How Does Your Construction Contract Treat Float
November 08, 2017 —
David Adelstein - Florida Construction Legal UpdatesAlthough there are different types of construction schedule float and more technical definitions, the definition that makes sense to me is that float is the amount of time a particular activity can be delayed without that activity delaying the project’s completion date (substantial completion date). In looking at a construction schedule, this determination is made from looking at the difference between the early start date for an activity and the late start date for that activity or the difference between the early finish date for that activity and the late finish date for that activity in your CPM schedule (which should be the same amount of time). This is often referred to as “total float” and is the float that I usually focus on since it may pertain to a delay to the substantial completion date of the project and can trigger either the assessment of liquidated damages and/or the contractor’s extended general conditions, whatever the case may be.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Florida Construction Legal UpdatesMr. Adelstein may be contacted at
Dadelstein@gmail.com
Your “Independent Contractor” Clause Just Got a Little Less Relevant
January 12, 2015 —
Garret Murai – California Construction Law BlogConstruction projects are complex, multi-partied, multi-disciplinary endeavors, in which subcontracting all or a portion of the work to be performed is not uncommon.
When subcontracting work, parties usually make it clear in their contracts that the party performing work is acting as an “independent contractor.” Here’s a fairly typical provision from the AIA A201 General Conditions:
The parties agree that the contractual relationship on Contractor to Owner is one solely of an independent contractor in all respects and that the Contract Documents do not in any way create a partnership, joint venture or any other relationship between Owner and Contractor other than the contractual relationship as specified in this Agreement.
These provisions are intended to shield the contracting party from claims that it is responsible for workers’ compensation premiums, retirement contributions, health care insurance, or other benefits provided for the benefit of employees of the company performing the work. Fair enough.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Wendel Rosen Black & Dean LLPMr. Murai may be contacted at
gmurai@wendel.com
Sustainability Puts Down Roots in Real Estate
January 27, 2020 —
Stephanie Amaru - Gravel2Gavel Construction & Real Estate Law BlogSustainability has evolved from a passing trend or niche preference into an undeniable, growing driver of the real estate market. This is particularly true as millennials comprise an increasing proportion of the workforce, home-buying population, and individuals influencing the future of real estate development in the United States.
If anything illustrates the significance of younger generations’ increasing interest in sustainability, it is the Global Climate Strike that drew participation of many thousands of young people, with 2,500 events scheduled in over 150 countries. In New York City, 1.1 million public school students were excused from school to join the strike in an event planned to precede the UN Summit, which itself was intended to push countries toward a commitment to faster transition to renewable energy and stricter climate targets. While both policymakers and citizens of previous generations have been split on their willingness to address global climate change with urgency, younger generations are feeling a stronger sense of responsibility for curbing the world’s trajectory towards a climate catastrophe, which will be inherited by them and their children. This has manifested in action that promotes awareness of and political action with respect to these issues—such as the Global Climate Strike—as well as evolving habits and preferences in both consumer goods and real estate.
Greener Space
In recent years, real estate developers have recognized that there is a market for “greener” developments that reduce annual expenditures on buildings, whether it be through small spaces requiring less electricity and promoting energy efficiency, or through renewable energy options such as solar photovoltaic power. Some real estate developers have chosen to install these options themselves, while others seek out sustainable financing options to cover the costs of renewable energy. If installing renewable energy is too costly, real estate developers will seek out more cost-effective locations for their brick-and-mortar operations.
Read the court decisionRead the full story...Reprinted courtesy of
Stephanie Amaru, PillsburyMs. Amaru may be contacted at
stephanie.amaru@pillsburylaw.com
Federal Court in New York Court Dismisses Civil Authority Claim for COVID-19 Coverage
October 11, 2021 —
Eric D. Suben - Traub LiebermanCourts nationwide have been grappling with coverage for business interruption claims arising from closures occasioned by the COVID-19 pandemic, with mixed results by jurisdiction. A recent decision on the issue from the federal Southern District of New York sheds light on New York law regarding this pressing issue.
In Elite Union Installations, LLC v. National Fire Insurance Company of Pittsburgh, PA, 2021 WL 4155016 (Sept. 13, 2021), directives issued by governmental authorities required the insured construction company to shut its doors, leading to a layoff of some employees while others continued to work from home. The insured made a claim under its commercial property coverage for damage to its premises, which it claimed were rendered “uninhabitable” and required repair in the form of alterations to comply with social distancing requirements. In the ensuing coverage litigation, National Union moved to dismiss the complaint alleging covered first-party property damage defined in the policy as “direct physical loss of or damage to property.”
Read the court decisionRead the full story...Reprinted courtesy of
Eric D. Suben, Traub LiebermanMr. Suben may be contacted at
esuben@tlsslaw.com
Litigation Counsel of America Honors Partner Victor Anderson with Peter Perlman Award
November 10, 2016 —
Victor R. Anderson, III – Haight Brown & Bonesteel LLPPartner Victor R. Anderson, III received the Peter Perlman Service Award in recognition of his efforts to improve the lives of others through his community service and charity work. The awards are presented to select attorneys throughout the year by the Litigation Counsel of America (LCA) to candidates whose exemplary contributions merit commendation.
The Litigation Counsel of America is a close-knit, peer-selected, and aggressively diverse honorary society of 3,500 of the best trial lawyers. Less than one-half of one percent of American lawyers, vigorously vetted for skills, expertise, and service are invited to be on the Counsel.
Read the court decisionRead the full story...Reprinted courtesy of
Victor R. Anderson, III, Haight Brown & Bonesteel LLPMr. Anderson may be contacted at
vanderson@hbblaw.com
Clearly Determining in Contract Who Determines Arbitrability of Dispute
April 26, 2021 —
David Adelstein - Florida Construction Legal UpdatesAs you know from prior postings: “Arbitration provisions are creatures of contract and must be construed ‘as a matter of contract interpretation.’ ” Fallang Family Limited Partnership v. Privcap Companies, LLC, 46 Fla.L.Weekly D639e (Fla. 4th DCA 2021) (citation omitted). Thus, if you prefer to arbitrate potential disputes, instead of litigating potential disputes, you want to include an arbitration provision in your contract. While there are positives and negatives to arbitration, no different than litigation, these positives and negatives should be considered during the contract negotiation process when dealing with the dispute resolution process in the contract.
Generally, under the law, the arbitrability of a dispute is determined by the court. However, this can be deferred to the arbitrator with clear and unmistakable language in the contract.
By way of example, the American Arbitration Association includes a rule that allows an arbitrator to rule on the arbitrability of the dispute, i.e., the claims asserted are subject to the governing arbitration provision in the contract. Recent law has suggested that if the objective is to authorize an American Arbitration Association arbitrator to make this determination, the contract clearly and unmistakably needs to state this intent and generally referring to the American Arbitration Association rules is not good enough. For this reason, I have included in arbitration provisions language that specifically states, “In the event of any dispute as to the arbitrability of any claim or dispute, the parties agree that an appointed arbitrator within the American Arbitration Association shall make this determination.” I have also included in arbitration provisions the converse so that if there is a dispute as to the arbitrability of a claim or dispute, the court, and not the arbitrator, will make this determination.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Testimony from Insureds' Expert Limited By Motion In Limine
October 21, 2015 —
Tred R. Eyerly – Insurance Law HawaiiThe court considered the scope of testimony to be offered by the insureds' expert regarding a policy written for sanitation districts. Binghamton-Johnson City Joint Sewage Bd. v. Am. Alternative Ins. Corp., 2015 U.S. Dist. LEXIS 112210 (N.D. N.Y. Aug. 25, 2015).
The city of Binghamton and the city's Sewage Board sued American Alternative Insurance Corporation (AAIC) for coverage for a collapsed wall. AAIC sought the limit to testimony of the insureds' expert, Paul B. Nielander, through a motion in limine.
AAIC argued that Nielander was not qualified as an expert in interpreting insurance policies. His knowledge and experience was limited to insurance practices in other states and the words contained in policies other than AAIC policies. He had no experience with (i) negotiating, drafting, or performing under an AAIC policy, (ii) handling claims or interpreting policies written in New York State, or (iii) drafting policies or otherwise participating in what he conceded was a "niche market" of providing insurance to sanitation districts. Further, Neilander was not qualified to offer expert analysis of when the structural failure of the wall occurred because he had no training or experience as an engineer.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
U.S. Supreme Court Oral Arguments: Maritime Charters and the Specter of a New Permitting Regime
February 24, 2020 —
Anthony B. Cavender - Gravel2GavelEarlier this month, the Supreme Court heard oral arguments in two important environmental cases—one that could change the approach to routine maritime charters and another that could introduce a potentially punishing permitting regime via a CWA citizen suit.
Cleaning the Delaware: CITGO Asphalt Refining Company v. Frescati Shipping Company
The CITGO case involves a large oil spill into the Delaware River, and who bears financial responsibility for the cleanup. CITGO chartered an oil tanker to bring Venezuelan crude oil to CITGO’s New Jersey refinery located on the Delaware River. The tanker struck a submerged and abandoned anchor within yards of the refinery, and a large and expensive oil spill resulted. In accordance with the Oil Pollution Act, both the shipper, Frescati Shipping Company, and the United States, paid for the immediate oil spill response, and CITGO was later sued for a large share of these costs based on the fact that it entered into a charter with Frescati, which obliged CITGO to provide a “safe berth.” The U.S. Court of Appeals for the Third Circuit held that CITGO was liable under the principles of maritime law, meaning that CITGO was strictly liable for the spill even if no one knew that the anchor was present on the floor of the river or lurking in the waters of the Delaware River. CITGO has argued that this result is unfair and poses a threat to the maritime shipping industry if it is held to be strictly liable for this spill. It appears that this is may well be the majority rule that is applied when interpreting these routinely entered maritime charters. The Court’s decision will be immensely important to the shipping industry.
Read the court decisionRead the full story...Reprinted courtesy of
Anthony B. Cavender, PillsburyMr. Cavender may be contacted at
anthony.cavender@pillsburylaw.com
