Is The Enforceability Of A No-Damage-For-Delay Provision Inappropriate For Summary Judgment
February 24, 2020 —
David Adelstein - Florida Construction Legal UpdatesIs the enforceability of a no-damage-for-delay provision inappropriate for resolution on a summary judgment? The recent decision in U.S. f/u/b/o Kingston Environmental Services, Inc. v. David Boland, Inc., 2019 WL 6178676 (D. Hawaii 2019), dealing with Florida law, suggests that it is inappropriate for a summary judgment resolution, particularly when there is a right to a jury trial.
In this case, a prime contractor was hired on a federal construction project in Hawaii. The prime contractor hired a subcontractor and the subcontractor sued the prime contractor and its surety under the Miller Act. Of interest, the subcontractor was seeking to recover for the costs it incurred due to construction delays. The prime contractor moved for summary judgment as to the no-damage-for-delay provision in the subcontract. The no-damages-for-delay provision read as follows (and it is a well-written no-damage-for-delay provision):
The Subcontractor expressly agrees that the Contractor shall not be liable to the Subcontractor for any damages or additional costs, whether foreseeable or unforeseeable, resulting in whole or in part from a delay, hindrance, suspension, or acceleration of the commencement or execution of the Work, caused in whole or in part by the acts or omissions, whether negligent or not, of the Contractor including other subcontractors or material suppliers to the Project, its agents, employees, or third parties acting on behalf of the Contractor. The Subcontractor’s sole remedy for any such delay, hindrance, suspension, or acceleration shall be a noncompensable time extension.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Insurer's Denial of Coverage to Additional Insured Constitutes Bad Faith
May 21, 2014 —
Tred R. Eyerly – Insurance Law HawaiiThe insurer's unreasonable denial of a defense and indemnity to a lessor/additional insured was found to be in bad faith. Seaway Props. v. Fireman's Fund Ins. Co., 2014 U.S. Dist. LEXIS 55998 (W.D. Wash. April 22, 2014).
Seaway leased restaurant space to Ciao Bella Food, LLC. In January 10, 2010, the underlying plaintiff was on her way to the restaurant when she attempted to step down from a concrete platform between the building parking lot and the entrance to the restaurant. Seaway's lease gave Ciao Bella the right to use the common areas, including the parking lot, but did not grant Ciao Bella exclusive control over the common areas. The plaintiff suffered injuries and claimed both Ciao Bella and Seaway were liable.
Seaway's lease required Ciao Bella to maintain a CGL policy and to name Seaway as an additional insured. Ciao Bella did so by securing a policy with Fireman's Fund. Fireman's Fund had notice of the plaintiff's claim by November 2010. Seaway demanded in March 2012 that Fireman's Fund indemnify and defend it. In September 2012, two years after it first learned of the plaintiff's injury, Fireman's Fund denied coverage, asserting that Seaway was not an insured under the policy.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
Amazon Can be Held Strictly Liable as a Product Seller in New Jersey
August 07, 2022 —
Michael L. DeBona - The Subrogation StrategistOn June 29, 2022, in N.J. Mfrs. Ins. Grp. a/s/o Angela Sigismondi v. Amazon.com, Inc., 2022 U.S. Dist. LEXIS 115826 (Sigismondi), the United States District Court for the District of New Jersey held that Amazon.com, Inc. (Amazon) is a “seller” under New Jersey’s product liability statute and can thus face strict liability for damages caused by products sold on its platform. Although the analysis is state-specific, Sigismondi may serve as an important decision for allowing product defect claims to proceed against Amazon when so often the third-party vendor that lists the product is unlocatable, insolvent, or not subject to the jurisdiction of United States courts.
In recent years, Amazon has been fighting product liability claims across the country. Amazon argues it is not a “seller” under states’ product liability laws but is merely an online marketplace that facilitates the sale of products by third-party vendors. What constitutes a “seller” in a particular state must be evaluated state-by-state, but various courts have accepted Amazon’s argument that it is not a “seller.” These decisions are based on Amazon’s level of control in the product sale and often focus on a finding that Amazon did not convey possession of the product or transfer its title.
Read the court decisionRead the full story...Reprinted courtesy of
Michael L. DeBona, White and WilliamsMr. DeBona may be contacted at
debonam@whiteandwilliams.com
Consumer Protection Act Whacks Seattle Roofing Contractor
July 21, 2011 —
Douglas Reiser, Builders Council BlogIt’s been over 1 year since we last visited the CertainTeed Corp. v. Seattle Roof Brokers lawsuit. After my original post, the contractor, James Garcia, appeared at Builders Counsel in a comment to defend himself. It appears that 1 year later, the court decided to side with CertainTeed and award them significant attorneys’ fees. Ready for the whole story? Its a pricey one.
Back in July 2010, good friend Mike Atkins (Seattle Trademark Attorney) authored a post about a Seattle roofing contractor who had been sued for false advertising on his website. The lawsuit was raised by CertainTeed, a roofing material producer, whose products were the target of a Seattle contractor’s ire. Seattle Roof Brokers, owned by James Garcia, published content on its website, remarking that CertainTeed products have a history of “premature failure” and that they “will fail?.resale inspection after 15-20 years.”
CertainTeed filed its action to obtain an injunction and damages under the Consumer Protection Act.
Read the full story…
Reprinted courtesy of Douglas Reiser of Reiser Legal LLC. Mr. Reiser can be contacted at info@reiserlegal.com
Read the court decisionRead the full story...Reprinted courtesy of
Insurer's Motion for Summary Judgment to Dispose of Hail Damage Claim Fails
November 25, 2024 —
Tred R. Eyerly - Insurance Law HawaiiThe court denied the insurer's motion for summary judgment seeking to dismiss the insured's complaint requesting coverage for hail damage and a claim for bad faith. Rodriquez v. State Farm Lloyds, 2024 U.S. Dist. LEXIS 160007 (W.D. Tex. Sept. 5, 2024).
Mr. Rodriquez sought coverage under his homeowners policy after a hail and wind storm damaged his roof. After inspection, State Farm agreed that some minimal loss caused by hail was covered, but determined that the covered loss was less than the amount of the deductible. State Farm further determined that any hail damage to the roof was excluded by an endorsement, Exclusion of Cosmetic Loss to Metal Roof Coverings Caused by Hail. State Farm also determined that some damage was caused by previous faulty workmanship or wear and tear, both of which were excluded from coverage.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
16 Wilke Fleury Attorneys Featured in Sacramento Magazine 2021 Top Lawyers!
September 20, 2021 —
Wilke Fleury LLPCongratulations to Wilke Fleury’s featured attorneys who made the Sacramento Magazine’s Top Lawyer List for 2021!
The voting for Professional Research Services’ survey to determine the top attorneys in 2021 for Sacramento Magazine was open to all licensed attorneys in Sacramento, Calif. Attorneys were asked whom they would recommend among 56 legal specialties, other than themselves, in the Sacramento area. Each attorney was allowed to recommend up to three colleagues in each given legal specialty. Once the online nominations were complete, each nominee was carefully evaluated on the basis of the survey results, the legitimacy of their license, and their current standing with the State Bar of California. Attorneys who received the highest number of votes in each specialty are reflected in the following list. – Sacramento Magazine
Read the court decisionRead the full story...Reprinted courtesy of
Wilke Fleury LLP
Sometimes a Reminder is in Order. . .
February 18, 2020 —
Christopher G. Hill - Construction Law MusingsRecently, I was talking with my friend Matt Hundley about a recent case he had in the Charlottesville, VA Circuit Court. It was a relatively straightforward (or so he and I would have thought) breach of contract matter involving a fixed price contract between his (and an associate of his Laura Hooe) client James River Stucco and the Montecello Overlook Owners’ Association. I believe that you will see the reason for the title of the post once you hear the facts and read the opinion.
In James River Stucco, Inc. v. Monticello Overlook Owners’ Ass’n, the Court considered Janes River Stucco’s Motion for Summary Judgment countering two arguments made by the Association. The first Association argument was that the word “employ” in the contract meant that James River Stucco was required to use its own forces (as opposed to subcontractors) to perform the work. The second argument was that James River overcharged for the work. This second argument was made without any allegation of fraud or that the work was not 100% performed.
Needless to say, the Court rejected both arguments. The Court rejected the first argument stating:
In its plain meaning, “employ” means to hire, use, utilize, or make arrangements for. A plain reading of the contractual provisions cited–“shall employ” and references to “employees”–and relied on by Defendant does not require that the persons performing the labor, arranged by Plaintiff, be actual employees of the company or on the company’s payroll. It did not matter how the plaintiff accomplished the work so long as it was done correctly. The purpose of those provisions was to allocate to Plaintiff responsibility for supplying a sufficient workforce to get the work done, not to impose HR duties or require the company to use only “in house” workers. So I find that use of contracted work does not constitute a breach of the contract or these contractual provisions.
Read the court decisionRead the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Newmeyer Dillion Attorneys Selected To The Best Lawyers In America© And Orange County "Lawyer Of The Year" 2020
September 03, 2019 —
Newmeyer DillionProminent business and real estate law firm Newmeyer Dillion is pleased to announce that ten of the firm's attorneys were recently recognized in their respective practice areas in The Best Lawyers in America© 2020. In addition, two attorneys have been named Best Lawyers ® 2020 "Lawyer of the Year." Greg Dillion was recognized by Best Lawyers as the 2020 Construction Law "Lawyer of the Year" award winner, while Thomas Newmeyer was recognized by Best Lawyers as the 2020 Litigation - Real Estate "Lawyer of the Year" award winner.
Attorneys named to The Best Lawyers in America, include:
Jason Moberly Caruso
Personal Injury Litigation – Plaintiffs, Product Liability Litigation – Plaintiffs
Michael S. Cucchissi
Real Estate Law
Jeffrey M. Dennis
Insurance Law
Gregory L. Dillion
Commercial Litigation, Construction Law, Insurance Law, Litigation – Construction, Litigation - Real Estate
Joseph A. Ferrentino
Litigation – Construction, Litigation - Real Estate
Jon Janecek
Real Estate Law
Thomas F. Newmeyer
Commercial Litigation, Litigation - Real Estate
John O'Hara
Litigation – Construction
Bonnie T. Roadarmel
Insurance Law
Jane Samson
Real Estate Law
Newmeyer Dillion is immensely proud of our lawyers, whose consistent recognition demonstrates their contributions to the firm, our clients and the legal profession.
With a history of over 35 years, Best Lawyers is the oldest peer review publication within the legal profession. Universally regarded as the definitive guide to legal excellence, Best Lawyers lists are compiled based on an exhaustive peer-review evaluation in which leading lawyers confidentially evaluate their professional peers. Their listings are published in 77 countries worldwide and are recognized for their reliable and unbiased selections. Only one lawyer for each specialty and location is recognized as the "Lawyer of the Year," an award given to the individual with the highest overall peer-feedback for a specific practice area and geographic region.
About Newmeyer Dillion
For 35 years, Newmeyer Dillion has delivered creative and outstanding legal solutions and trial results that align with the business objectives of clients in diverse industries. With over 70 attorneys working as an integrated team to represent clients in all aspects of business, employment, real estate, privacy & data security and insurance law, Newmeyer Dillion delivers tailored legal services to propel clients' business growth. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California and Nevada, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949.854.7000 or visit www.newmeyerdillion.com.
Read the court decisionRead the full story...Reprinted courtesy of
