Seattle Washington Building Expert Directory

Join: Computer Science Meets Construction

August 20, 2018 — Aarni Heiskanen - AEC Business
Increasingly, projects need to be optimized to create the most value for their clients and users. With the fragmented nature of project teams, decisions can be lost, communication sporadic, and information disjointed. In addition, the rapid pace of innovation means that it’s difficult – if not impossible – for architects and engineers to be aware of all the latest construction products and materials. It is these problems that inspired the creation of Join. Join is a smart platform that helps project teams collaborate more efficiently and effectively, whether as part of a project optimization process or throughout the entire project lifecycle. The platform connects construction teams, pulls together different types of project information, and integrates manufacturing into construction. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Speculative Luxury Homebuilding on the Rise

April 08, 2014 — Beverley BevenFlorez-CDJ STAFF
Forbes reported that there is a “comeback in speculative building of luxury homes in centers of wealth across the country.” “The appearance of spec homes in the upper price range is an indication of the maturation of the housing cycle,” Stuart Gabriel, director of the Ziman Center for Real Estate at UCLA, told Forbes. “It’s an indication of increasing levels of confidence on the part of home builders.” Dana Kuhn, of the Corky McMillin Center for Real Estate at San Diego State University, stated that she “would expect luxury buyers to want more design control than can be afforded them if the house is mostly complete when they make their purchase.” But the article showed the flip side: Some luxury buyers are “too busy to bother with such involvement” and even prefer to buy the house fully furnished. Read the court decision
Read the full story...
Reprinted courtesy of

Water Damage: Construction’s Often Unnoticed Threat

November 02, 2020 — Yaron Dycian - Construction Executive
Fire damage to commercial buildings might get headlines, but water damage, whether to projects under construction or completed buildings, delivers massive financial blows to owners, developers and contractors. The impact is massive, reaching many billions of dollars per year. One water leak on the 19th floor at a construction site of a high-end apartment building in New York City resulted in $30 million in property damage and millions in delayed delivery penalties. Imagine this all-too-typical scenario: A 20-story building has thousands of pipe connections and many tens of thousands throughout the entire building. It only takes one of those joints failing, perhaps due to human oversight. Early on a Saturday morning when no one is onsite, one of the connections inside a wall begins to leak, slowly at first. In a couple hours the connection fails completely, sending a cascade of water into the building. The site is located next to a highway, so the security guards don’t hear the water flowing. The leak goes undetected until crews come back onsite on Monday morning. By that point, lower levels of the building have been inundated with thousands of gallons of water that has destroyed construction material, carpeting and electrical switchgear. It’s flowed into the elevator pits and mechanical room. Reprinted courtesy of Yaron Dycian, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Dycian may be contacted at yaron@wint.ai

Colorado Requires Builders to Accommodate High-Efficiency Devices in New Homes

December 14, 2020 — David M. McLain – Colorado Construction Litigation
Starting in 2009, the Colorado Legislature began adding requirements that builders offer certain options to accommodate high-efficiency devices. These requirements started with solar prewire options in 2009, then water-smart home options in 2010. In 2020, the Legislature added requirements for electric vehicle charging and heating systems. These sections apply to unoccupied homes serving as sales inventory or a model home or manufactured homes, as defined by Colorado law. While the Legislature has only required builders to include options to accommodate these devices, it may be just a matter of time until builders must install the prescribed devices themselves. In 2009, the Legislature passed C.R.S. 38-35.7-106, which was amended this year by HB 20-1155. As it now reads, Colorado law requires every builder of single-family detached residences to offer to have the home’s electrical or plumbing system, or both, include:

A residential photovoltaic solar generation system or a residential thermal system, or both;
Upgrades of wiring or plumbing, or both, planned by the builder to accommodate future installation of such systems; and
A chase or conduit, or both, constructed to allow ease of future installation of the necessary wiring or plumbing for such systems.

Read the court decision
Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell
Mr. McLain may be contacted at mclain@hhmrlaw.com

OSHA Again Pushes Back Record-Keeping Rule Deadline

November 30, 2017 — Tom Ichniowski - Engineering News-Record
The federal Occupational Safety and Health Administration is extending again—this time, by two weeks—the compliance date for its rule requiring companies to file annual electronic reports of workplace injuries and illnesses. Read the court decision
Read the full story...
Reprinted courtesy of Tom Ichniowski, ENR
Mr. Ichniowski may be contacted at ichniowskit@enr.com

Mitsui Fudosan Said to Consider Rebuilding Tilted Apartments

October 28, 2015 — Katsuyo Kuwako – Bloomberg
Mitsui Fudosan Co., Japan’s biggest developer, is considering rebuilding an apartment complex in Yokohama after one of the four buildings started to tilt, according to a person familiar with the situation. Kiyotaka Fujibayashi, president and chief executive officer of Mitsui Fudosan Residential Co., on Thursday explained the plans to residents, according to the person, who asked not to be named because the information is private. Another option the company is studying is buying back the apartments from the residents at a price higher than what they had paid, the person said. The project was sold in 2006. Mitsui Fudosan is the latest developer to come under scrutiny for defects at residential projects in the Tokyo area. Mitsubishi Estate Co., Japan’s biggest developer by market value, said last year it would rebuild a residential complex in the upscale Aoyama neighborhood after finding faults. Also last year, Sekisui House Ltd. said it would reconstruct a residential complex that was being built by Taisei Corp. after finding some columns were missing reinforcing metals. Read the court decision
Read the full story...
Reprinted courtesy of Katsuyo Kuwako, Bloomberg

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

The Colorado Court of Appeals Rules that a Statutory Notice of Claim Triggers an Insurer’s Duty to Defend.

October 23, 2012 — David M. McLain, Higgins, Hopkins, McLain & Roswell

Gene and Diane Melssen d/b/a Melssen Construction (“Melssen”) built a custom home for the Holleys, during which period of time Melssen retained a CGL insurance coverage from Auto Owners Insurance Company. Soon after completion of the house, the Holleys noticed cracks in the drywall and, eventually, large cracks developed in the exterior stucco and basement slab. Thereafter, the Holleys contacted Melssen, the structural engineer, an attorney, and Auto-Owners, which assigned a claims adjuster to investigate the claim.

In April 2008, the Holleys sent Melssen a statutory notice of claim pursuant to C.R.S. § 13-20-803.5 (“NOC”). In this NOC, the Holleys claimed approximately $300,000 in damages related to design and construction defects. The Holleys also provided a list of claimed damages and estimated repairs, accompanied by two reports from the Holleys’ consultant regarding the claimed design and construction defects. In June 2008, Melssen tendered the defense and indemnity of the claim to Auto-Owners. While Auto-Owners did not deny the claim at that time, it did not inspect the property or otherwise adjust the claim. Thereafter, in October 2008, Auto-Owners sent Melssen a letter denying coverage on the basis that the damage occurred outside of the applicable policy period.

Ultimately, Melssen settled the claims against it for $140,000.

Read the full story…

Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell, LLC. Mr. McLain can be contacted at mclain@hhmrlaw.com

Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES