Fairfield Connecticut Building Expert Directory

Graham & Who May Trigger The Need To Protest

December 23, 2023 — Hugo Fraga - Ahlers Cressman & Sleight PLLC
On May 30, 2023, the Washington Court of Appeals, Division I, issued a decision that appears to expand a contractor’s obligation with respect to WSDOT notice and claim procedures. In Graham Contracting, Ltd. v. City of Federal Way, No. 83494-1-I, 2023 WL 3721171 (Wash. Ct. App. May 30, 2023) (Unpublished), the Court held that under the 2016 WSDOT Standard Specifications for Road, Bridge, and Municipal Construction (“Standard Specifications”), a Contractor must protest the actions of not only the “Engineer” but also the actions of any person or organization acting on behalf of the Owner. This case arises out of a public construction contract in which Graham Contracting Ltd (“Graham”) built a multi-million dollar roadway improvement for the City of Federal Way along a stretch of Pacific Highway. The appeal was from the trial court’s granting of the City’s motion for summary judgment to dismiss claims by Graham for extra time and money due to delays and impacts to Graham’s construction of the Project. Read the court decision
Read the full story...
Reprinted courtesy of Hugo Fraga, Ahlers Cressman & Sleight PLLC
Mr. Fraga may be contacted at hugo.fraga@acslawyers.com

Insurance Coverage Litigation Section to Present at Hawaii State Bar Convention

October 15, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The Hawaii State Bar convention will be on October 24, 2014, at the Hawaiian Hilton. The Insurance Coverage Litigation Section will make a presentation from 8:30 a.m. to 11:45 a.m. Three presentations will be made. First, Richard C. Mosher (Anderson Kill), Kathy Dang (Marsh), and Beau Monday (Hawaiian Telcom) will discuss cyber-liability claims and insurance options. Next, David R. Harada-Stone (Tom Petrus & Miller) and I (Damon Key Leong Kupchak Hastert) will address "occurrences," i.e., deciding on and the impact of determining the number of occurrences in particular factual settings. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Massachusetts Judge Holds That Insurer Breached Its Duty To Defend Lawsuit After Chemical Spill

October 16, 2018 — Lawrence J. Bracken, II & Alexander D. Russo - Hunton Insurance Recovery Blog
A District Court Judge for the District of Massachusetts recently ruled that Ace Property and Casualty Insurance Co. breached its duty to defend its insured in a lawsuit brought by Plaistow Project, LLC, after a family owned laundromat leaked chemicals onto Plaistow Project’s property. Plaistow Project, LLC v. ACE Prop. & Cas. Ins. Co., No. 16-CV-11385-IT, 2018 WL 4357480, (D. Mass. Sept. 13, 2018). Plaistow Project sued State Line Laundry Services in state court, and ACE denied coverage under the pollution exclusion in State Line Laundry’s insurance policy. Plaistow Project then settled with State Line Laundry. Under the settlement terms, Plaistow Project was assigned State Line Laundry’s rights against ACE. In the subsequent coverage litigation, Plaistow Project alleged that ACE had breached its duty to defend State Line Laundry under its insurance policy. ACE argued that (1) the burden was on the policyholder to demonstrate that the policy’s “sudden and accidental” exception applied to the policy’s pollution exclusion; and (2) the policyholder could not show the “sudden and accidental” exception applied based on the complaint. Reprinted courtesy of Lawrence J. Bracken, II, Hunton Andrews Kurth and Alexander D. Russo, Hunton Andrews Kurth Mr. Bracken, may be contacted at lbracken@HuntonAK.com Mr. Russo may be contacted at arusso@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Nicholas A. Thede Joins Ball Janik LLP

October 02, 2015 — Beverley BevenFlorez-CDJ STAFF
As of September 1st, Nicholas A. Thede, an insurance recovery litigator, joined Ball Janik LLP’s Insurance Recovery, Construction Defect, and Litigation practices. According to the release, Mr. Thede “has advised clients in a wide variety of insurance disputes, including claims arising under general liability, professional liability, directors and officers, employee dishonesty, homeowners, and automotive insurance policies. Thede has successfully represented clients in trials, arbitrations, and appeals, and has obtained numerous favorable settlements for his clients. He has handled insurance disputes throughout Oregon and Washington, along with several other jurisdictions. Mr. Thede has substantial experience litigating claims for insurance ‘bad faith’ and recovery of attorney fees in a variety of settings.” Ball Janik LLP is headquartered in Portland, Oregon. Read the court decision
Read the full story...
Reprinted courtesy of

New York Appellate Court Expands Policyholders’ Ability to Plead and Seek Consequential Damages

February 27, 2019 — Michael S. Levine & Joshua S. Paster - Hunton Andrews Kurth
In a huge win for policyholders, a New York appellate court, in D.K. Property, Inc. v National Union Fire Insurance Company of Pittsburgh, Pa., held that an insured need not provide a detailed factual description or explanation for why consequential damages are recoverable at the pleading stage. Rather, an insured’s complaint must only (i) specify the types of consequential damages claimed; and (ii) allege that those damages reasonably were contemplated by the parties prior to contracting. Here, D.K. Property’s building was damaged as a result of construction on an adjoining building, and it timely filed a claim with National Union under a policy that covers “direct physical loss or damage to” the building. National Union neither paid the claim nor disclaimed coverage. Instead, according to D.K. Property, National Union made unreasonable and increasingly burdensome information demands over a three-year period, which it alleges was a “tactic” to make pursuing the claim so expensive that D.K. Property would abandon the claim. As a result of the delay, D.K. Property alleges the structural damage to its building has worsened. Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth and Joshua S. Paster, Hunton Andrews Kurth Mr. Levine may be contacted at mlevine@HuntonAK.com Mr. Paster may be contacted at jpaster@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Mexico's Richest Man Carlos Slim to Rebuild Collapsed Subway Line

November 01, 2021 — The Associated Press - Bloomberg
Mexico City (AP) -- Mexico’s richest man reached an agreement with Mexico City authorities Wednesday to rebuild or reinforce an elevated subway line that collapsed in May, killing 26 people. Telecom and construction magnate Carlos Slim said his Grupo Carso’s construction subsidiary would pay the cost of rebuilding the span that collapsed, and reinforcing other parts of the elevated line to meet higher standards in a city plagued with severe earthquakes. Grupo Carso said in a statement to the country’s stock market that the outlay did not constitute any admission of responsibility for the collapse, and would not “materially affect” the company’s business. Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg

How the Election Could Affect the Housing Industry: Steven Cvitanovic Authors Construction Today Article

October 07, 2016 — Steven M. Cvitanovic – Haight Brown & Bonesteel LLP
Though non-policy issues dominating the news cycle have set this presidential election apart, both Hillary Clinton and Donald Trump have recognized the importance of housing and infrastructure investment. In an article for Construction Today, Partner Steven Cvitanovic outlines several challenges facing the real estate development industry, and analyzes how Clinton and Trump might benefit or harm the industry. Read the court decision
Read the full story...
Reprinted courtesy of Steven M. Cvitanovic, Haight Brown & Bonesteel LLP
Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com

Client Alert: Restaurant Owed Duty of Care to Driver Killed by Third-Party on Street Adjacent to Restaurant Parking Lot

January 07, 2015 — R. Bryan Martin, Lawrence S. Zucker II, & Kristian B. Moriarty – Haight, Brown, & Bonesteel, LLP
In Annocki v. Peterson Enterprise, LLC, (Filed 11/14/2014, Certified for Publication 12/5/2014, No. B251434) the Court of Appeal, Second District, held a restaurant owed a duty of care to the driver of a motorcycle who died as a result of the negligent driving of a third party exiting the restaurant’s parking lot. Decedent, Joseph M. Annocki, was driving his motorcycle on Pacific Coast Highway in Malibu, when it collided with the vehicle operated by Terry Allen Turner, who was exiting the parking lot of “Geoffrey’s" restaurant, which was owned and operated by the Defendant, Peterson Enterprise, LLC (“Peterson”). The parents of the decedent (“Plaintiffs”) filed suit against Peterson, alleging Peterson failed to adequately staff the restaurant parking lot, which caused Turner to become confused and make an illegal left turn onto Pacific Coast Highway, thereby causing the accident that killed decedent. Plaintiffs further alleged Peterson knew, or should have known, that its parking lot and driveway were designed and in such condition as to create a danger of decreased visibility of the adjacent highway, and failed to adequately provide signage directing patrons that only right turns could be made onto Pacific Coast Highway. Reprinted courtesy of Haight Brown & Bonesteel LLP attorneys R. Bryan Martin, Lawrence S. Zucker II and Kristian B. Moriarty Mr. Martin may be contacted at bmartin@hbblaw.com Mr. Zucker may be contacted at lzucker@hbblaw.com Mr. Moriarty may be contacted at kmoriarty@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES