FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Formal Request for Time Extension Not Always Required to Support Constructive Acceleration

April 25, 2022 — David Adelstein - Florida Construction Legal Updates
Does a constructive acceleration claim require the contractor to always request an extension of time which is then denied by the owner? While this is certainly the preference and the contractor should be requesting an extension of time as a matter of course for an excusable delay, the answer is NO! in certain circumstances. This is conveyed in the factually detailed case discussed below where a formal request for an extension of time was not required for the contractor to support its constructive acceleration claim. But first, what is constructive acceleration: Constructive acceleration “occurs when the government demands compliance with an original contract deadline, despite excusable delay by the contractor.” The Federal Circuit in Fraser defined the elements of constructive acceleration as follows: (1) that the contractor encountered a delay that is excusable under the contract; (2) that the contractor made a timely and sufficient request for an extension of the contract schedule; (3) that the government denied the contractor’s request for an extension or failed to act on it within a reasonable time; (4) that the government insisted on completion of the contract within a period shorter than the period to which the contractor would be entitled by taking into account the period of excusable delay, after which the contractor notified the government that it regarded the alleged order to accelerate as a constructive change in the contract; and (5) that the contractor was required to expend extra resources to compensate for the lost time and remain on schedule. Nova Group/Tutor-Saliba v. U.S., 2022 WL 815826, *42 (Fed.Cl. 2022) quoting Fraser Constr. Co. v. U.S., 384 F.3d 1354, 1361 (Fed. Cir. 2004) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Building Supplier Sued for Late and Defective Building Materials

December 04, 2013 — CDJ STAFF
The Lawson Henry Co. bought an unfinished townhome in Snowshoe, West Virginia with the intent of getting it finished and sold. To reach that goal, they contracted with O.C. Cluss Professional Services and O.C. Cluss Lumber Co. to provide them with building materials. According to the plaintiff, Cluss failed to deliver the building materials by the agreed-on date, causing the plaintiff to miss out on the peak season for selling the townhome. The suit also alleges that in addition to materials being delivered late, some were defective or of poor quality. The Lawson Henry Co. is charging Charles C. Cluss and his companies of breach of contract. Read the court decision
Read the full story...
Reprinted courtesy of

---

Agree to Use your “Professional Best"? You may Lose Insurance Coverage! (Law Note)

March 01, 2017 — Melissa Dewey Brumback - Construction Law in North Carolina
Yesterday, I was part of a panel at the NC Bar Association Construction Law Winter Meeting, discussing insurance issues for design professionals. One topic we touched on was how to avoid invalidating your insurance. As most of you know, Errors & Omissions insurance (“E&O” coverage) is meant to provide coverage for mistakes you may make in performing your professional architecture or engineering services. E&O coverage is important to protect you in the event of a lawsuit because, as you know, no set of plans is perfect (nor is perfection the standard of care). Be careful, though. Do not promise to provide a higher standard of care than the “professional standard“. If you are asked to sign a contract that states you will use your “professional best,” “best efforts”, “highest care” or similar, you are being asked to sign something that could cost you your E&O coverage. Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Ragsdale Liggett PLLC
Ms. Brumback may be contacted at mbrumback@rl-law.com

---

Not Our Territory: 11th Circuit Dismisses Hurricane Damage Appraisal Order for Lack of Jurisdiction

July 24, 2023 — Veronica P. Adams & Koorosh Talieh - Hunton Insurance Recovery Blog
The hurdles policyholders have faced with the appraisal process in Florida are far from over. In the past, many Florida courts have limited the scope for appraisal, strictly construing the policy provision against the policyholder. Yet, recently, in Positano Place at Naples I Condominium Association, Inc., et al. v. Empire Indemnity Insurance Company, the Eleventh Circuit dismissed an insurer’s appeal of the district court’s ruling compelling appraisal and a stay of a pending litigation. In Positano Place at Naples I Condominium Association, Inc., et al. v. Empire Indemnity Insurance Company, the policyholder Positano filed a claim for property insurance benefits under the policy as a result of damage to the property from Hurricane Irma in 2017. After investigating the claim, Empire found that there was damage to only three of the five properties covered under the policy and disputed the amount of loss. Reprinted courtesy of Veronica P. Adams, Hunton Andrews Kurth and Koorosh Talieh, Hunton Andrews Kurth Ms. Adams may be contacted at vadams@HuntonAK.com Mr. Talieh may be contacted at ktalieh@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Flint Water Crisis and America’s Clean Water Access Failings

June 28, 2021 — Pam Radtke Russell - Engineering News-Record
Growing up on a Navajo reservation in Arizona, Jay Yazzie, now a senior environmental engineer at Brown and Caldwell, did not have running water in his home. To get its water supply, the family would take a 55-gallon drum to a livestock well or to a distribution point to obtain potable water for everyday use. He was 10 when his family was finally hooked up to a reliable supply. Reprinted courtesy of Pam Radtke Russell, Engineering News-Record Ms. Russell may be contacted at Russellp@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

Florida Court Puts the Claim of Landlord’s Insurer In The No-Fly Zone

March 06, 2023 — William L. Doerler - The Subrogation Strategist
In United States Aviation Underwriters v. Turnberry Airport Holdings, LLC, No. 3D22-270, 2023 Fla. App. LEXIS 1207 (U.S. Aviation), the Court of Appeal of Florida, Third District (Appellate Court) considered whether the insurer for a commercial landlord could pursue subrogation against the landlord’s tenant. Based on the terms of the lease between the landlord and the tenant, the Appellate Court held that the landlord’s insurer could not pursue subrogation. In U.S. Aviation, the defendant, Turnberry Airport Holdings, LLC (Turnberry Airport) leased space to an insured aircraft owner. The lease contained the following provision: TENANT agrees that all policies of insurance obtained by it in connection with the Space or as required hereunder shall contain appropriate waiver of subrogation clauses. Read the court decision
Read the full story...
Reprinted courtesy of William L. Doerler, White and Williams LLP
Mr. Doerler may be contacted at doerlerw@whiteandwilliams.com

---

You Don’t Have To Be a Consumer to Assert a FDUTPA Claim

February 22, 2018 — David Adelstein – Florida Construction Legal Updates
A few years ago, the Fourth District Court of Florida rendered an opinion in Caribbean Cruise Line, Inc. v. Better Business Bureau of Palm Beach County, Inc., 169 So.3d 164 (Fla. 4th DCA 2015) regarding Florida’s Deceptive and Unfair Trade Practices Act (referred as to “FDUTPA”) (Florida Statute s. 501.201et seq.). This case held that a party can assert a FDUTPA claim even though the party is NOT a consumer. The party still has to prove there was an injury to consumers in filing such claim, but again, the party can bring the claim even though it is NOT a consumer. Caribbean Cruise Line, 169 So.3d at 169 (“[W]hile the claimant would have to prove that there was an injury or detriment to consumers in order to satisfy all of the elements of a FDUTPA claim, the claimant does not have to be a consumer to bring the claim.”).See also Cemex Construction Materials Florida, LLC v. Armstrong World Industries, Inc., 2018 WL 905752, *15 (M.D.Fla 2018) (relying on Caribbean Cruise Line to find that even though the plaintiff does not need to be a consumer, the plaintiff still must prove an injury to consumers to satisfy elements of a FDUTPA claim). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

---

Allegations Versus “True Facts”: Which Govern the Duty to Defend? Bonus! A Georgia Court Clears Up What the Meaning of “Is” Is

December 11, 2023 — Rachel E. Hudgins & Syed S. Ahmad - Hunton Insurance Recovery Blog
Courts scrutinize a complaint’s factual allegations to decide whether the allegations trigger a duty to defend. [1] If the facts unambiguously exclude coverage, there is no duty to defend. [2] But what if the factual allegations fall within a policy exclusion, but the allegations are untrue or questionable? What if the true facts would mean the exclusion doesn’t apply? In that case, many courts have found that the insurer should base its decision on the policyholder’s version of the “true facts.” [3] An insurer can’t rely on the complaint’s allegations to deny coverage when the facts that the insurer knows or can ascertain show that the claim is covered. [4] A recent case, United Minerals & Properties Inc. v. Phoenix Insurance Co., No. 4:23-cv-00050 (N.D. Ga.), illustrates these policy interpretation principles. Reprinted courtesy of Rachel E. Hudgins, Hunton Andrews Kurth and Syed S. Ahmad, Hunton Andrews Kurth Ms. Hudgins may be contacted at rhudgins@HuntonAK.com Mr. Ahmad may be contacted at sahmad@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

---