CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Woodbridge II and the Nuanced Meaning of “Adverse Use” in Hostile Property Rights Cases in Colorado

November 23, 2020 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
Earlier this year, the Colorado Court of Appeals issued an opinion addressing at length “whether the requirement that the use be ‘adverse’ in the adverse possession context is coextensive with adverse use in the prescriptive easement context.” See Woodbridge Condo. Ass’n, Inc. v. Lo Viento Blanco, LLC, 2020 COA 34 (Woodbridge II), ¶ 2, cert. granted, No. 20SC292, 2020 WL 5405376 (Colo. Sept. 8, 2020). As detailed below, the Woodbridge II court concluded that the meanings of “adverse” in these two contexts are not coextensive—while “hostility” in the adverse possession context requires a claim of exclusive ownership of the property, a party claiming a prescriptive easement is only required to “show a nonpermissive or otherwise unauthorized use of property that interfered with the owner’s property interests.” Thus, the Woodbridge II court reasoned a claimants’ acknowledgement or recognition of an owner’s title alone is insufficient to defeat “adverse use” in the prescriptive easement context. This significant ruling is at odds with a prior division’s broad statement, while considering a prescriptive easement claim, that “[i]n general, when an adverse occupier acknowledges or recognizes the title of the owner during the occupant’s claimed prescriptive period, the occupant interrupts the prescriptive use.” See Trask v. Nozisko, 134 P.3d 544, 553 (Colo. App. 2006). Perhaps for that reason, Woodbridge II is currently pending certiorari review before the Colorado Supreme Court in a case that should provide some much-needed clarity on what constitutes “adverse use” in the context of a prescriptive easement. As we await the Colorado Supreme Court’s decision, I thought it worthwhile to provide a brief analysis of the Woodbridge II court’s deep dive into the nuances of “adverse use” in this field of Colorado law. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

---

Standard For Evaluating Delay – Directly from An Armed Services Board Of Contract Appeal’s Opinion

October 04, 2021 — David Adelstein - Florida Construction Legal Updates
Sometimes, it is much better to hear it from the horse’s mouth. That is the case here. The Armed Services Board of Contract Appeal’s (ASBCA) opinion in Appeals of -GSC Construction, Inc., ASBCA No. 59402, 2020 WL 8148687 (ASBCA November 4, 2020) includes an informative discussion of a contractor’s burden when it encounters excusable delay and, of importance, the standard for evaluating delay. It’s a long discussion but one that parties in construction need to know, appreciate, and understand. EVERY WORD IN THIS DISCUSSION MATTERS. Construction projects get delayed and with a delay comes money because time is money. Many claims are predicated on delay. These can be an owner assessing liquidated damages due to a delayed job or a contractor seeking its costs for delay. Either way, the standard for evaluating delay and the burdens imposed on a party cannot be understated and, certainly, cannot be overlooked. For this reason, here is the discussion on evaluating delay directly from the horse’s mouth in the Appeal of-GSC Construction, Inc.:

The critical path is the longest path in the schedule on which any delay or disruption would cause a day-for-day delay to the project itself; those activities must be performed as they are scheduled and timely in order for the project to finish on time. Wilner v. United States, 23 Cl. Ct. 241, 245 (1991). In Yates-Desbuild Joint Venture, CBCA No. 3350 et al., 17-1 BCA ¶ 36,870, our sister board compiled an excellent and very helpful synopsis of the standards for evaluating delay claims, which I adopt nearly verbatim among the discussion that follows.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Insured's Collapse Claim Survives Summary Judgment

October 28, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The insurer's motion for summary judgment seeking to dispose of the insured's claim for collapse was denied. Life Skills, Inc. v. Harleysville Ins. Co., 2024 U.S. Dist. LEXIS 143658 (D. Mass. Aug. 13, 2024). Life Skills was a non-profit social service agency providing residential and day habilitation services to adults with autism and intellectual and developmental disabilities. The head office was covered by a policy issued by Harleysville with building coverage limits of $3,038,300. Damage occurred in a ceramics classroom located in the basement of the building. The floor sank between eight to twelve inches in the northeast corner. The ceramics classroom contained two large kilns weighing approximately 200 pounds. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Remodel Leads to Construction Defect Lawsuit

October 16, 2013 — CDJ STAFF
The Sacramento, California law firm Anderson Shoech has announced that it will be filing a construction defect lawsuit concerning a single-family home in Sonora, California. The remodel is alleged to have lead to roof leaks and mold growth. Anderson Schoech will have the home inspected by a general contractor who will be retained as an expert witness. Read the court decision
Read the full story...
Reprinted courtesy of

---

Design-Assist Collaboration/Follow-up Post

March 16, 2020 — John P. Ahlers - Ahlers Cressman & Sleight PLLC
Shortly after posting the blog article “Design-Assist an Ambiguous Term Causing Conflict in the Construction Industry,” I received an email from Brian Perlberg, the Executive Director and Senior Counsel for ConsensusDocs. He brought two ConsensusDocs forms to my attention: ConsensusDocs 541 Design Assist Addendum and ConsensusDocs 300 Integrated Form of Agreement (IFOA). In the ConsensusDocs model of “design-assist,” the lead design professional retains design responsibility but benefits from input and consultation from the construction team during design development. By contrast, in the design-build project delivery method, the constructor assumes design responsibility and liability for either the entire project design (design-build) or just a component of the design (delegated design). The ConsensusDocs 541 document goal is to provide “accurate information concerning program, quality, cost, constructability and schedule from all parties.” It provides a range of standard and optimal services during design development that essentially shifts the curve of selecting the construction manager (CM) and most importantly, special trade contractors, to much earlier in the process, perhaps as soon as the owner’s program is developed. This opens a world of possibilities for the design and construction team to collaborate early and often. The design professional, however, does not abdicate its design responsibility or authority in this process. The ultimate goal is to end the all-too-common wasteful cycle of design and redesign that is common in construction projects.[1] Read the court decision
Read the full story...
Reprinted courtesy of John P. Ahlers, Ahlers Cressman & Sleight PLLC
Mr. Ahlers may be contacted at john.ahlers@acslawyers.com

---

Indemnity Clauses—What do they mean, and what should you be looking for?

May 07, 2015 — Craig Martin – Construction Contractor Advisor
It seems that every construction contract now-a-days, contains an indemnity clause. Contractors should be reviewing these indemnity clauses very carefully to understand the potential scope of an indemnity obligation and your opportunity to negotiate changes. What is an indemnity Clause? An indemnity clause transfers risk from one party to another. When a contractor signs an indemnity agreement, it is agreeing to pay for damages for which another party could be liable. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

---

Where-Forum Art Thou? Is the Chosen Forum Akin to No Forum at All?

May 30, 2022 — William Doerler - The Subrogation Strategist
Many courts enforce forum selection clauses in contracts between parties. In W. Bay Plaza Condo. Ass’n v. Sika Corp., No. 3D21-1834, 2022 Fla. App. LEXIS 1637 (W. Bay Plaza), the Court of Appeal of Florida, Third District (Court of Appeal) answered the question of whether a mandatory forum selection clause in a manufacturer’s warranty was enforceable as to a condominium association, who was a non-signatory. The trial court enforced the forum selection clause – calling for litigation in New Jersey rather than Florida – and the Court of Appeal affirmed the ruling. As stated in W. Bay Plaza, in late 2013 and early 2014, West Bay Plaza Condominium Association (W.B. Plaza Condo. Ass’n) contracted with Built Right Installers International Corporation, R.J. Miranda Consultants, Inc. and UCI Engineering Inc. (collectively, the Construction Defendants) to have repairs done to the exterior of the property. In 2016, Sika Corporation (Sika), a New Jersey corporation, gave a five-year warranty to W.B. Plaza Condo. Ass’n for three sealant products used to repair the garage at the property. In 2019, W.B. Plaza Condo. Ass’n sued the Construction Defendants for breach of contract and professional negligence. Subsequently, W.B. Plaza Condo. Ass’n amended its complaint and filed a claim against Sika, alleging that Sika breached its warranty because its products failed to provide a watertight barrier. Sika filed a motion to dismiss the action, alleging that Florida was an improper venue because its’ warranty contained a mandatory forum selection clause. W.B. Plaza Condo. Ass’n argued that it was not bound by the forum selection clause because it was a non-signatory to the warranty and, even if it was bound by the clause, there were compelling reasons not to enforce it. Read the court decision
Read the full story...
Reprinted courtesy of William Doerler, White and Williams LLP
Mr. Doerler may be contacted at doerlerw@whiteandwilliams.com

---

Construction Litigation Roundup: “Who Needs Them”

August 28, 2023 — Daniel Lund III - Lexology
Who needs them? So argued a surety pursuing recovery under its general agreement of indemnity when the indemnitors urged a Louisiana federal court to dismiss the surety’s complaint for failure to join various allegedly required parties as defendants in the litigation. As part of its court action, the surety moved for preliminary injunction to enforce its collateral security rights. In response thereto, the indemnitors informed the court that if the injunction were to be granted, the indemnitors would “be forced to sell assets that are encumbered by security interests senior to those held by” the surety. In connection therewith, the indemnitors demanded that the other creditors be joined in the action or the lawsuit dismissed. The indemnitors also urged that the public project owner be joined as a party because the surety was seeking proceeds from the project that were still in the possession of the project owner. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

---