Seattle Washington Building Expert Directory

Compliance with Building Code Included in Property Damage

February 07, 2018 — Tred R. Eyerly – Insurance Law Hawaii

A Circuit Court in Florida issued a final judgment determining that the insured's obligation to comply with building code provisions was included in the property damage experienced. Pin-Pon Corp. v. Landmark, Am. Ins. Co., No. 312009CA012244 (Fla. Cir. Ct. Dec. 28, 2017). The decision is here.

At trial, the plaintiff's architect testified that the total pricing for the code upgrades was $6.2 million. On appeal, the appellate court ruled that plaintiff's Exhibit 98, an Upgrade Insurance Claim, was improperly admitted as a business record. The appellate court stated that the jury may have considered Exhibit 98 in determining the amount of code upgrade damages. Therefore, the verdict was reversed and remanded for a trial on the code upgrade damages only.

Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawarii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Eleven Newmeyer Dillion Attorneys Named to 2023 U.S. News Best Lawyers in Multiple Practice Areas

August 29, 2022 — Newmeyer Dillion
NEWPORT BEACH, Calif. – August 18, 2022 – Prominent business and real estate law firm Newmeyer Dillion is pleased to announce that eleven of the firm’s attorneys were recently selected for inclusion and will be recognized in their respective areas in The Best Lawyers in America© 2023. Additionally, Greg Dillion, Thomas Newmeyer and Michael McClellan have been selected to Best Lawyers 2023 Lawyer of the Year list in Litigation - Construction, Construction Law and Litigation - Real Estate respectively. The eleven 2023 Best Lawyers are:

Best Lawyers is the oldest peer-review publication for the legal profession. Attorneys are chosen through intensive peer-review surveys in which leading lawyers evaluate their professional peers. Best Lawyers listings are published in almost 70 countries worldwide and are recognized for their reliable and unbiased selections. Read the court decision
Read the full story...
Reprinted courtesy of

One More Statutory Tweak of Interest to VA Construction Pros

April 25, 2022 — Christopher G. Hill - Construction Law Musings
While I have focused on the recent “pay if paid” legislation in recent posts, the Virginia General Assembly has taken other action that is of interest to those of us that represent construction professionals in Virginia. One such action is yet another tweak to the so-called “wage theft” statute that essentially made a general contractor the guarantor of all wage payments of its downstream construction partners. The first of the tweaks to the statute passed in 2020 was to create a defense for a general contractor if it obtained a written certification of wage payment from its immediate downstream subcontractor. This year, the General Assembly expanded the protection provided by such certification to all subcontractors. In other words, any contractor or subcontractor can now protect itself from wage theft claims by the use of a certification that all wages were paid from its immediate downstream partner. The text of the changes can be found here. [note that the Governor has sent suggested grammatical amendments that did not affect the substance] Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Super Lawyers Recognized Five Lawyers from Hunton’s Insurance Recovery Group

August 29, 2022 — Hunton Insurance Recovery Blog
Partners, Larry Bracken, Lorie Masters, and Koorosh Talieh (KT), were each recognized as Super Lawyers, while associates Yaniel Abreu and Rachel Hudgins were selected as Rising Stars for Insurance Coverage in 2022. Super Lawyers, part of Thomson Reuters, is a rating service of outstanding lawyers from more than 70 practice areas who have attained a high degree of peer recognition and professional achievement. The patented selection process includes independent research, peer nominations and peer evaluations. Ultimately, no more than 5% of lawyers in a state are selected as Super Lawyers, and less than 2.5% are recognized as Rising Stars. Congratulations on this achievement! Reprinted courtesy of Hunton Andrews Kurth LLP Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

AI – A Designer’s Assistant or a Replacement?

November 28, 2022 — Aarni Heiskanen - AEC Business
Over the last few months, we’ve seen an online explosion of AI-powered text and image generators. Many non-designers welcome these tools as a way to express themselves and create results that would have taken professionals days to complete. The obvious question is, should designers start feeling scared? Interior designs from a photo you upload In Business of Home, Fred Nicolaus writes about how he tested with an L.A. designer Shaun Crha an online tool called Interior AI. They uploaded pictures of empty rooms, selected basic prompts (“midcentury modern bathroom,” for example), and watched the machine go. After tweaking the tool settings, they started getting impressive results. Launched in September 2022, Interior AI is the creation of Pieter Levels, a programmer. He built the site in five days by connecting it to a commercially available AI engine called Stable Diffusion. It has been trained with images from Pinterest and other photo sources. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Distinguishing Hawaii Law, New Jersey Finds Anti-Assignment Clause Ineffective

March 22, 2017 — Tred R. Eyerly – Insurance Law Hawaii
The New Jersey Supreme Court found that an anti-assignment provision could not be applied to bar a post-loss claim assignment. Givaudan Fragrances Corp. v. Aetna Cas. & Sur. Co., 2017 N.J. LEXIS 121 (N.J. Feb. 1, 2017). In reaching its decision, the court distinguished a decision from the Hawaii Supreme Court enforcing consent-to-assignment clauses and failing to recognize any post-loss exception to such clauses. See Del Monte Fresh Produce (Hawaii), Inc. v. Fireman's Fund Ins. Co., 183 P.3d 734 (Haw. 2007). Plaintiff Givaudan Fragrances Corporation (Fragrances) was sued for environmental contamination at a manufacturing site. A related corporate entity had operated the facility from the 1960s to 1990. Fragrances sought coverage under policies issued to its predecessor. The predecessor attempted to assign to Fragrances post-loss rights under the policies. The insurers resisted, claiming the predecessor was the named insured, not Fragrances, and that the insurers did not consent to an assignment of the predecessor's policies. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

EPA Coal Ash Cleanup Rule Changes Send Utilities, Agencies Back to Drawing Board

February 21, 2022 — Corinne Grinapol - Engineering News-Record
The U.S. Environmental Protection Agency plans to deny requests by three power facilities for extended deadlines to close unlined coal ash impoundments that are risks to groundwater, while offering only a provisional extension to another. The decision came as part of a larger agency push to strengthen regulation of coal combustion residuals disposal and facilities with unlined storage. Reprinted courtesy of Corinne Grinapol, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES