SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Equal Access to Justice Act Fee Request Rejected in Flood Case

January 06, 2020 — Tred R. Eyerly - Insurance Law Hawaii
The insured's claim for fees under the Equal Access to Justice Act (EAJA) for seeking coverage under a flood policy was rejected. Hampson v. Wright Nat'l Flood Ins. Co., No. 4:19-cv-10083-KMM (S.D. Fla. Aug. 11, 2019)(Order on Motion to Dismiss). The order is here. The insurer did not compensate plaintiff for flood-related damages under the terms of a Standard Flood Insurance Policy (SFIP). The insurer was a Write-Your-Own (WYO) Program insurance carrier participating in the National Flood Insurance Program (NFIP). By statute, a WYO carrier acts as a "fiscal agent" and "fiduciary" of the United States. The insured's property suffered damage from a hurricane. The insured sued the carrier for breach of contract and attorney's fees under EAJA. The insurer moved to dismiss the claim for fees under EAJA. A party could recover fees and costs under the EAJA as the prevailing party in a case "brought by or against the United States . . . unless the court finds the position of the United States was substantially justified." 28 U.S.C. 2412 (d) (1) (A), (b). The statute defined the "United States" to include "any agency and any official of the United States acting in his or her official capacity." However, attorney's fees were not recoverable under the EAJA in cases for breach of an SFIP brought against a WYO program insurance carrier participating in the NFIP because WYO carriers were not considered "agencies" under the EAJA. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Super Lawyers Selects Haight Lawyers for Its 2023 California Rising Stars List

June 12, 2023 — Haight Brown & Bonesteel LLP
Congratulations to Patrick McIntyre, Kathleen Moriarty and Kristian Moriarty who have been selected to the 2023 California Rising Stars list. Each year, no more than 2.5 percent of the lawyers in the state are selected by the research team at Super Lawyers to receive this honor. Super Lawyers, part of Thomson Reuters, is a rating service of outstanding lawyers from more than 70 practice areas who have attained a high degree of peer recognition and professional achievement. The annual selections are made using a patented multiphase process that includes a statewide survey of lawyers, an independent research evaluation of candidates and peer reviews by practice area. The result is a credible, comprehensive and diverse listing of exceptional attorneys. The Super Lawyers lists are published nationwide in Super Lawyers magazines and in leading city and regional magazines and newspapers across the country. Super Lawyers magazines also feature editorial profiles of attorneys who embody excellence in the practice of law. Read the court decision
Read the full story...
Reprinted courtesy of Haight Brown & Bonesteel LLP

---

California Supreme Court Holds that Prevailing Wages are Not Required for Mobilization Work, for Now

October 18, 2021 — Garret Murai - California Construction Law Blog
In the midst of the Great Depression the federal government enacted the Davis-Bacon Act (40 U.S.C. section 32141 et seq.) to help workers on federal construction projects. Under the Davis-Bacon Act, minimum wages must be paid to workers on federal public works projects based on local “prevailing” wages. At the time, the goal of the law was to help curb the displacement of families by employers who were recruiting lower-wage workers from outside local areas. A darker history suggests that it was also intended to discourage minority workers from competing with unionized white workers. Fast forward to today. Many states, including California, adopted “Little Davis-Bacon” laws applying similar requirements on state and local public works projects. California’s prevailing wage law (Labor Code section 1720 et seq.) requires contractors on state and local public works projects pay their workers the general prevailing rate of per diem wages based on the classification or type of work performed by the employee in the locality where the project is located. Over the years, labor unions have sought to expand the definition of what constitutes a “public works project” from private residential developments receiving public funding (generally, prevailing wages required) to off-site fabrication of materials at permanent facility for a public works project (no prevailing wages required) to enforcement mechanisms such as making a general contractor liable for prevailing wage violations of its subcontractors (yes, indeedy, see Labor Code section 1775). Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---

RCW 82.32.655 Tax Avoidance Statute/Speculative Building

August 29, 2018 — Scott R. Sleight - Ahlers Cressman & Sleight PLLC Blog
With land prices increasing, developers are looking for opportunities to save on development costs, including cost saving tax strategies. Thus, we have seen increasing interest in development strategies that offer tax savings. One strategy is speculative building: Owners of property who self-perform construction avoid sales tax and B&O tax on the self-performed scope. See Blog Article Posted April 9, 2013, titled What Is A Speculative Builder? In addition, the Department of Revenue has provided an explanation of speculative building. Read the court decision
Read the full story...
Reprinted courtesy of Scott R. Sleight, Ahlers Cressman & Sleight PLLC
Mr. Sleight may be contacted at scott.sleight@acslawyers.com

---

Substitutions On a Construction Project — A Specification Writer Responds

July 03, 2022 — Melissa Dewey Brumback - Construction Law in North Carolina
In response to the post about Substitute Materials on a construction project, Phil Kabza explains how his company, SpecGuy, handles tracking of all such materials on a project. Phil writes: Excellent and important topic, about which there is much confusion among design professionals and contractors. We try to maintain definitions for:

• Pre-bid requests for prior approval of proposed comparable products where products are named in the specifications
• True pre-bid substitution requests that present an alternate type of product from that specified (ie., not “comparable” but perhaps suitable)
Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Ragsdale Liggett
Ms. Brumback may be contacted at mbrumback@rl-law.com

---

Federal Government Partial Shutdown – Picking Up the Pieces

February 27, 2019 — Jacob W. Scott -
Now that the partial shutdown has ended (though with the specter of another just around the corner), contractors are asking, “What now?” and “What did that cost me?” Although every case is fact-specific, following are some guidelines for moving forward after the shutdown. Following up on our previous guidance, contractors should make sure that any court, board, or agency filings made during the shutdown were received and properly docketed. If there is any question whether a filing was received, file it again as soon as possible with proof of the earlier attempt to file. The busiest tribunals, such as the federal courts, the Court of Federal Claims, the Boards of Contract Appeals, and the Government Accountability Office, remained open, or at least open to accept filings, and all indications are that filings made during the shutdown were received and acknowledged. But for some of the other tribunals or agencies, such as the Small Business Administration (“SBA”) Office of Hearings and Appeals and the SBA Office of Government Contracting and Business Development, prudence dictates double-checking that all filings were received. In many cases, non-statutory deadlines have been or will be adjusted by the court, board, or agency. Read the court decision
Read the full story...
Reprinted courtesy of Jacob W. Scott, Smith Currie
Mr. Scott may be contacted at jwscott@smithcurrie.com

---

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

“Incidental” Versus “Direct” Third Party Beneficiaries Under Insurance Policies in Which a Party is Not an Additional Insured

April 18, 2023 — Garret Murai - California Construction Law Blog
As they say, when it rains, it pours. Indemnity and insurance are the “Big Two” when it comes to risk avoidance on construction projects. The next case, LaBarbera v. Security National Security Company, 86 Cal.App.5th 1329 (2022), involves both. It’s an interesting case, which I think could have gone either way, involving claims by a higher-tiered party that they were a third party beneficiary under an insurance policy in which they were not named as an additional insured. The LaBarbera Case The Indemnity Provision and Insurance Policy In June 1016, Chris LaBarbera hired Richard Knight doing business as Knight Construction to remodel his house in Carmichael, California. The construction contract included an indemnity provision which provided that Knight would defend and indemnify LaBarbera from all claims arising out the remodeling work except for claims arising from LaBarbera’s sole negligence and willful misconduct. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---