Seattle Washington Building Expert Directory

Spotting Problem Projects

October 26, 2017 — David R. Cook Jr. - Autry, Hanrahan, Hall & Cook, LLP
Perhaps more than any other specialty contractor, electrical contractors bear the brunt of the “problem project.” Long after most other trades have completed their work and scattered in the wind, electrical contractors remain on site until the owner’s last inspection. And when the project is a “problem project,” the owner or prime contractor tend to liberally share their losses and liquidated damages among those specialty contractors remaining on site at the end. So what is an electrical contractor to do when the project starts coming off the rails? What is a Problem Project? First, it helps to identify the attributes of a problem project. While there are many negative qualities of a bad job, a problem project is one that busts budgets – whether labor, material, or time. Most commonly, the problem project will significantly exceed the labor budget. Because an electrical contractor’s most important (and understandably expensive) resource is its people, the labor budget is critical to the success of a job. When a project suffers delays or is ineptly managed, the labor costs soar, turning a potentially profitable job into a disaster. Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook, Autry, Hanrahan, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

Eleventh Circuit Finds No “Property Damage” Where Defective Component Failed to Cause Damage to Other Non-Defective Components

October 11, 2021 — Anthony L. Miscioscia & Margo Meta - White and Williams
In Florida, damage caused by faulty workmanship constitutes “property damage;” however, the cost of repairing or removing defective work does not. Amerisure Mutual Insurance Company v. Auchter Company, 673 F.3d 1294 (11th Cir. 2012) (Auchter). But what happens when the cost of repairing or removing defective work results in loss of use of the tangible property which is not physically injured? The United States Court of Appeals for the Eleventh Circuit was recently faced with this question in Tricon Development of Brevard, Inc. v. Nautilus Insurance Company, No. 21-11199, 2021 U.S. App. LEXIS 27317 (11th Cir. Sep. 10, 2021). Tricon arose out of the construction of a condominium. Tricon was hired to serve as general contractor for the project and hired a subcontractor to fabricate and install metal railings. The railings installed by the subcontractor were defective and damaged, improperly installed, and failed to meet the project’s specifications. Tricon filed an insurance claim with Nautilus Insurance Company, the subcontractor’s commercial general liability insurer, for the cost to remove and replace the railings.[1] Reprinted courtesy of Anthony L. Miscioscia, White and Williams and Margo Meta, White and Williams Mr. Miscioscia may be contacted at misciosciaa@whiteandwilliams.com Ms. Meta may be contacted at metam@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Faulty Workmanship Claims Amount to Multiple Occurrences

August 03, 2022 — Tred R. Eyerly - Insurance Law Hawaii
In a recommended decision, the magistrate found that claims of faulty workmanship against the insured constituted multiple occurrences. Millsap Waterproofing, Inc. v. United States Fire Ins. Co., 2022 U.S. Dist. LEXIS 90112 (S.D. Tex. May 19, 2022). Maravilla Condominiums in Galveston, Texas was damaged by Hurricane Ike in 2008. While repairing the damage caused by the hurricane, an unrelated fire broke out and damaged 77 units. In 2010, the Maravilla Owners Association, Inc. hired several contractors, including Millsap Waterproofing, Inc. Multiple problems arose with the various contractors' work. In 2016, Maravilla sued the contractors alleging that their shoddy work damaged the condominium complex. More than 80 condominium owners intervened, alleging that Millsap negligently performed work on windows, doorways, walkways, and balconies, resulting in extensive water damage. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Home Prices in 20 U.S. Cities Rose at Faster Pace in January

April 01, 2015 — Nina Glinski – Bloomberg
(Bloomberg) -- Home prices in 20 U.S. cities appreciated at a faster pace in the year ended in January, indicating the residential real-estate market continues to firm. The S&P/Case-Shiller index of property values increased 4.6 percent from January 2014, the biggest gain since September, after rising 4.4 percent the prior month, a report from the group showed Tuesday in New York. That matched the median projection of 28 economists surveyed by Bloomberg. On a national scale, prices rose 4.5 percent from January 2014. A dearth of supply will continue to drive up home prices heading into the busy spring selling season as demand is spurred by rising rents. Builders like KB Home expect to post strong revenue in the warmer months ahead, based on early signs of strength, particularly among first-time buyers. Read the court decision
Read the full story...
Reprinted courtesy of Nina Glinski, Bloomberg
Ms. Glinski may be contacted at nglinski@bloomberg.net

Housing Markets Continue to Improve

February 11, 2013 — CDJ STAFF
The National Association of Home Builders reports that for a sixth consecutive month there has been an increase in the number of housing markets that have shown improvement. The January report saw 242 improving markets, which in February grew to 259. The NAHB notes that there are now improving markets in every state, “suggesting that the housing recovery has substantial momentum.” Not all markets showed continued improvement. Three metropolitan areas were dropped from the list of improving markets, but another twenty were added. The NAHB has been tracking this data since September 2011, when there were only twelve improving markets through the whole country. Read the court decision
Read the full story...
Reprinted courtesy of

Eye on Housing Examines Costs of Green Features

July 09, 2014 — Beverley BevenFlorez-CDJ STAFF
The National Association of Home Builders’ Eye on Housing reported that it costs more to build a green home, however, builder’s experience with green techniques reduces costs. According to McGraw Hill Construction survey data (as quoted by Eye on Housing), “the incremental cost for builders to construct green homes was 8% in 2013. For remodelers, green projects raised costs by 9% on average.” Furthermore, “McGraw Hill’s analysis found that the cost to build green varied to some degree by the amount of green construction undertaken.” Read the court decision
Read the full story...
Reprinted courtesy of

A Retrospective As-Built Schedule Analysis Can Be Used to Support Delay

May 23, 2022 — David Adelstein - Florida Construction Legal Updates
Delay claims are part of construction. There should be no surprise why. Time is money. A delay claim should be accompanied by expert opinions that bolster evidence that gets introduced. The party against whom the delay claim is made will also have an expert – a rebuttal expert. Not surprisingly, each of the experts will rely on a different critical path as to relates to the same project. The party claiming delay will rely on a critical path that shows the actions of the other party impacted their critical path and proximately caused the delay. This will be refuted by the opposing expert that will challenge the critical path and the actions claimed had no impact on the critical path (i.e., did not proximately cause the delay). Quintessential finger pointing! This was the situation in CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022), where the government terminated the contractor for convenience and the contractor claimed equitable adjustments for, among other things, delay. The contractor’s expert relied on an as-built critical path analysis by “retrospectively creating updates to insert between the contemporaneous updates.” Id., supra, n.3. The government’s expert did not do a retrospective as-built analysis and relied on only contemporaneous schedule updates. Id. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Southern California Lost $8 Billion in Construction Wages

August 17, 2011 — CDJ STAFF

Los Angeles and Orange Counties are first on a list no area wants to be on. According to the Sacramento Bee, reporting on data from the U.S. Bureau of Economic Analysis, LA and Orange Counties saw an $8 billion drop in construction wages in 2010, as compared to 2006. In 2006, the region saw payrolls of $26.8 billion, but in 2010, that was reduced to $18.5 billion.

This was not the largest percentage change. Of the metropolitan areas with the largest declines in construction earnings, Las Vegas saw a $3.6 billion drop, however that represented half of their 2006 totals of $7.2 billion. Conversely, a $3.3 billion drop in the New York area represented only 10% of what had been $33.8 billion in payroll in 2006.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES