Ten Firm Members Recognized as Super Lawyers or Rising Stars
September 16, 2019 —
Jonathan Schirmer - Ahlers Cressman & Sleight PLLCWhile we avoid using this blog as a platform for self-promotion, long-time readers will know we make an exception to recognize the Super Lawyers of the firm, each of whom is humbled to receive this peer-rated award.
Super Lawyers recognizes attorneys who have distinguished themselves in their legal practice as recognized by their peers. Attorneys are selected through a patented selection process combining peer nominations and independent research. Results are based on legal excellence, industry involvement, and civic leadership. Only five percent of lawyers in Washington State are selected for the honor of Super Lawyers, and no more than 2.5 percent are selected for the honor of Super Lawyers Rising Stars.
John P. Ahlers, one of the firm’s founding partners, was again recognized as one of the Top 10 Lawyers out of all Washington lawyers.
Founding partner Paul R. Cressman Jr. was again recognized as one of the 100-Best Lawyers considering Lawyers State of Washington wide.
In addition, four other firm members are also recognized as Super Lawyers: Founding Partner Scott R. Sleight, Brett M. Hill, Bruce A. Cohen, and Lawrence S. Glosser. Partners Ryan W. Sternoff and Lindsay (Taft) Watkins, and associates Ceslie A. Blass and Scott D. MacDonald are all recognized as Super Lawyer Rising Stars, which recognizes attorneys either 40 years old or younger, or in practice 10 years or less.
Read the court decisionRead the full story...Reprinted courtesy of
Ahlers Cressman & Sleight PLLC
Late Progress Payments on Local Public Works Projects Are Not a Statutory Breach of Contract
May 10, 2022 —
Ted Senet & Christopher Trembley - Gibbs GidenCalifornia local public agencies and their contractors should take note of a recent appellate decision pertaining to late progress payments on public works projects. In Clark Bros., Inc. v. North Edwards Water Dist., 2022 Cal. App. LEXIS 331, filed on April 22, 2022, the Court of Appeal for the Fourth Appellate District held that a local agency’s late progress payments to a general contractor did not constitute breach of contract under the prompt payment penalty statute, Public Contract Code § 20104.50. Notwithstanding this holding, the contractor recovered damages, interest, fees, and costs in excess of its contract amount.
In 2013, the North Edwards Water District awarded a $6.2 million contract to Clark Bros., Inc. to construct a water treatment facility. The District’s water contained excessive levels of arsenic, and the project was sponsored by the State of California with funds earmarked to provide safe drinking water. The State agreed to disburse funds to the District during construction upon the State’s review and approval of the contractor’s progress payment applications. The contract required completion of the work within one year following the District’s issuance of a notice to proceed to the contractor.
As a result of factors arguably outside the control of the contractor, including unforeseen site conditions and the failure of the District’s equipment supplier to meet delivery deadlines, the project was significantly delayed beyond the deadline for completion. The District nonetheless terminated the contractor, which in turn filed suit against the District and the State. The contractor asserted claims for breach of contract, including breach of contract for the District’s failure to pay the contractor’s progress payment applications within the time specified under Public Contract Code § 20104.50. Subsection (b) of the statute provides:
Any local agency which fails to make any progress payment within 30 days after receipt of an undisputed and properly submitted payment request from a contractor on a construction contract shall pay interest to the contractor equivalent to the legal rate set forth in subdivision (a) of Section 685.010 of the Code of Civil Procedure.
Reprinted courtesy of
Ted Senet, Gibbs Giden and
Christopher Trembley, Gibbs Giden
Mr. Senet may be contacted at tsenet@gibbsgiden.com
Mr. Trembley may be contacted at Ctrembley@gibbsgiden.com
Read the court decisionRead the full story...Reprinted courtesy of
Denver’s Proposed Solution to the Affordable Housing Crisis
March 06, 2022 —
Taylor Ostrowski - Colorado Construction Litigation BlogOver the past ten years, Colorado has seen a population growth of almost 15 percent, with many residing in Denver. In fact, in 2020, Denver ranked among the top five cities for inbound growth in the United States. At the same time, from 2010 through 2020, the state’s production of new housing decreased by 40 percent. The decrease in supply, coupled with the increase in demand has exasperated the already rising cost of housing in the state. This, along with other external factors such as job loss due to the COVID pandemic, has resulted in a statewide housing crisis.
The City of Denver is proposing a revision to the municipal code that would expand affordable housing through three main tools: (1) increasing “linkage fees,” (2) requiring new multi-family development to designate a percentage of units to be affordable, and (3) offering zoning and financial incentives. The proposal addresses both rental housing and ownership opportunities. Although it is essential to combat the housing crisis and increased homelessness in the region, it is equally important to understand the impacts the proposed affordable housing ordinance would have on developers, if and when enacted.
Read the court decisionRead the full story...Reprinted courtesy of
Taylor Ostrowski, Higgins, Hopkins, McLain & Roswell, LLCMs. Ostrowski may be contacted at
ostrowski@hhmrlaw.com
New Hampshire Applies Crete/Sutton Doctrine to Bar Subrogation Against College Dormitory Residents
May 17, 2021 —
Kyle Rice - The Subrogation SpecialistPursuant to the Sutton Doctrine, first announced in Sutton v. Jondahl, 532 P.2d 478 (Okla. Ct. App. 1975), some jurisdictions consider a tenant a coinsured of its landlord absent an express agreement to the contrary. In Ro v. Factory Mut. Ins. Co., No. 2019-0620, 2021 N.H. LEXIS 34 (Mar. 10, 2021), the Supreme Court of New Hampshire held that the Sutton Doctrine, adopted by New Hampshire in Cambridge Mut. Fire Ins. Co. v. Crete, 846 A.2d 521 (N.H. 2004), extends to resident students in a college dormitory. Thus, absent specific language to the contrary, a student is an implied coinsured under the fire insurance policy issued for his or her dormitory.
In 2016, two students at Dartmouth College, Daniel Ro and Sebastian Lim, set up a charcoal grill on a platform outside of a fourth-floor window in the Morton Hall dormitory. The grill started a fire on the platform that ultimately spread to the roof of the dormitory. During fire suppression efforts, all four floors of the dormitory sustained significant water damage. Following the loss, the building’s insurer, Factory Mutual Insurance Company (Insurer), paid $4,544,313.55 to the Trustees of Dartmouth College for the damages.
Read the court decisionRead the full story...Reprinted courtesy of
Kyle Rice, White and WilliamsMr. Rice may be contacted at
ricek@whiteandwilliams.com
Wildfire Risk Scores and Insurance Placement: What You Should Know
July 15, 2024 —
Louis "Dutch" Schotemeyer & Molly L. Okamura - Newmeyer DillionWhat Are Wildfire Risk Scores and How Are They Calculated?
Wildfire risk scores are scores assigned to properties by third-party vendors based on the likelihood of direct or indirect exposure to a wildfire. Wildfire risk scores can be a factor used by insurance companies when making coverage decisions. Additionally, wildfire risk scores can be a helpful metric for real estate developers to consider when determining whether to buy a piece of property.
There are a variety of vendors that use unique methods to calculate wildfire risk scores. For example, CoreLogic, FireLine, and RedZone are vendors used by insurance companies in California. Some vendors' scoring scales are from 1-10, and some are from 1-100, but generally the higher the score, the higher the likelihood of a wildfire impacting the property. There is no national, standardized scoring scale.
Reprinted courtesy of
Louis "Dutch" Schotemeyer, Newmeyer Dillion and
Molly L. Okamura, Newmeyer Dillion
Mr. Schotemeyer may be contacted at dutch.schotemeyer@ndlf.com
Ms. Okamura may be contacted at molly.okamura@ndlf.com
Read the court decisionRead the full story...Reprinted courtesy of
Five Actions Construction and Energy Risk Managers Can Take to Avoid the Catastrophic Consequences of a Cyber Attack
June 27, 2022 —
Eve-Lynn Gisonni - Saxe Doernberger & VitaWith the ever-increasing usage of technology in the construction and energy industries, risks to business operations have also increased. Property developers and construction contractors rely on electronic data and communications more than ever to streamline projects, ensure efficient and timely supply chain delivery, and facilitate immediate communications between parties. However, with this dependence upon technology comes the heightened risk of cyber criminals frustrating construction operations and driving up costs.
Similarly, as the energy sector has grown more dependent upon online networks for deliverables, vulnerabilities have become more pronounced in trades dependent upon electrical grids. When an entire electricity network must be taken offline in defense of a cyber-attack, this impacts countless industries such as hospitals and health care operations, manufacturers and suppliers, and local and interstate traffic systems.
Read the court decisionRead the full story...Reprinted courtesy of
Eve-Lynn Gisonni, Saxe Doernberger & VitaMr. Gisonni may be contacted at
EGisonni@sdvlaw.com
Nevada Supreme Court Holds That Insureds Can Use Extrinsic Evidence to Prove Duty to Defend
February 28, 2022 —
Bethany L. Barrese - Saxe Doernberger & VitaThe recent Nevada Supreme Court ruling in Zurich American Insurance Company v. Ironshore Specialty Insurance Company1 benefits insureds seeking to establish an insurer’s duty to defend. As a matter of first impression, the court clarified that insureds have the burden to prove that an exception to a policy exclusion applies in order to trigger the insured’s duty to defend. However, while the policyholder may use extrinsic evidence to establish the insurer’s duty to defend, the insurer may not use extrinsic evidence to deny that duty.
The facts of the underlying claim are set in the 2000s when the insured subcontractors worked to build thousands of homes in Nevada. The subcontractors were insured by Zurich American Insurance Company (“Zurich”) during that period. After the homes were complete, the subcontractors switched from Zurich to Ironshore Specialty Insurance Company (“Ironshore”). Between 2010 and 2013, homeowners brought claims against the subcontractors alleging that the properties were damaged due to construction defects. The subcontractors tendered the claims to Zurich as the insurer at the time of construction. Zurich then sought defense and indemnification from Ironshore. Ironshore denied coverage under a “continuing and progressive” policy exclusion, claiming that the property damage occurred due to faulty work that predated the Ironshore policy. Notably, an exception to the exclusion applied if “sudden and accidental” property damage occurred within the Ironshore policy period. Given that the underlying lawsuits did not include specific allegations describing when or how the property damage occurred, Ironshore and Zurich disagreed on whether the exception to the exclusion was triggered..
Read the court decisionRead the full story...Reprinted courtesy of
Bethany L. Barrese, Saxe Doernberger & VitaMs. Barrese may be contacted at
BBarrese@sdvlaw.com
Hirers Must Affirmatively Exercise Retained Control to be Liable Under Hooker Exception to Privette Doctrine
September 12, 2023 —
Garret Murai - California Construction Law BlogDon’t drink and drive people. I mean seriously. It’s been over 40 years since California native Candace Lightner formed
Mothers Against Drunk Driving in 1980 after her 13-year-old daughter, Candace, was killed by a drunk driver who later served just 9 months in jail before getting out and getting into his sixth (yes, sixth) drunk driving accident. It hurts the victims and their families, makes a mess for the offender (and their family), and, as the next case,
Marin v. Department of Transportation, 88 Cal.App.5th 529 (2023), illustrates, can needlessly draw out the pain as the victim’s family seeks financial recourse for their emotional loss from others.
Miguel Angel Rodriguez De La Cruz, a highway construction worker, was killed by a drunk driver. I’m not sure what his family did on the legal front after his death – perhaps sued the drunk driver – but among possible others they sued the California Department of Transportation. And they lost. Although there is no such thing as “winning” and “losing” in these types cases. It’s just losing and losing.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
