute of limitations because the window subcontractor was not a licensed contractor and, therefore, the five-year statute of limitations for actions founded on written contracts should apply. Read the court decision
Read the full story...
Reprinted courtesy of Clay Whittaker, Cole, Scott, & Kissane, P.A.
Mr. Whittaker may be contacted at clay.whittaker@csklegal.com

Violation of Prompt Payment Statutes is Not a Breach of Contract. But That’s Not the Most Interesting Part

November 01, 2022 — Garret Murai - California Construction Law Blog
While construction projects can get messy, they don’t get much messier than the next case, which, while involving a fairly limited legal issue, has such jaw dropping facts it’s worth a read if only to make you feel a bit better about your own project. The Clark Bros. Case In Clark Bros, Inc. v. North Edwards Water District, 77 Cal.App.5th 801 (2022), general contractor Clark Bros., Inc. was awarded over $3 million in damages against a local water district on a water treatment facility project. The Project The North Edwards Water District serves approximately 220 customers in the Mojave Desert. It has one employee, Dollie Dimples Kostopoulos. Seriously, you can’t make this stuff up. The drinking water it provides to its customers contains three times the legal limit of arsenic, a carcinogen. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Formal Request for Time Extension Not Always Required to Support Constructive Acceleration

April 25, 2022 — David Adelstein - Florida Construction Legal Updates
Does a constructive acceleration claim require the contractor to always request an extension of time which is then denied by the owner? While this is certainly the preference and the contractor should be requesting an extension of time as a matter of course for an excusable delay, the answer is NO! in certain circumstances. This is conveyed in the factually detailed case discussed below where a formal request for an extension of time was not required for the contractor to support its constructive acceleration claim. But first, what is constructive acceleration: Constructive acceleration “occurs when the government demands compliance with an original contract deadline, despite excusable delay by the contractor.” The Federal Circuit in Fraser defined the elements of constructive acceleration as follows: (1) that the contractor encountered a delay that is excusable under the contract; (2) that the contractor made a timely and sufficient request for an extension of the contract schedule; (3) that the government denied the contractor’s request for an extension or failed to act on it within a reasonable time; (4) that the government insisted on completion of the contract within a period shorter than the period to which the contractor would be entitled by taking into account the period of excusable delay, after which the contractor notified the government that it regarded the alleged order to accelerate as a constructive change in the contract; and (5) that the contractor was required to expend extra resources to compensate for the lost time and remain on schedule. Nova Group/Tutor-Saliba v. U.S., 2022 WL 815826, *42 (Fed.Cl. 2022) quoting Fraser Constr. Co. v. U.S., 384 F.3d 1354, 1361 (Fed. Cir. 2004) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES