Seattle Washington Building Expert Directory

Homeowner Survives Motion to Dismiss Depreciation Claims

September 23, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The insurer's motion to dismiss claims for improper claims handling when considering implementation of depreciation was denied. Morrison v. Indian Harbor Ins. Co, et al., 2024 U.S. Dist. LEXIS 115664 (S. D. W. Va. July 1, 2024). Plaintiff's home suffered flood damage. The house was insured by Indian Harbor a surplus lines carrier that offered specialized and high risk property policies in West Virginia. Surplus lines policies were procured in West Virginia through a "surplus lines licensee." Here, Neptune Flood Inc. was the surplus lines licensee broker for Indian Harbor. Peninsula Insurance Bureau, Inc. was an administrator and loss adjuster involved in the claim. After the flood, Plaintiff notified defendants of the damage and immediately cleaned and repaired the house. Plaintiff asserted that Neptune was given notice of the loss and one of its agents made recommendations regarding the coverage available and conveyed the information to Peninsula and Indian Harbour. Plaintiff claimed that defendants misrepresented his policy coverage and made incorrect adjustments for depreciation based on Neptune's statements and recommendations. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Challenging a Termination for Default

September 23, 2024 — David Adelstein - Florida Construction Legal Updates
No contractor wants to be terminated for default. It is the harshest contractual recourse. It is a recourse that has implications, particularly in the public sector. However, a party needs to be in a position to support the basis of the termination for default, and the terminated party, in most instances, should not be in a position to imply accept the basis of the default. This applies regardless of the project. In the federal context: “When a contractor challenges a default termination, the government bears the burden of establishing the validity of the termination.” Sergent’s Mechanical Systems, Inc. v. U.S., 2024 WL 4048175, *7 (Fed.Cl. 2024) (internal quotation and citation omitted). Once the government establishes the default, “the contractor bears the burden of establishing that the default was excused by fault of the government.” Id. at *8 (internal quotation and citation omitted). Relevant considerations as to whether the contractor is in default include the contractor’s failure to meet contract specifications or the required schedule. Sergent’s Mechanical Systems, supra, at *8. “[T]here is ‘a requirement that the contractor give reasonable assurances of performance in response to a validly issued cure notice.” Id. (internal quotation and citation omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Flood-Threat Assessment Finds Danger Goes Far Beyond U.S. Homes

October 18, 2021 — Leslie Kaufman, Rachael Dottle & Mira Rojanasakul - Bloomberg
If the floods don’t get you, lack of electricity or a swamped hospital might. Nearly a quarter of U.S. critical infrastructure—utilities, airports, police stations and more—is at risk of being inundated by flooding, according to a new report by First Street Foundation, a Brooklyn nonprofit dedicated to making climate risk more visible to the public. Around 25% of national critical infrastructure is at risk. Roughly 14% of Americans’ properties face direct risk from major storms, but the study shows danger extends far from those property lines. Reprinted courtesy of Leslie Kaufman, Bloomberg, Rachael Dottle, Bloomberg and Mira Rojanasakul, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

Condo Building Increasing in Washington D.C.

November 05, 2014 — Beverley BevenFlorez-CDJ STAFF
Builder reported that in Washington D.C., "the condo pipeline has increased for the first time since 2005, according to Alexandria, Va.,-based research firm Delta Associates." Supply has grown with "3,100 units either being marketed or sold in around the nation's capital." Furthermore, "condo prices have jumped 12 percent year over year." “The size of the projects are smaller than they were in the last boom cycle,” William Rich, senior vice president and multifamily practice director at Delta, told Builder. Read the court decision
Read the full story...
Reprinted courtesy of

More Regulations for Federal Contractors

October 08, 2014 — Craig Martin – Construction Contractor Advisor
The Office of Federal Contract Compliance Programs (OFCCP) has been busy. In the last several weeks, the OFCCP has proposed regulations that will require contractors and subcontractors to provide summary compensation data and another rule prohibiting federal contractors and subcontractors from discriminating against employees or applicants who inquire about, discuss, or disclose their own compensation or the compensation of another employee or applicant. Equal Pay Report The OFCCP has proposed Summary Compensation regulations which would require federal contractors and subcontractors with more than 100 employees to “provide summary data on the compensation paid to employees by sex, race, ethnicity, specified job categories, and other relevant data points.” Covered employers would have to submit three types of information: 1. the total number of workers within a specific EEO-1 job category by race, ethnicity and sex; Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson Dugan and Murray, LLP
Mr. Gopal may be contacted at pgopal2@bloomberg.net

No Coverage Where Cracks in Basement Walls Do Not Amount to Sudden Collapse

January 10, 2018 — Tred Eyerly - Insurance Law Hawaii

In another of a series of collapse cases arising out of Connecticut, the federal district court found there was no coverage for the homeowner's cracked basement wall caused by defective concrete. Liston-Smith v. CSAA Fire & Cas. Ins. Co., 2017 U.S. Dist. LEXIS 206211 (D. Conn. Dec. 15, 2017).

Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly, Insurance Law Hawaii
Tred Eyerly may be contacted at te@hawaiilawyer.com

Toolbox Talk Series Recap - The New Science of Jury Trial Advocacy

December 31, 2024 — Douglas J. Mackin - The Dispute Resolver
In the November 21, 2024 edition of Division 1's Toolbox Talk Series, John Jerry Glas discussed how construction lawyers should adjust their trial strategies in response to shifts in juror attitudes. Glas believes that jurors have changed in the last twenty years, with modern jurors being more reluctant than ever to be seen as a lawyer’s puppet. Instead, they simply want a lawyer to help them organize and wade through evidence without spinning it and without spoon-feeding it. Essentially, Glas believes that lawyers achieve better jury trial results if they acknowledge the paradigm shift in jury psychology and reinvent themselves in response by influencing jury deliberations without directly telling a jury what to do. Glas refers to this as the “Waiter Pivot” and recently published a book on the topic. Throughout his presentation, Glas discussed how construction lawyers can embrace the Waiter Pivot throughout a jury trial:

Voir Dire: Lawyers make their first impressions on a jury during voir dire. As such, lawyers should avoid questions that make jurors feel judged or stereotyped. Instead, give the jurors credit and make use of the opportunity to begin framing their case. For example, Glas once repeated the word “specifications” or “specs” in every question during voir dire where his product liability case turned on whether or not the product deviated from specifications.

Read the court decision
Read the full story...
Reprinted courtesy of Douglas J. Mackin, Cozen O’Connor
Mr. Mackin may be contacted at dmackin@cozen.com

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES