Seattle Washington Building Expert Directory

Insurer Incorrectly Relies Upon "Your Work" Exclusion to Deny Coverage

June 10, 2019 — Tred R. Eyerly - Insurance Law Hawaii
The Eleventh Circuit reversed the district court's determination that there was no coverage based upon the policy's "your work" exclusion. Southern-Owners Ins. Co. v. Mac Contractors of Fla, LLC, 2019 U.S. App. LEXIS 10689 (11th Cir. April 11, 2019). Mac Contractors contracted with the homeowners to custom build their home. After construction began, Mac left the site before completing the project and before the issuance of a certificate of occupancy. The homeowners sued, alleged damage to wood floors and the metal roof. Southern-Owners originally agreed to defend under the CGL policy, but later withdrew the defense and filed this action for declaratory relief. The parties cross-filed motions for summary judgment. Southern-Owners argued that the "your work" exclusion applied to bar coverage. The "your work" exclusion barred coverage for "'property damage' to 'your work' arising out of it or any part of it and included in the 'products' completed operations hazard.'" The "products' completed operations hazard" included all "'property damage' occurring away from premises you own or rent and arising out of . . . 'your work' except . . . (1) products that are still in your physical possession; or (2) work that has not yet been completed or abandoned." Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

New Orleans Is Auctioning Off Vacant Lots Online

March 12, 2015 — Patrick Clark – Bloomberg
New Orleans is selling almost 1,800 properties on the Web to fatten its tax coffers and build on the momentum it's enjoying in the local real estate market. The question is, who's going to show up for the online auction, and what are they going to do with the lots they buy? On Friday, the city posted a list of 1,786 properties—90 percent of them vacant lots—that it plans to sell in the auction. Bidding on the properties, of which the city took control after the owners failed to pay property taxes, will start at $3,000 in most cases, plus the cost of trying to track down the most recent owner. Read the court decision
Read the full story...
Reprinted courtesy of Patrick Clark, Bloomberg
Mr. Clark may be contacted at jclark185@bloomberg.net

Differing Site Conditions: What to Expect from the Court When You Encounter the Unexpected

September 05, 2022 — Margarita Kutsin - Ahlers Cressman & Sleight
[1]Seattle Tunnel Partners (“STP”), a joint venture of Dragados USA and Tutor Perini, entered into a $1.4 billion contract with the Washington State Department of Transportation (“WSDOT”) to replace the Highway 99 viaduct. In December 2013, a tunnel boring machine (“TBM”) bearing the moniker “Bertha,” then the largest TBM ever built, measuring 425 feet long and 57 feet in diameter, struck an underground pipe. Shortly after the impact, Bertha overheated and eventually could no longer make forward progress. A massive repair effort ensued causing a 2.5-year delay in reaching substantial completion. WSDOT sued STP for the delay, seeking liquidated damages of $57 million. In response, STP argued its delay was excusable because it was caused by Bertha’s impact with the pipe, and the steel well casing was a Differing Site Condition (DSC) undisclosed in the contract documents. STP asserted counterclaims against WSDOT, alleging breach of contract and seeking $300 million in damages. Ultimately, a jury found that the steel well casing on the pipe was not a DSC, foreclosing STP’s excusable delay defense and counterclaims, and resulting in a $57 million verdict, plus interest, in favor of WSDOT. Read the court decision
Read the full story...
Reprinted courtesy of Margarita Kutsin, Ahlers Cressman & Sleight
Ms. Kutsin may be contacted at margarita.kutsin@acslawyers.com

Florida High-Rise for Sale, Construction Defects Possibly Included

October 30, 2013 — CDJ STAFF
The owners of One Bal Harbour in Bal Harbour, Florida have filed for bankruptcy and are seeking to sell off the luxury condominium and hotel building. There have been problems with the building, including flooding and allegations of structural defects. The original developer went bankrupt and sold before the construction defect lawsuits begain. The building’s opening price of $13 million won’t wipe out Elcom’s $20 million in debt. Read the court decision
Read the full story...
Reprinted courtesy of

Reaffirming the Importance of Appeal Deadlines Under the Contract Disputes Act

January 26, 2017 — Chadd Reynolds – Autry, Hanrahan, Hall & Cook, LLP
A recent United States Court of Federal Claims (“COFC”) decision emphasizes the importance of deadlines for appealing a contracting officer’s (“CO”) decision under the Contract Disputes Act (“CDA”). On July 22, 2016, the COFC granted the consolidation of two naval contract dispute appeals totaling nearly $12.4 million in response to Nova Group/Tutor-Saliba’s (“NTS”) motion to resolve two Requests for Equitable Adjustment (“REA”) in the same forum. See Nova Group/Tutor-Saliba v. United States, No. 15-885C, 2016 WL 4009886, at *5 (Fed. Cl. July 22, 2016). NTS’s motion before the COFC sought to transfer an appeal of a REA before the COFC to the Armed Services Board of Contract Appeals (“ASBCA”), where another appeal of a REA arising under the same contract was presently on appeal. The COFC rejected NTS’s appeal to transfer the REA to the ASBCA because NTS did not appeal the REA within the 90-day limit under the CDA. Instead, the COFC allowed NTS to transfer the REA before the ASBCA to the COFC because timeliness was not an issue. Read the court decision
Read the full story...
Reprinted courtesy of Chadd Reynolds, Autry, Hanrahan, Hall & Cook, LLP
Mr. Reynolds may be contacted at reynolds@ahclaw.com

Exception to Watercraft Exclusion Does Not Apply

September 24, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The court determined that an additional insured was not entitled to coverage despite an exception to the watercraft exclusion. Holden v. U.S. United Ocean Serv., LLC, 2014 U.S. App. LEXIS 15954 (5th Cir. Aug. 19, 2014). United entered a contract with Buck Kreihs Company, Inc. under which Buck Kreihs would perform ship-repair work for United. Under the contract, Buck Kreihs would indemnify United for all liabilities arising out of the work or services performed by Buck Kreihs for United. The contract further provided that Buck Kreihs was to procure general liability coverage and name United as an additional insured. Buck Kreihs did so under a policy issued by St. Paul. Holden, an employee of Buck Kreihs, was injured while preparing to remove a gangway that led from a dock at Buck Kreihs's facility to a barge owned by United. Holden sued United, which tendered to St. Paul as an additional insured. St. Paul denied coverage under the policy's watercraft exclusion. Holden and United settled. United pursued its third party suit against St. Paul. The district court granted summary judgment to St. Paul. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

California Bid Protests: Responsiveness and Materiality

January 06, 2016 — Garret Murai – California Construction Law Blog
It can be a rough and tumble world out there. And in the case of public works construction in California, this includes bid disputes. California’s competitive bidding laws require that a public works contract be awarded to the “lowest responsible bidder.” However, as we’ve mentioned before, there are two requirements which must be satisfied for a bidder to be determined to be the lowest responsible bidder: (1) the awarded bidder’s bid must be “responsive”; and (2) the awarded bidder must be “responsible.” In a case decided this past month, DeSilva Gates Construction v. Department of Transportation, Case No. C074521 (December 14, 2015), the California Court of Appeals for the Third District addressed the first of these two requirements, whether two bids on $34 million highway widening project were responsive, which in turn involves a two-step process: (1) whether the bids were responsive or not; and (2) if not, whether the variance in the bids were “material” or “immaterial.” Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

EEOC Chair Issues New Report “Building for the Future: Advancing Equal Employment Opportunity in the Construction Industry”

June 05, 2023 — The U.S. Equal Employment Opportunity Commission
WASHINGTON – The U.S. Equal Employment Opportunity Commission (EEOC) Chair Charlotte A. Burrows issued a report today titled, “Building For The Future: Advancing Equal Employment Opportunity in the Construction Industry.” The report provides findings and next steps based on the agency’s enforcement experience, witness testimony presented at the EEOC’s May 2022 hearing on discrimination and harassment in construction and other Commission hearings, and academic research. “The recent historic federal infrastructure investments provide a once-in-a-generation opportunity to break down barriers and expand opportunity in the construction industry,” said EEOC Chair Charlotte A. Burrows. “While discrimination has long been an issue in the industry, we can decide the future. I look forward to working with industry leaders, employers, and unions to help ensure safe and inclusive workplaces for all workers.” Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES