Seattle Washington Building Expert Directory

Proving Impacts to Critical Path to Defeat Liquidated Damages Assessment

December 16, 2019 — David Adelstein - Florida Construction Legal Updates
When a contractor is staring down the barrel of an owner’s assessment of liquidated damages, the burden will fall on the contractor to establish that the delay was attributable to the owner and the owner’s agents. The contractor will want to do this not only to defeat the assessment of liquidated damages, but because it will want to establish that the delay caused it to incur extended field overhead (general conditions) for which the owner is responsible. A contractor supports its burden by proving the impacts to its critical path. “In general, proving an allegation of government-caused delays without a means of showing the critical path is a steep prospect.” James Talcott Construction v. U.S., 2019 WL 1040383, *8 (Fed. Cl. 2019) (unreported opinion) (finding that because contractor did NOT present a critical path analysis it could not support its claim for delay caused by the government). Avoiding the assessment of liquidated damages means the contractor needs to support that it encountered excusable delay and it is/was entitled to an extension of time to complete the project. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

ADA Lawsuits Spur Renovation Work in Fresno Area

November 06, 2013 — CDJ STAFF
The El Gallo restaurant in Clovis, California has completed more than $45,000 worth of accessibility upgrades, ranging from installing signs for handicap parking to an $8,000 wheelchair-accessible ramp. The restaurant closed in 2010 when they were sued over alleged Americans with Disabilities Act (ADA) violations. But the El Gallo was only the first Fresno-area business hit with an accessibility lawsuit. And others wanted to avoid getting sued at all. Donald Bremseth, an architect working in Clovis, said that designing modifications to older buildings to bring them into compliance with the ADA has kept him busy, designing dozens of projects in the area. Daniel Zoldak, vice president of Lars Anderson & Associates, noted at on one inspection, he saw about 50 ADA violations, and with the fines at least $2,000 per violation, $10,000 or $20,000 of renovations doesn’t look so bad. That’s under the new law, which also allows a business 30 days to get into compliance. Under the old law, the minimum fine was $4,000. Read the court decision
Read the full story...
Reprinted courtesy of

Federal Judge Issues Preliminary Injunction Blocking State's Enforcement of New Law Banning Mandatory Employee Arbitration Agreements

February 24, 2020 — Amy R. Patton, Jeffrey K. Brown & Tyler B. Runge - Payne & Fears
On January 31, 2020, Judge Kimberly Mueller issued a preliminary injunction "in full" preventing the State of California from enforcing AB 51, the state's new law effectively banning mandatory employee arbitration agreements. As we previously reported, AB 51 adds section 432.6 to the Labor Code and section 12953 to the Government Code, which together prohibit employers from requiring an employee, as a condition of employment, continued employment, or receipt of employment-related benefits, to waive any right, forum, or procedure to pursue a claim under the California Fair Employment and Housing Act or the Labor Code. In other words, AB 51 bans mandatory employment arbitration agreements for employment-related claims. In early December 2019, the U.S. Chamber of Commerce and a coalition of business organizations sued the state of California in federal court in a bid to have AB 51 declared preempted --- and therefore unenforceable --- by the Federal Arbitration Act. The case is Chamber of Commerce of the United States v. Becerra, Case No. 2:19-cv-2456 KJM DB (E.D. Cal.). On December 30, 2019, Judge Mueller issued a temporary restraining order preventing the state from enforcing AB 51 pending the resolution of plaintiffs' motion for a preliminary injunction. You can read our report here. Reprinted courtesy of Payne & Fears attorneys Amy R. Patton, Jeffrey K. Brown and Tyler B. Runge Ms. Patton may be contacted at arp@paynefears.com Mr. Brown may be contacted at kb@paynefears.com Mr. Runge may be contacted at tbr@paynefears.com Read the court decision
Read the full story...
Reprinted courtesy of

Contractor Jailed for Home Repair Fraud

November 27, 2013 — CDJ STAFF
An Illinois man has received his third prison sentence for construction fraud, this time for five and a half years. Perry Porter was arrested in October and plead guilty to aggravated home repair fraud. Mr. Porter had charged a homeowner $1,000 per hour for a home repair that should have cost a total of $500. Mr. Porter has also been ordered to pay $6,700 in restitution to the victim. Read the court decision
Read the full story...
Reprinted courtesy of

Additional Insured Not Entitled to Coverage for Post-Completion Defects

December 21, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The general contractor, an additional insured on the subcontractor's policy, was not entitled to coverage for construction defect claims that arose after completion of the project. Weitz Co. v. Acuity, 2016 U.S. Dist. LEXIS 150433 (S.D. Ohio Oct. 31, 2016). Weitz was the general contractor hired by Twin Lakes for construction of a residential community. One of the subcontractors, Miter Masonry, was insured by Acuity under a CGL policy. Work on the project began in 2002 and was substantially completed in 2005. In 2011, Twin Lakes notified Weitz that there were moisture infiltration issues at the project that may be related to work during the project. Twin Lakes filed a Demand for Arbitration against Weitz on November 30, 2012. Twin Lakes alleged that the defects included the building wrap, windows, doors, wood trim, aluminum wrap, vinyl siding, flashing and brick veneer not being installed in accordance with contract documents and/or industry standards. The arbitration panel awarded damages to Twin Lakes in the amount of $2,775,771.86. The panel found that Weitz breached sections of the contract which caused moisture intrusion and damage to all the units. The panel ultimately held that Weitz could recover from the subcontractors 100% of the $2,775,771.86 awarded. Acuity's insured, Miter Masonry, was determined to be 4% at fault for the damages. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

New-Home Sales in U.S. Unexpectedly Fall to Four-Month Low

January 07, 2015 — Victoria Stilwell – Bloomberg
Purchases of new U.S. homes unexpectedly declined in November to a four-month low, underscoring a lack of momentum this year in residential real estate. Sales dropped 1.6 percent to a 438,000 annualized pace last month following a 445,000 rate in October that was weaker than previously estimated, Commerce Department figures showed today in Washington. The median estimate of 73 economists surveyed by Bloomberg called for a 460,000 pace in November. Read the court decision
Read the full story...
Reprinted courtesy of Victoria Stilwell, Bloomberg
Ms. Stilwell may be contacted at vstilwell1@bloomberg.net

Illinois Court Determines Insurer Must Defend Negligent Misrepresentation Claim

December 09, 2011 — Tred R. Eyerly - Insurance Law Hawaii

Although the insureds disclosed flooding problems in the basement, the buyers purchased their home. USAA Cas. Ins. Co. v. McInerney, 2011 Ill. App. LEXIS 1130 (Ill Ct. App. Oct. 31, 2011). In a supplemental disclosure, the insureds reported that during heavy rains light seepage occurred in the basement.

After moving in, the buyers experienced significant water infiltration and flooding in the basement. The buyers and their children also began to experience mold-related illnesses.

The buyers sued for rescission of the contract or, in the alternative, damages. They alleged breach of contract, fraudulent misrepresentation and negligent misrepresentation. In the claim for negligent misrepresentation, the buyers alleged that the insureds carelessly omitted the fact that there were material defects in the basement and foundation when they should have known of such defects.

Read the full story…

Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

Candis Jones Named to Atlanta Magazine’s 2022 “Atlanta 500” List

February 14, 2022 — Candis Jones - Lewis Brisbois Newsroom
Atlanta, Ga. (February 11, 2022) - Atlanta Partner Candis R. Jones has been named to Atlanta Magazine’s 2022 “Atlanta 500” list of the most powerful business leaders in Atlanta. This is the second year in a row she has received this recognition. To compile this list, the publication reviewed nominations from the public and consulted experts across various sectors. The magazine’s editors and writers considered not only the status of the nominees within their respective organizations, but also whether the nominees were visionary by, for example, leading programs for their communities or creating opportunities for employees. Read the court decision
Read the full story...
Reprinted courtesy of Candis Jones, Lewis Brisbois
Ms. Jones may be contacted at Candis.Jones@lewisbrisbois.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES