Cambridge Massachusetts Building Expert Directory

Construction Lien Does Not Include Late Fees Separate From Interest

December 30, 2019 — David Adelstein - Florida Construction Legal Updates
Construction liens can include unpaid finance charges. But, what about late fees? You know, the late fees that certain vendors like to include in their contract or purchase order unrelated to finance charges. An added cost for being delinquent with your payment. Can a late fee be tacked onto the lien too? In a recent case, Fernandez v. Manning Building Supplies, Inc., 2019 WL 4655988 (Fla. 1st DCA 2019), a residential owner hired a contractor for a renovation job. The contractor entered into a contract with a material supplier. The terms of the supplier’s contract with the contractor provided that there would be a 1.5% delinquency charge for late payments and it seemed apparent that the delinquency charge was separate from finance charges. Florida Statute s. 713.06(1) provides in relevant portion:

A materialman or laborer, either of whom is not in privity with the owner, or a subcontractor or sub-subcontractor who complies with the provisions of this part and is subject to the limitations thereof, has a lien on the real property improved for any money that is owed to him or her for labor, services, or materials furnished in accordance with his or her contract and with the direct contract and for any unpaid finance charges due under the lienor’s contract.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Texas LGI Homes Goes After First-Time Homeowners

May 13, 2014 — Beverley BevenFlorez-CDJ STAFF
According to Big Builder, while many consumers have “gone to rentals…as the homeownership rate fell,” that hasn’t stopped Texas-based builder LGI Homes from marketing to the entry-level buyer: “We do not believe that we’re becoming a renter society,” Eric Lipar, LGI CEO told Big Builder. “We believe there is a need and a desire for homeownership.” “The real growth will be powered by an aggressive sales and marketing operation that aims to pull renters out of their apartments (or single-family rentals) and into LGI homes,” reported Big Builder. “So far this pitch has worked in Texas (Dallas, Houston, San Antonio, and Austin), in addition to Phoenix and Tampa, Fla.” Read the court decision
Read the full story...
Reprinted courtesy of

California Assembly Bill Proposes an End to Ten Year Statute of Repose

May 09, 2011 — CDJ STAFF

California Assemblyman Furutani has introduced a bill that if passed would eliminate the ten year statute of repose in certain construction defect cases. The statute of repose would not apply when “an action in tort to recover damages for damage to real or personal property, or for personal injury or wrongful death from exposure to hazardous or toxic materials, pollution, hazardous waste, or associates environmental remediation activities,” according to the latest amended version of AB 1207.

When Furutani first introduced the bill, it was aimed at small businesses only. However, the description of the bill, which read, “An act to amend Section 14010 of the Corporations Code, relating to small businesses” has been stricken from the bill, and it has been amended to read, “An act to amend Section 337.15 of the Code of Civil Procedure, relating to civil actions.”

The change in the bill’s intent has caused some outcry among attorneys in the blogosphere. For instance, Sean Sherlock of Snell & Wilmer stated that “the proposed amendment is unnecessary, and would upset nearly 50 years of deliberative legislation and judicial precedent on construction defects liability and the 10–year statute — all apparently motivated by a decision in a single, isolated Superior Court lawsuit that has not yet been reviewed by the court of appeal.” Sherlock is referring to Acosta v. Shell Oil Company, in which the Superior Court agreed to dismiss the plaintiffs’ claims against the developer based in part on the ten year statute of repose. AB 1207 was amended five days after the ruling in Acosta v. Shell Oil Company.

California AB 1207 has been re-referred to the Judiciary Committee.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

Type I Differing Site Conditions Claim is Not Easy to Prove

May 30, 2018 — David Adelstein - Florida Construction Legal Updates
A differing site condition claim will almost universally result in both a cost and time impact. There will be additional, unanticipated costs incurred. And there will likely be a delay requiring additional time to perform. A Type I differing site condition claim is when the contractor encounters conditions at the site different than those indicated in the contract documents. That seems easy enough to prove, right. Nope. And, I mean nope! If you don’t believe me, consider the recent decision in Meridian Engineering Co. v. U.S., 885 F.3d 1351 (Fed.Cir. 2018). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

RDU Terminal 1: Going Green

June 30, 2014 — Melissa Dewey Brumback – Construction Law in North Carolina
Last week, I had the fortune to join the Triangle USGBC for its “Talk & Walk” about the RDU Terminal 1 renovation project and its sustainable features. For those who haven’t had the chance, I recommend you check out the new terminal specifics the next time you find yourself jet-setting in or out of Raleigh on Southwest airlines. Terminal 1 has been in operation since 1981, with the last upgrade in 1991. The 2010 opening of the new Terminal 2 had, until now, cemented Terminal 1′s status as the airport’s ugly duckling- complete with the long, featureless metal addition abandoned to times past. While the $68 million Terminal 1 renovation cannot compete with the Terminal 2 $580 million budget, it nevertheless is an entirely re-imagined space. Better traffic flow (yes, you can now find where to go through security!), increased daylighting, a new canopy system, and commercial curb canopy (see photo) all complete the new architectural image. Clark Nexsen principals Irvin Pearce and Doug Brinkley explained the renovation, which included energy saving escalators- the first escalator system in North Carolina that slows down during non-use. Other sustainable features include LEED complaint flooring, 86% structural building re-use (slabs on grade, composite decks, and structural roof deck), and 28% reuse of exterior walls. Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Construction Law in North Carolina
Ms. Brumback can be contacted at mbrumback@rl-law.com

Philadelphia Revises Realty Transfer Tax Treatment of Acquired Real Estate Companies

January 05, 2017 — Nancy Frantz, Kevin Koscil & James Vandermark – White and Williams LLP
On December 8, 2016, the Philadelphia City Council voted unanimously to amend the ordinance governing realty transfer taxes in an effort to increase tax revenue. The current combined realty transfer tax rate in Philadelphia is 4.0% and will increase to 4.1% after December 31, 2016.[1] The amendment significantly impacts how taxes are imposed upon transfers of ownership in so-called “real estate companies” and effectively eliminates deals commonly referred to as 89-11 transactions. The amendment mainly focuses on transfers of real estate companies, rather than direct transfers of real estate, but it also affects certain direct transfers of real estate in exchange for noncash consideration. Reprinted courtesy of White and Williams LLP Nancy Frantz, Kevin Koscil and James Vandermark Ms. Frantz may be contacted at frantzn@whiteandwilliams.com Mr. Koscil may be contacted at koscilk@whiteandwilliams.com Mr. Vandermark may be contacted at vandermarkj@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

How the Cumulative Impact Theory has been Defined

November 30, 2020 — David Adelstein - Florida Construction Legal Updates
Largely in the federal contract arena, there is a theory referred to as “cumulative impacts” used by a contractor to recover unforeseeable costs associated with a multitude of changes that have an overwhelming ripple effect on its efficiency, particularly efficiency dealing with its original, base contract work. In other words, by dealing with extensive changes, there is an unforeseeable impact imposed on the contractor relative to its unchanged or base contract work. Under this theory, the contractor oftentimes prices its cumulative impact under a total cost approach with an examination on its cost overrun. However, this is not an easy theory to prevail on because there needs to be a focus on the sheer number of changes, causation supporting the impact, and whether there were concurrent impacts or delays that played a role in the ripple effect. See, e.g., Appeals of J.A. Jones Const. Co., ENGBCA No. 6348, 00-2 BCA P 31000 (July 7, 2000) (“However, in the vast majority of cases such claims are routinely denied because there were an insufficient number of changes, contractor-caused concurrent delays, disruptions and inefficiencies and/or a general absence of evidence of causation and impact.”). To best articulate how the cumulative impact theory has been defined, I want to include language directly from courts and board of contract appeals that have dealt with this theory. This way the contractor knows how to best work with their experts with this definition in mind–and, yes, experts will be needed–to persuasively package and establish causation and damages stemming from the multitude of changes. While many of these definitions are worded differently, you will see they have the same focus dealing with the unforeseeable ripple effect of the extensive changes. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Avoid L&I Violations by Following Appropriate Safety Procedures

November 07, 2022 — Reeya Patel - Ahlers Cressman & Sleight PLLC
Department of Labor and Industries of the State of Washington v. Roof Doctor, Inc. d/b/a Roof Doctors, Inc. of Tacoma (Unpublished opinion) Roof Doctor, a company engaging maintenance of roofs, was hired to complete work for a commercial building in Tacoma in February 2018. During the job, Roof Doctor was cited for two violations by a Washington State Department of Labor and Industries’ (L&I) compliance inspector and seven additional asbestos violations. Each citation was rated with a probability of 1 – 3 to determine the likelihood of injury, illness, or disease. The ratings allowed issuance of an appropriate monetary penalty. The disputes among the parties on appeal were as follows: First, L&I and Roof Doctor disputed the asbestos probability ratings and calculated penalties. L&I produced as evidence, the fact that nine employees were physically hanging roofing material with asbestos, but none had training or knew that the material contained asbestos. L&I did agree that that most of the employees were experienced in handling roofing material and knew of the dangers that asbestos presented. Roof Doctor explained that because the employees were working outdoors, the danger of asbestos exposure was mitigated due to a low probability that a high concentration of asbestos could be inhaled by the employees when outdoors. Read the court decision
Read the full story...
Reprinted courtesy of Ahlers Cressman & Sleight PLLC

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES