Florida Federal Court to Examine Issues of Alleged Arbitrator Conflicts of Interests in Panama Canal Case
May 24, 2021 —
Sarah B. Biser & Philip Z. Langer - ConsensusDocsThe parties in a $238-million dispute over the construction of the third set of locks for the Panama Canal are raising issues concerning alleged conflicts of interest on the part of the International Chamber of Commerce (“ICC”) arbitrators in the United States District Court for the Southern District of Florida.[2] The case may address rarely litigated issues concerning whether arbitrators who sit on multiple arbitration panels together or who support appointment of each other to lead arbitration panels have disabling conflicts of interest.
The case pits Grupo Unidos por el Canal, S.A. (“Grupo”), a consortium of Spanish, Italian, Belgian, and Panamanian construction firms, against Autoridad del Canal de Panama (“ACP”), the Panamanian entity that operates the Panama Canal and that sponsored the multi-billion-dollar, decade-long project to expand the Canal’s capacity by building a new set of locks (the “Project”). The current dispute (the “Panama 1 Arbitration”), which centers on the suitability of the rock coming from the excavations to be used to produce concrete aggregates for the Project, was arbitrated before a three-member ICC Tribunal and resulted in a $238-million award to ACP and against Grupo. The ICC Tribunal reversed a decision of the dispute review board established in the parties’ contract.
Reprinted courtesy of
Sarah B. Biser, Fox Rothschild LLP and
Philip Z. Langer, Fox Rothschild LLP
Ms. Biser may be contacted at sbiser@foxrothschild.com
Mr. Langer may be contacted at planger@foxrothschild.com
Read the court decisionRead the full story...Reprinted courtesy of
General Contractor Intervening to Compel Arbitration Per the Subcontract
December 06, 2021 —
David Adelstein - Florida Construction Legal UpdatesIt is not uncommon that a general contractor’s subcontract will include an arbitration provision. Or it will allow the general contractor to select binding arbitration as the method to resolve disputes at the general contractor’s SOLE OPTION. A general contractor’s subcontract should absolutely give the general contractor this important right. (Keep this in mind when drafting dispute resolution provisions for a general contractor.)
It is also not uncommon for a subcontractor the sue a general contractor’s payment bond surety, and NOT the general contractor. One reason to do this is to create an argument to avoid the dispute resolution provision in the subcontract. (Another reason is to avoid any pay-if-paid defense.) When this occurs, a general contractor may still want to arbitrate the subcontractor’s payment bond dispute and a way to do so is for the general intervene in the lawsuit and move to compel arbitration. Sometimes, it is even practical for the general contractor to immediately initiate the arbitration process against the subcontractor, particularly if the general contractor wants to assert a counterclaim, so that the motion to compel is supported by the formal demand for arbitration (and filed with the American Arbitration Association or other body administering the arbitration). I have done this on a number of occasions.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?
January 27, 2020 —
Ted R. Gropman & Christine Z. Fan - ConsensusDocsConstruction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date.
Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved.
There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973).
Reprinted courtesy of
Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP
Mr. Gropman may be contacted at gropmant@pepperlaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Chairman of the Senate Committee on Banking, Housing and Urban Affairs Calls for CFPB Investigation into Tenant Screening Businesses
December 13, 2021 —
Brian H. Montgomery - Gravel2Gavel Construction & Real Estate Law BlogSenator Sherrod Brown (D-OH), Chairman of the Senate Committee on Banking, Housing, and Urban Affairs, has written to
newly confirmed Consumer Financial Protection Bureau (CFPB) Director Rohit Chopra, asking him to review companies in the tenant screening industry for possible Fair Credit Reporting Act violations and other violations of U.S. laws. The CFPB, for its part, has already published a bulletin alerting Consumer Reporting Agencies (CRAs) and other furnishers of consumer information that, as federal, state and local pandemic-related housing protections expire, the Bureau will be giving greater enforcement focus to these businesses’ compliance with accuracy and dispute obligations under the Fair Credit Reporting Act (FCRA) and Regulation V. While it is still unclear whether Director Chopra will direct the Bureau to investigate specific businesses flagged by Chairman Brown, the tenant screening industry will likely face increased scrutiny in the coming months, which may impact their service offerings and cause interruptions for landlords relying on these businesses and services.
There are approximately 2,000 tenant screening companies across the United States. These companies are used by landlords to better identify and perform background checks on prospective tenants. These reports typically provide a prospective tenant’s rental and eviction histories, credit score, debt-to-income ratio, and outstanding credit obligations, among other financial metrics. The reports also usually include a criminal background check, including searches of sex offender registries and other public records searches. Many tenant screening companies then use this information to provide an estimate of the risk that each tenant presents, calculated through proprietary algorithmic formulas. These reports are usually available to landlords at a cost ranging from approximately $5 to $55 per report, usually passed through to the prospective tenant through application fees.
Read the court decisionRead the full story...Reprinted courtesy of
Brian H. Montgomery, PillsburyMr. Montgomery may be contacted at
brian.montgomery@pillsburylaw.com
Bill to Include Coverage for Faulty Workmanship Introduced in New Jersey
December 04, 2013 —
CDJ STAFFOn November 25, Gary S. Schaer, a Democrat from Bergen and Passic, introduced a bill into the New Jersey legislature that would require insurers to cover faulty workmanship. The bill would require commercial liability insurance policies to cover “property damage or bodily injury resulting from faulty workmanship.” Policies that do not provide this coverage could not be offered in the state of New Jersey should the measure pass and be enacted into law.
Read the court decisionRead the full story...Reprinted courtesy of
Not a Waiver for All: Maryland Declines to Apply Subrogation Waiver to Subcontractors
September 23, 2024 —
Gus Sara - The Subrogation StrategistIn Lithko Contr., LLC v. XL Ins. Am. Inc., No. 31, Sept. Term, 2023, 2024 Md. LEXIS 256, the Supreme Court of Maryland considered whether a tenant who contracted for the construction of a large warehouse facility waived its insurer’s rights to subrogation against subcontractors when it agreed to waive subrogation against the general contractor. The court ultimately decided that the unambiguous language of the subrogation waiver in the development agreement between the parties did not extend to subcontractors. The court also held that the tenant’s requirement that subcontracts include a subrogation waiver did not, in this case, impose a project-wide waiver on all parties. The court, however, found that the requirement that the subcontracts include a similar, but not identical, waiver provision rendered the subcontract’s waiver clauses ambiguous and remanded the case to the lower court to determine if the parties to the development agreement – i.e., Duke Baltimore LLC (“Duke”) and Amazon.com.dedc, LLC (“Amazon”) – intended that the waiver clause in the subcontracts covered claims against subcontractors.
This case involved roof and structural damage to a warehouse in Baltimore, Maryland that Duke owned. In March 2014, Amazon entered into a development agreement with Duke for the construction of the warehouse. Amazon also agreed to subsequently lease the warehouse from Duke. Although Amazon essentially owned and/or developed the project, the development agreement identified Duke as “Landlord” and Amazon as “Tenant.”
Read the court decisionRead the full story...Reprinted courtesy of
Gus Sara, White and WilliamsMr. Sara may be contacted at
sarag@whiteandwilliams.com
Newmeyer & Dillion Ranked Fourth Among Medium Sized Companies in 2016 OCBJ Best Places to Work List
September 01, 2016 —
Newmeyer & Dillion LLPProminent business and real estate law firm
Newmeyer & Dillion LLP is proud to announce that it has been ranked fourth among medium sized companies in the
Best Places to Work in Orange County – 2016 Survey. The firm was the only law firm to make the top 25 of its category. This marks the fifth consecutive year Newmeyer & Dillion LLP has made the list showing that its deep commitment to professionalism and client service is shared and appreciated by its workforce.
Jeff Dennis, Newmeyer & Dillion’s Managing Partner, believes the award is representative of the team effort and atmosphere that is fostered at the firm. “We believe that client satisfaction goes hand-in-hand with work-place satisfaction. By combining an environment in which individual effort is recognized, with a team approach in which everyone is respected, we have achieved the perfect balance for success. We are honored that our employees appreciate our efforts in this regard.”
Created in 2009, the awards program evaluates entries based on workplace policies, practices, demographics and also collects employee surveys to measure overall satisfaction and experience. The Best Companies Group worked alongside the Orange County Business Journal in collecting and analyzing the data and is a partner in the project.
Newmeyer & Dillion has been honored in the July 25 issue of the Orange County Business Journal. For more information on the survey process and to see other award recipients contact Jackie Miller at 877-455-2159 or visit www.BestPlacestoWorkOC.com.
About Newmeyer & Dillion
For more than 30 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of business, employment, real estate, construction and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client’s needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949-854-7000 or visit www.ndlf.com.
Read the court decisionRead the full story...Reprinted courtesy of
Cities' Answer to Sprawl? Go Wild.
December 06, 2021 —
Chris Malloy - BloombergIn a neighborhood of right-angled stone, stucco and brick buildings not far from Milan’s central train station, two thin towers stand out. Green and shaggy-edged, they look like they’re made of trees. In fact, they’re merely covered in trees — hundreds of them, growing up from the towers’ staggered balconies, along with 11,000 perennial and covering plants, and roughly 5,000 shrubs.
The greenery-festooned towers, called the Bosco Verticale, or Vertical Forest, are residential buildings in a broader-than-usual sense. The 18- and 26-story structures are “a home for trees that also houses humans and birds,” according to the website of architect Stefano Boeri, who has built tree-covered buildings elsewhere and is working on similar projects in Antwerp, Belgium, and Eindhoven in the Netherlands.
The Bosco Verticale is an example of urban rewilding, the growing global trend of introducing nature back into cities. There are consequences to the pace of today’s urban growth, which is the fastest in human history, including loss of biodiversity, urban heat islands, climate vulnerability, and human psychological changes. The U.S. Forest Service estimates that some 6,000 acres of open, undeveloped space become developed each day. Globally, past urban planning decisions like the prioritization of the car have given rise to cities that, but for scattered parks, tend to be divorced from nature. Rewilding aims to make cities better and more sustainable for people, plants, and animals.
Read the court decisionRead the full story...Reprinted courtesy of
Chris Malloy, Bloomberg
