Seattle Washington Building Expert Directory

Construction Delays: Which Method Should Be Used to Calculate Delay?

July 25, 2021 — David Adelstein - Florida Construction Legal Updates
If you need to prove and allocate construction project delays, you should engage a scheduling consultant qualified with CPM (critical path method) analysis. You should also engage counsel to assist in preserving your rights, as well as presenting and maximing your arguments for delay. There are numerous methodologies used to quantify and allocate delay. You want to discuss the most effective analysis for your case and facts including whether you want/should use a forward-looking prospective analysis or a backward-looking retrospective analysis that factors in as-built data. In doing so, you want to make sure you understand the pros and cons of each methodology including the bases to attack the methodology that will be subject to cross-examination. The five primary CPM methodologies are as follows:

As-Planned Versus As-Built. This methodology compares the as-planned baseline schedule to an as-built schedule reflecting progress to assign delay. An as-built schedule that reflects progress includes actual start dates, finish dates, and durations. The actual dates and durations are compared with the as-planned dates and durations on the baseline schedule to determine delay. Under this methodology, the delay impact is determined retrospectively.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Gone Fishing: Tenant’s Insurer Casts A Line Seeking To Subrogate Against The Landlord

October 17, 2022 — William L. Doerler - The Subrogation Strategist
In J&J Fish on Ctr. Str., Inc. v. Crum & Forster Specialty Ins. Co., No. 20-cv-644-bhl, 2022 U.S. Dist. LEXIS 16361, the United States District Court for the Eastern District of Wisconsin (District Court) recognized that “[t]here will be no further fish fries on Center Street until someone pays to repair the collapsed floor at J&J Fish on Center Street, Inc. (J&J Fish).” The contenders were: 1) J&J Fish; 2) its’ insurer, Crum & Forster Specialty Insurance Company (Insurer); and 3) J&J Fish’s landlord, Vision Land, LLC (Vision). Recognizing Insurer’s right to subrogate against Vision based on the terms of the parties’ lease, the District Court held Insurer owed J&J Fish coverage for the losses it sustained, but that Insurer could subrogate against Vision for anything it had to pay J&J Fish. In J&J Fish, Vision and J&J Fish signed a lease (Lease) for a building (the Building) located in Milwaukee, Wisconsin. The Lease required Vision to “purchase and keep in full force and effect on the building(s) . . . insurance against fire and such other risks as may be included in all-risks policies . . .” Vision, however, never obtained any insurance on the Building. Pursuant to the Lease, Vision also agreed to “maintain and repair the structure including the slab floor and exterior walls of the Premises.” With respect to J&J Fish, the Lease required J&J Fish to maintain “Physical Damage insurance, including but not limited to fire . . . and all other risks of direct physical loss as insured . . . for the full replacement cost of all additions, improvements (including leasehold improvements) and alterations to the Premises.” J&J Fish purchased a commercial property and casualty insurance policy (the Policy) from Insurer. The Policy covered “additions, improvements . . . and alterations” as the Lease required. In addition, it insured the Building itself against “collapse,” subject to certain exceptions. Read the court decision
Read the full story...
Reprinted courtesy of William L. Doerler, White and Williams LLP
Mr. Doerler may be contacted at doerlerw@whiteandwilliams.com

Traub Lieberman Attorneys Recognized as 2020 Super Lawyers and Rising Stars

November 16, 2020 — Traub Lieberman
Traub Lieberman is pleased to announce that Super Lawyers has named nineteen of our attorneys as 2020 Super Lawyers and Rising Stars. Super Lawyers selects attorneys using a multiphase selection process in which nominations and evaluations are combined with independent research. Each candidate is evaluated on 12 indicators of peer recognition and professional achievement. Selections are made on an annual, state-by-state basis. The objective is to create a credible, comprehensive and diverse listing of outstanding attorneys that can be used as a resource for attorneys and consumers searching for legal counsel. The Super Lawyers designation recognizes the top 5% of attorneys in the U.S. and the Rising Stars designation recognizes the top 2.5% of attorneys in the U.S. under the age of forty, as chosen by their peers and through independent research within their practice area. Read the court decision
Read the full story...
Reprinted courtesy of Traub Lieberman

$109-Million Renovation Begins on LA's Willowbrook/Rosa Parks Station

October 02, 2018 — Greg Aragon - Engineering News-Record
The Los Angeles County Metropolitan Transportation Authority (Metro), along with the Los Angeles office of Stantec, recently began work on the $109-million Willowbrook/Rosa Parks Station Improvement Project in Los Angeles. Read the court decision
Read the full story...
Reprinted courtesy of Greg Aragon, ENR
ENR may be contacted at ENR.com@bnpmedia.com

Florida Courts Inundated by Wave of New Lawsuits as Sweeping Tort Reform Appears Imminent

April 03, 2023 — John A. Rine - Lewis Brisbois
Tampa, Fla. (March 22, 2023) – Plaintiffs’ attorneys throughout Florida are rushing to file lawsuits in anticipation of sweeping tort reform legislation. It has been reported that some plaintiffs’ firms in the Sunshine State have filed hundreds – and in some cases thousands – of new lawsuits this week ahead of the potential enactment of the bill. It has also been reported that this record number of new suits being filed is causing difficulty and failures in some court computer systems. These plaintiffs’ attorneys are panicked by HB 837. This bill will potentially provide the most radical tort reform the state has seen in several decades. The specific revisions to civil litigation are dramatic. For instance, the statute of limitations would be cut in half, from four years to two years. Additionally, insurance carriers would be immune from claims of bad faith if they tender the limits within 90 days of notice of a claim. Carriers will also enjoy numerous new protections from bad faith litigation even where there is no tender in the first 90 days. Read the court decision
Read the full story...
Reprinted courtesy of John A. Rine, Lewis Brisbois
Mr. Rine may be contacted at John.Rine@lewisbrisbois.com

Expired Contract Not Revived Due to Sovereign Immunity and the Ex Contractu Clause

September 15, 2016 — David R. Cook Jr. – AHHC Construction Law Blog
A few months ago, a decision by the Supreme Court of Georgia in Georgia Department of Labor v. RTT Associates, Inc. provided a strict rule for contractors who work with state agencies to determine whether a state agency has waived its sovereign immunity. The issue as framed by the Court was “whether an agency’s waiver of immunity from a breach of contract claim as a result of entering into a written contract remains intact in the event the contract is extended without a written document signed by both parties expressly amending the contract, as required by its terms.” The case involved a contract executed on March 1, 2012, by a contractor, RTT Associates, Inc. (RTT), and the Georgia Department of Labor (DOL), whereby RTT was to develop certain computer software for the DOL by the completion date, June 30, 2012. The contract required that amendments be in writing and fully executed by both parties. Time was of the essence and RTT’s obligation under the contract survived the expiration or termination of the contract. Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook Jr., Autry, Hanrahan, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

Sureties and Bond Producers May Be Liable For a Contractor’s False Claims Act Violations

October 19, 2017 — Michael C. Zisa & Susan Elliott – Peckar & Abramson, P.C.
Two recent decisions from the United States District Court for the District of Columbia and the United States Court of Federal Claims highlight that sureties and bond producers are not immune to the potentially severe consequences of the False Claims Act (“FCA”) and related federal fraud statutes. In each case, the Court determined that sureties and bond producers can face potential liability under these fraud statutes for direct and indirect submission of false claims to the federal government. Reprinted courtesy of Michael C. Zisa, Peckar & Abramson, P.C. and Susan Elliott, Peckar & Abramson, P.C. Mr. Zisa may be contacted at mzicherman@pecklaw.com Ms. Elliott may be contacted at selliott@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

CDJ’s #2 Topic of the Year: Ewing Constr. Co., Inc. v. Amerisure Ins. Co., 2014 Tex. LEXIS 39 (Tex. Jan.17, 2014)

December 31, 2014 — Beverley BevenFlorez-CDJ STAFF
Ewing received quite a bit of attention around the blogosphere, and Tred R. Eyerly of Damon Key Leong Kupchak Hastert wrote a nicely succinct case summary on his blog, Insurance Law Hawaii: “In a much anticipated decision, the Texas Supreme Court ruled that a general contractor who agrees to perform its work in a good and workmanlike manner does not "assume liability" for damages arising out of its defective work so as to trigger the Contractual Liability Exclusion.” Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES