Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?
January 27, 2020 —
Ted R. Gropman & Christine Z. Fan - ConsensusDocsConstruction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date.
Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved.
There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973).
Reprinted courtesy of
Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP
Mr. Gropman may be contacted at gropmant@pepperlaw.com
Read the court decisionRead the full story...Reprinted courtesy of
So, You Have a Judgment Against a California Contractor or Subcontractor. What Next? How Can I Enforce Payment?
May 04, 2020 —
William L. Porter - Porter Law GroupThe Contractors’ State License Board (“CSLB”) represents the interests of the public in California construction matters. In the field of California construction, the CSLB is all powerful. The agency has the right to suspend the license of any contractor or subcontractor who does not pay on a construction related judgment against it. If you are successful in obtaining a court judgment against a contractor or a subcontractor in a construction-related case, you can utilize the services of the CSLB to suspend the contractors’ license of that contractor or subcontractor until the judgment has been paid. Once the license is suspended, the contractor or subcontractor has no legal right to work as a contractor or subcontractor and can even be arrested for doing so. Details on using the CSLB to suspend the license of a contractor or subcontractor who has a construction-related judgment against it can be accessed at this particular CSLB link:
CSLB – Judgment.
On receipt of notice of the construction-related judgment, the CSLB will either suspend the contractors’ license of any contractor or subcontractor who does not pay on the judgment or who does not appeal the judgment to the Court of Appeals or file bankruptcy within 90 days. There also exists an opportunity for the licensed debtor to file a bond with the CSLB. The bond will either have to be renewed annually or the judgment paid, whichever comes first.
Read the court decisionRead the full story...Reprinted courtesy of
William L. Porter, Porter Law GroupMr. Porter may be contacted at
bporter@porterlaw.com
Nonresidential Construction Employment Expands in August, Says ABC
December 16, 2019 —
Associated Builders and Contractors - Construction ExecutiveThe construction industry added 14,000 net new jobs in August, according to an Associated Builders and Contractors analysis of data released by the U.S. Bureau of Labor Statistics. On a year-over-year basis, industry employment has expanded by 177,000 jobs, or 2.4%.
Nonresidential construction employment increased by 11,600 net jobs in August and is up by 114,200 net jobs over the last 12 months, translating into 2.5% growth. The majority of job gains emerged from nonresidential specialty trade contractors, which added 5,400 jobs last month and nearly 103,000 positions over the past year. Heavy and civil engineering added 4,400 net new jobs, while nonresidential building added 1,800 jobs on a monthly basis.
The construction unemployment rate stood at 3.6% in August, up 0.2 percentage points from the same time last year. Unemployment across all industries stood at 3.7% in August, unchanged from the previous month.
“While job growth across all industries fell short of projections, today’s employment report was just about perfect,” said ABC Chief Economist Anirban Basu. “Yes, employment growth has been softening for quite some time, with average monthly job growth totaling 150,000 during the last six months after approaching 200,000 during the prior six-month period. And employment growth estimates were also revised lower for both June and July. That said, looking beyond the headline number, August’s labor market performance was more than respectable, even accounting for about 25,000 of the jobs being added for temporary Census work.
Reprinted courtesy of
ABC, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
TOP TAKE-AWAY SERIES: The 2023 Fall Meeting in Washington, D.C.
November 13, 2023 —
Marissa L. Downs & Jennifer M. Kanady - The Dispute ResolverOver 500 construction lawyers, experts, and consultants descended on Washington last week for the Forum’s 2023 Fall Meeting. Newly minted Forum Chair John Cook and Program Coordinators Catherine Delorey and Brian Zimmerman put together a stellar program focused on navigating government construction. For this installation of the post-meeting post, I'm teaming up with guest contributor, Jennifer Kanady, to bring you 10 of our top take-aways from this unique program.
10. Contracting with the government is replete with risk that could easily trap the unwary. Nobody likes to be taken advantage of. But hell hath no fury like the U.S. Government scorned. Erin Cannon-Wells and Aaron Silberman, gave a (truly) delightful, Indiana-Jones-inspired presentation on the regulations that can doom the unwitting contractor who is less than perfectly forthright in its dealings. The government has created financial incentives for members of the public to report your company’s violations as part of a qui tam action. When you consider the number of potential whistleblowers in the bidding process and the contracting chain, a qui tam action would seem more likely than not. Add to that the sanctions contractors might face for even innocent errors either by their own companies or their downstream subs, and government contracting begins to sound increasingly like the Temple of Doom. Oh, and in case you were only focused on affirmative claims, beware the “reverse false claim” which is concealing information that would rightfully entitle the government to a credit…
Reprinted courtesy of
Marissa L. Downs, Laurie & Brennan, LLP and
Jennifer M. Kanady, FAC Services, LLC
Ms. Downs may be contacted at mdowns@lauriebrennan.com
Ms. Kanady may be contacted at JKanady@facfin.com
Read the court decisionRead the full story...Reprinted courtesy of
Consider Manner In Which Loan Agreement (Promissory Note) Is Drafted
March 02, 2020 —
David Adelstein - Florida Construction Legal UpdatesConsider who you loan money too and, perhaps more importantly, the manner in which your loan agreements (promissory notes) are drafted. By way of example, in what appears to be a failed construction project in Conrad FLB Management, LLC v. Diamond Blue International, Inc., 44 Fla. L. Weekly D2897a (Fla. 3d DCA 2019), a group of lenders lent money to a limited liability company (“Company”) in connection with the development of a project. Promissory notes were executed by Company and executed by its managing member as a representative of Company, and not in a personal capacity. Company, however, did not own the project. Rather, an affiliated entity owned the project (“Affiliated Entity”). Affiliated Entity had the same managing member as Company. Once the Company received the loan proceeds, it transferred the money to Affiliated Entity, presumably for purposes of the project.
The loans were not repaid and the lenders sued Company, Affiliated Entity, and its managing member, in a personal capacity. The lenders claimed they were all jointly liable under the promissory notes. Although the trial court granted summary judgment in favor of the lenders, this was reversed on appeal as to the Affiliated Entity and the managing member because there was a factual issue as to whether they should be bound by the note executed on behalf of Company.
First, Florida Statute s. 673.4011(1) provides that “a person is not liable on a promissory note unless either (a) the person signed the note, or (b) the person is represented by an agent who signed the note.” Conrad FLB Management, LLC, supra. Affiliated Entity is a separate entity and did not execute the note.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Mortgage Firms Face Foreclosure Ban Until 2022 Under CFPB Plan
April 05, 2021 —
Alex Wittenberg - BloombergMillions of homeowners who’ve fallen behind on mortgage payments due to the pandemic would have more time before facing foreclosure under rules proposed Monday by the Consumer Financial Protection Bureau.
The revamp would generally prohibit mortgage servicers from starting foreclosures until after Dec. 31, the CFPB said in a statement. The goal is to give the nearly 3 million borrowers who’ve delayed or stopped making payments a chance to resume them before lenders initiate forced home sales.
A key reason why the CFPB said the change is necessary is because an estimated 1.7 million consumers will exit U.S. forbearance relief programs in September and the ensuing months, meaning they will have to start making payments again.
Read the court decisionRead the full story...Reprinted courtesy of
Alex Wittenberg, Bloomberg
Godfather Charged with Insurance Fraud
July 01, 2011 —
CDJ STAFFTexas-based Godfather Construction is a recipient of a fraud suit from the Cook County state attorney’s office. The firm incorporated in Illinois in April 2010, moving there to do business after storms damaged homes in the Chicago suburbs, according to a report in the Chicago Tribune. The state attorney alleges that Godfather brought unlicensed out-of-state workers and the work they performed was “incomplete or shoddy.” Godfather is claimed to have received about $60,000 from Illinois homeowners. The prosecutors are seeking restitution for Godfather’s clients and seek to forbid the firm from doing business in Illinois.
Read the full story…
Read the court decisionRead the full story...Reprinted courtesy of
Notes from the Nordic Smart Building Convention
June 29, 2017 —
Aarni Heiskanen - AEC BusinessThe first Nordic Smart Building Convention took place in Helsinki on June 14 and 15, 2017. It was an inspiring event with great keynotes, tech talks, and an exhibition of smart building products and services.
The event was organized by HUB13, a leading co-working space provider in Finland. I had met with the producer of the convention, Sjoerd Postema, when he was planning the event. He asked for my ideas on possible topics and presenters. Later, he invited me to host a workshop and a roundtable at the convention.
Read the court decisionRead the full story...Reprinted courtesy of
Aarni Heiskanen, AEC BusinessMr. Heiskanen may be contacted at
info@aepartners.fi
