Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?
January 27, 2020 —
Ted R. Gropman & Christine Z. Fan - ConsensusDocsConstruction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date.
Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved.
There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973).
Reprinted courtesy of
Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP
Mr. Gropman may be contacted at gropmant@pepperlaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Powering Goal Congruence in Construction Through Smart Contracts
February 22, 2021 —
Michael Matthews - Construction ExecutiveThe $814 billion U.S. commercial construction market requires a unique assembly of designers, contractors, subcontractors and suppliers to work together in a highly orchestrated manner to make sure that the right labor, material, equipment, tools and information all comes together at the right place and time. Alignment and coordination between companies is critical for a project to be successful; completed safely, on time, on budget and resulting in an asset that performs as designed.
Yet the industry is slowed by an operating model bogged down by transactional and informational barriers that destroys value across the construction supply chain. Companies are connected through contracts and purchase orders that are undercut by mistrust that yields adversarial relationships and conflicting priorities that result in restricted transparency, elongated payment cycles and an abundance of resource-sucking reconciliations, audits and disputes.
With margins already razor thin, company protectionism cascades down from owners, developers and operators to contractors, subcontractors and suppliers with each player focused on optimizing their piece at the expense of the whole. Perhaps this is part of the reason 98% of megaprojects experience cost overruns or delays, 95% of projects are unable to meet even one business objective; and 70% of all construction projects are not completed within 10% of the proposed budget.
Reprinted courtesy of
Michael Matthews, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Insurer Has Duty to Defend Despite Construction Defects
January 06, 2012 —
CDJ STAFFIn a case the judge attributed to “shoddy masonry work,” the US District Court of Illinois has rendered a decision in AMCO Insurance Company v. Northern Heritage Builders. Northern Heritage built a home in Chicago for Michael McGrath (who joined Northern Heritage as a defendant). According to the decision, “seven months after he moved into the house, McGrath noticed water coming in the house and warped millwork.” This was attributed to porous block, installed by the mason with Northern Heritage’s knowledge.
McGrath sued National Heritage for both the damage to his house and its contents. The court rejected his claim for the contents. For the damages to his house, he was awarded $601,570.50 in damages. He also sued his homeowner’s insurance carrier for damages not covered in his suit against National Heritage. There he was awarded $1,130,680.16.
AMCO informed National Heritage that it had neither duty to defend nor duty to indemnify. The judge considered whether AMCO had a duty to defend. Under Illinois law, “damage to a construction project resulting from construction defects is not an ‘accident’ or ‘occurrence’ because it represents the natural and ordinary consequence of faulty construction.” However, it is noted that while if the defects lead only to damage to the project itself, there is no occurrence, “if the building owner asserts damages to other property besides the construction itself, there is an ‘occurrence’ and ‘property damage.’” The judge further noted that were construction defects an occurrence, “shoddy work” would be rewarded by double pay, once by the homeowner and a second time by the insurer. Judge Kendall concluded that as McGrath had alleged damage to the contents of his house, AMCO had a duty to defend National Heritage.
She then looked at the issue of whether AMCO had a duty to indemnify. Should they pay the $601,570.50? Judge Kendall noted that “the duty to indemnify is narrower than the duty to defend.” The key point here was that once McGrath’s insurance carrier covered him for the damage to the contents of his house, “AMCO’s duty to defend ended.” Once McGrath “only sought damages for the natural consequences of faulty workmanship” there was no occurrence, hence nothing for AMCO to cover.
Judge Kendall granted a summary dismissal of AMCO’s claim that they had no duty to defend while upholding their claim that they had no duty to indemnify.
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
Is New York Heading for a Construction Defect Boom?
March 12, 2015 —
Beverley BevenFlorez-CDJ STAFFThe New York Times reported that “[t]here is growing concern that some developers are repeating the mistakes of the last housing boom and delivering substandard product.”
“My phone is ringing already on projects that were just completed,” Steven D. Sladkus, a Manhattan real estate lawyer who says his firm has dozens of active construction defect cases, told the New York Times. “Uh-oh, here we go again.”
Recent data shows a rising trend of building plans in New York: “Last year, the city issued construction permits for 20,300 units of housing, according to the Real Estate Board of New York. And the state attorney general’s office received submissions for 263 offering plans for condo conversions and new construction in 2014, up from 184 in 2011. Those numbers will most likely grow in 2015, encouraged by Mayor Bill de Blasio’s push to build more housing.”
Read the court decisionRead the full story...Reprinted courtesy of
Wilke Fleury Attorneys Featured in 2022 Northern California Super Lawyers and Rising Stars Lists
September 05, 2022 —
Wilke Fleury LLPWilke Fleury is extremely proud that 14 of its incredibly talented attorneys are featured in the Annual List of Top Attorneys in the 2022 Northern California Super Lawyers magazine! Super Lawyers rates attorneys in each state using a patented selection process and publishes a yearly magazine issue that produces award-winning features on selected attorneys. Congratulations to this talented group:
Read the court decisionRead the full story...Reprinted courtesy of
Wilke Fleury LLP
Architect Not Responsible for Injuries to Guests
September 01, 2011 —
CDJ STAFFThe Texas Court of Appeals has ruled, with one dissent, that the architectural firm that designed a home was not responsible to the injuries caused to guests when a balcony collapsed. Judge David Puryear wrote the majority opinion in Black + Vernooy Architects v. Smith.
Black + Vernooy designed a vacation home for Robert and Kathy Maxfield in 2000. The Maxfields hired a general contractor to build the home. The general contractor hired a subcontractor to build a balcony; however, the subcontractor did not follow the architect’s design in building the balcony.
A year after the house was completed; the Maxfields were visited by Lou Ann Smith and Karen Gravely. The balcony collapsed under the two women. Ms. Gravely suffered a broken finger, a crushed toe, and bruises. Ms. Smith was rendered a paraplegic as a result of the fall. They sued the Maxfields, the general contractor, and the architects for negligence. The Maxfields and the general contractor settled. A jury found that the architects held 10% of the responsibility. The architects appealed the judgment of the district court.
The Appeals Court reversed this judgment, noting that “there has been no allegation that the Architects negligently designed the balcony or that the Architects actually created the defects at issue.” Further, “the Smiths allege that the defect was caused by the construction practices of the contractor and subcontractor when the balcony was not built in accordance with the design plans of the Architects.”
The court found that even though the architects had a duty “to endeavor to guard against defects and deficiencies in the construction of the home and to generally ascertain whether the home was being built in compliance with the construction plans,” this duty did not extend to third parties.
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
Dusseldorf Evacuates About 4,000 as World War II Bomb Defused
August 20, 2014 —
Dorothee Tschampa – BloombergEmergency services in the northern German city of Dusseldorf are preparing to evacuate more than 4,000 people, including residents of a retirement home, as work gets under way to disarm a World War II bomb discovered during construction work yesterday.
A further 15,000 people, living within a 1 kilometer (0.6 mile) radius of the site, are being asked to stay indoors and keep away from windows, authorities said in a press release published on its website. The disposal is scheduled for 4 p.m. Roads in the vicinity are expected to remain closed until at least 5 p.m.
The 500-kilogram (1,100 pound) U.S. aircraft bomb was unearthed on the site of the former Reitzenstein army barracks, which is being redeveloped as a residential area. It’s the fourth or fifth find since last year in the northeastern district of Moersenbroich, where new apartment buildings and houses are under construction, Tobias Schuelpen, a press spokesman for the local fire service, said by phone.
Read the court decisionRead the full story...Reprinted courtesy of
Dorothee Tschampa, BloombergMs. Tschampa may be contacted at
dtschampa@bloomberg.net
Facing Manslaughter Charges In Worker's 2021 Trench Collapse Death, Colorado Contractor Who Willfully Ignored Federal Law Surrenders To Police
February 06, 2023 —
U.S. Department of LaborBRECKENRIDGE, CO – The owner of a Vail construction company facing felony manslaughter charges has surrendered to local law enforcement after the Summit County Sheriff's Office in Breckenridge, Colorado, issued an arrest warrant on Jan. 24, 2023, related to the findings of a federal safety investigation into a deadly trench collapse in November 2021.
In May 2022, the U.S. Department of Labor's Occupational Safety and Health Administration cited Peter Dillon, owner of the now-defunct A4S LLC, after a worker installing residential sewer pipes suffered fatal injuries when the trench around him caved in. The collapse resulted from deteriorating conditions at the project, which A4S LLC could have prevented by using legally required trench protection systems.
OSHA issued three willful citations to A4S LLC for not ensuring the excavation was inspected by a competent person, failing to instruct employees on the recognition and avoidance of unsafe conditions and not having a trench protective system in place. Investigators also issued an additional serious citation for not having a safe means of egress within 25 lateral feet of employees working in a trench.
The agency proposed penalties of $449,583 and placed the company in OSHA's Severe Violator Enforcement Program.
The department referred the case to the 5th Judicial District Attorney's office recommending criminal charges for A4S LLC's refusal to require safety protection, despite worsening trench conditions that included at least one trench collapse.
A4S LLC has since shuttered and Dillon agreed to forfeit any future ownership, leadership or management position that involves trenching or excavation, or the oversight of workplace safety and health.
Read the court decisionRead the full story...Reprinted courtesy of
