Fairfield Connecticut Building Expert Directory

Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season

January 13, 2020 — David Adelstein - Florida Construction Legal Updates
There are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be. For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:

[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season. Meridian Engineering, 2019 WL at *7 (internal citations omitted)

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Why Should Businesses Seek Legal Help Early On?

December 03, 2024 — Scott L. Baker - Los Angeles Litigation Blog
Most business owners are natural problem solvers. They assess the issue that lies before them and develop a strategy to overcome it. It’s a critical mindset to have, but do all business owners have the skillset to solve every issue? While it is understandable that business owners may want to attempt to resolve issues on their own, it is invariably beneficial to obtain guidance for legal issues earlier rather than later. 3 Reasons to Consult an Attorney Sooner than Later Many people might consider working with an attorney to be a last resort. Typically, this is not the case; rather, getting knowledgeable legal counsel sooner than later can help business owners because:

It’s Cheaper: Early legal intervention can often prevent disputes from leading to litigation, which can be expensive. Working with an attorney to resolve a conflict before it escalates into a larger issue is often a good business decision and wise investment.

Read the court decision
Read the full story...
Reprinted courtesy of Scott L. Baker, Baker & Associates
Mr. Baker may be contacted at slb@bakerslaw.com

The Buck Stops Over There: Have Indemnitors Become the Insurers of First and Last Resort?

September 17, 2015 — Garret Murai – California Construction Law Blog
Insurance and indemnity are the primary risk management strategies on construction projects. Insurance, such as commercial general liability insurance, insures against third party claims for bodily injury and property damage, and in the case of builder’s risk insurance, insures against first party claims during construction. Indemnity, on the other hand, shifts liability from one party to another and can be broader than the types of claims covered by insurance although anti-indemnity statutes can limit the breadth of those claims. Sometimes though insurance and indemnity work in ways you might never have expected, like in the next case, Valley Crest Landscape Development, Inc. v. Mission Pools of Escondido, Inc., Case No. G049060 (July 2, 2015), in which the California Court of Appeals for the Fourth District held a subcontractor liable in the face of both an indemnity claim brought by a general contractor as well as a subrogation claim brought by the general contractor’s insurance company. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Clean Water Act Cases: Of Irrigation and Navigability

January 06, 2020 — Anthony B. Cavender - Gravel2Gavel
The federal courts have recently decided two significant Clean Water Act (CWA) cases: State of Georgia, et al. v. Wheeler, where the US District Court for the Southern District of Georgia held that the 2015 rulemaking proceeding of EPA and the U.S. Army Corps of Engineers redefining the term “Waters of the United States” in the CWA violated the Act as well as the Administrative Procedure Act; and the Ninth Circuit’s decision in Pacific Coast Federation of Fishermen’s Associations, et al. v. Glaser, where the appeals court ruled that the lower court erroneously interpreted a CWA NPDES permitting exception involving agricultural return flows. An Absence of Navigability: State of Georgia, et al. v. Wheeler Decided on August 21, 2019, the district court, one of the few courts to grapple with the rule’s compliance with the CWA and the Administrative Procedure Act (APA), held that the agencies’ redefinition of the terms “Interstate Waters,” “Tributaries” and “Adjacent Waters” violated the CWA by reading “navigability” out of the new definitions, or by failing to adhere to the Supreme Court’s rulings in the 2005 case of Rapanos v. United States, in particular Justice Kennedy’s concurrence regarding the application of the “significant nexus” in case-by-case adjudications as to whether a particular body of water was covered by the Act. Moreover, some provisions of the rule conflicted with the APA because they were not a logical outgrowth of the rules proposed by the agencies in 2014, and on which they solicited comments, and other determinations were not supported by a reasonable explanation. In addition, without a clear statement from Congress that it supported the rule’s effect of increasing the nature and extent of enhanced federal jurisdiction over waters subject to the CWA, the court was loathe to approve the rule. Accordingly, the rule was remanded to the agencies for additional review consistent with this decision. This decision is of particular importance as it may well be the first case to subject this new EPA rule—the linchpin of much of EPA’s regulation under the CWA—to extended review. (Other courts have only been asked to enjoin the rule, which involves a different type of review.) Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

OSHA Again Pushes Back Record-Keeping Rule Deadline

November 30, 2017 — Tom Ichniowski - Engineering News-Record
The federal Occupational Safety and Health Administration is extending again—this time, by two weeks—the compliance date for its rule requiring companies to file annual electronic reports of workplace injuries and illnesses. Read the court decision
Read the full story...
Reprinted courtesy of Tom Ichniowski, ENR
Mr. Ichniowski may be contacted at ichniowskit@enr.com

Connecticut Supreme Court to Review Several Issues in Asbestos Coverage Case

November 08, 2017 — Ciaran Way & Robert F. Walsh – White and Williams LLP
On October 18, 2017, in R.T. Vanderbilt Company v. Hartford Accident & Indemnity Company, the Connecticut Supreme Court certified four issues for appeal, which relate to trigger, allocation, pollution exclusions, and the occupational disease exclusion in the context of asbestos bodily injury claims. This post identifies the issues the Connecticut Supreme Court will decide on appeal and sets forth the Appellate Court’s ruling on each issue. Issue 1: Whether a “continuous trigger” theory of coverage applies to asbestos-related disease claims and whether expert medical testimony on the timing of injury should be precluded The Appellate Court applied a continuous trigger, and found that the trial court properly excluded testimony from medical experts the insurers had proffered to prove that the asbestos disease process did not support a continuous trigger. Reprinted courtesy of Ciaran Way, White and Williams LLP and Robert Walsh, White and Williams LLP Ms. Way may be contacted at wayc@whiteandwilliams.com Mr. Walsh may be contacted at walshr@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Colorado Passes Compromise Bill on Construction Defects

May 03, 2017 — Jesse Witt - The Witt Law Firm
After four failed attempts, Colorado legislators have finally reached a compromise on construction defect legislation. This afternoon, HB17-1279 gained unanimous approval from the House Committee on State, Veterans, and Military Affairs. The bill is expected to pass both chambers easily and be signed into law by Governor John Hickenlooper. Proponents say that a bill is needed spur more condominium construction in the state. They contend that homebuilders have been reluctant to construct multifamily projects in recent years based on a perceived fear that small groups of homeowners can file lawsuits in the name of their community associations without adequate the consent of other members. A 2013 study found that quality control and insurance costs only reduce homebuilder profits by a small amount, but concerns about litigation have nevertheless prompted some construction professionals to focus on constructing apartments and other products. Reprinted courtesy of Jesse Howard Witt, Acerbic Witt Mr. Witt may be contacted at www.witt.law Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Ruling Finds Builder and Owners at Fault in Construction Defect Case

December 30, 2013 — CDJ STAFF
A Minnesota home owners association has been found 30liable for some of the damage to their homes in a jury trial. The Interlachen Propertyowners Association made a claim of construction defects against Keupers Architects and Builders who had constructed the 24-unit town home complex. According to the association’s lawyer, the half-log siding was improperly installed, leading to water intrusion and rot. The jury did find for the homeowners on the construction defect claim, but found on a claim of negligent repairs that the association was 30% at fault, due to insufficient maintenance of the building. “We don’t think any amount of maintenance would have saved these buildings,” said Jason Tarasek, the lawyer for the association. The association is likely to appeal. Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES