Not So Fast, My Friend: Pacing and Concurrent Delay
April 25, 2022 —
William E. Underwood - ConsensusDocsWhen critical path activities are delayed by the owner (or another party), contractors will sometimes “pace,” or slow down, other activities to match the owner-caused delay. After all, why should the contractor hurry up and wait? But paced activities can often appear as concurrent delays on a project’s overall schedule. And all too often, contractors fail to contemporaneously document their efforts to pace work. Not only can this create avoidable disputes with owners and other contractors, but it can also create future roadblocks to the recovery of delay damages. This article examines the interplay between pacing and concurrent delay[1] and what contractors should do to minimize risk and preserve their rights to obtain more than a simple time extension for project delays.
Pacing versus Concurrent Delay
As a basic matter, most contracts allocate responsibility/liability for a schedule delay to the party that caused the delay. For example, if an owner is contractually required to provide equipment for a contractor to install, then the owner likely bears responsibility for any delays caused if the equipment is delivered late. If, however, the contractor was also behind schedule on other activities during this time and the project would have been delayed regardless of the owner’s late deliveries, then the delay is probably concurrent. And the contractor will generally be entitled to only an extension of time, and no other monetary relief.
Read the court decisionRead the full story...Reprinted courtesy of
William E. Underwood, Jones Walker LLP (ConsensusDocs)Mr. Underwood may be contacted at
wunderwood@joneswalker.com
White and Williams LLP Secures Affirmation of Denial to Change Trial Settings Based on Plaintiffs’ Failure to Meet the Texas Causation Standard for Asbestos Cases
July 06, 2020 —
Christian Singewald & Rochelle Gumapac - White and Williams LLPThe Delaware Supreme Court, in a rare split opinion, affirmed the trial court’s denial of Plaintiffs’ Request to Change Trial Settings in favor of all defendants, including a major automotive manufacturer represented by White and Williams LLP, in a mesothelioma case with a young decedent who had an alleged economic loss claim exceeding $9,000,000, in Shaw v. American Friction, Inc. et al., No. 86, 2019. This decision operates to dismiss all of Plaintiffs’ claims based on their failure to meet Delaware’s strict expert deadlines and establish a prima facie case under Texas law.
Plaintiffs’ Complaint invoked the application of Texas substantive law and alleged that multiple manufacturers were negligent and strictly liable for failing to warn the decedent of the alleged dangers posed by the use of asbestos-containing products. Plaintiffs’ alleged asbestos exposures from defendants’ products caused Mr. Shaw’s disease and subsequent death.
In 2007, Texas instituted its now well-known causation requirement, which requires the “dose” of asbestos exposure from each defendant’s products to be quantified by an expert. Borg-Warner Corp. v. Flores, 232 S.W.3d 765, 773 (Tex. 2007). Prior to decedent’s death, Plaintiffs’ counsel deposed decedent and his father for product identification purposes. During the depositions, Plaintiffs’ counsel failed to obtain the necessary factual information from his clients for an expert to be able to opine as to alleged exposure doses from any defendant’s product. Despite lacking the requisite information for a prima facie case under Texas law, Plaintiffs sought and were given placement in an expedited trial setting, which had strict, defined deadlines.
Reprinted courtesy of
Christian Singewald, White and Williams LLP and
Rochelle Gumapac, White and Williams LLP
Mr. Singewald may be contacted at singewaldc@whiteandwilliams.com
Ms. Gumapac may be contacted at gumapacr@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
Norristown, PA to Stop Paying Repair Costs for Defect-Ridden Condo
February 10, 2014 —
Beverley BevenFlorez-CDJ STAFFThe city of Norristown, Pennsylvania has already paid “$3.4 million for construction repairs and legal expenses” for the 26-unit condominium on 770 Sandy Street, according to The Times Herald. Therefore city officials recently declared that “they will no longer pay the $40,000 annual cost for maintenance, electricity and repairs” for the building.
“At some point, the folks that own it have to step up and take responsibility for it,” Norristown Council President William Caldwell told The Times Herald. “No later than February 28, the municipality will cease to provide or pay for maintenance of 770 Sandy Street.”
Previously, Norristown had received court orders to repair the building, after numerous construction defects turned up including “missing firestops in numerous walls, missing grout and steel rebar in block-wall, emergency stair towers, faulty electrical wiring and no provision for firestopping in the first-floor garage ceiling.” City officials “were faulted by Montgomery County Common Pleas Court judges for not properly inspecting the construction.”
Charles Madracchia, past Customers Bank attorney and current Homeowner attorney, is “continuing active litigation in both federal and state court.”
Read the court decisionRead the full story...Reprinted courtesy of
Single-Family Home Starts Seen Catching Up to Surging U.S. Sales
May 07, 2015 —
David Wilson – BloombergNew single-family houses are selling fast enough in the U.S. that homebuilders will have to pick up the pace of starting them, according to Neil Dutta, head of U.S. economics at Renaissance Macro Research LLC.
The attached chart compares annual growth rates in sales and starts, as compiled by the Commerce Department, during the past 25 years. The top panel shows the rates, while the bottom panel tracks the percentage-point gap between then.
Last month’s sales of one-family homes totaled 510,000 at an annual rate, according on the average estimate of economists in a Bloomberg survey. The projection amounts to a 26.6 percent increase from a year ago. Builders began working on 2.7 percent fewer homes in March, according to data released yesterday. The 29.3-point differential would be the widest since July 1995.
Read the court decisionRead the full story...Reprinted courtesy of
David Wilson, BloombergMr. Wilson may be contacted at
dwilson@bloomberg.net
Solar Energy Isn’t Always Green
August 27, 2014 —
Beverley BevenFlorez-CDJ STAFFIEEE Spectrum reported that photovoltaics, used in Solar Energy, “varies substantially by technology and geography” and some emit chemical pollution. However, IEE Spectrum stated that “the industry could readily eliminate many of the damaging side effects that do exist.”
One challenge is that “nearly half the world’s photovoltaics are manufactured in China” who, according to IEEE Spectrum, “typically [does] the worst job of protecting the environment and their workers.”
It is also difficult for consumers to make choices based upon photovoltaic manufacturer practices, since solar energy doesn’t have a formal ecolabel like Energy Star, IEEE Spectrum reported.
Read the court decisionRead the full story...Reprinted courtesy of
Steps to Curb Construction Defect Actions for Homebuilders
June 15, 2017 —
Jason Daniel Feld – Kahana & Feld, LLPThe homebuilding and construction industries in California are at a record high in 2017 according to the National Homebuilders Association. While there is finally prosperity and growth for builders, developers and contractors after suffering from the recession of 2008, there is also a growth in construction defect claims. As with every industry and especially with construction, there are several risk prevention methods that can help curb this litigation.
Time Frames for Pursuing Construction Defect Claims
It is important to know and understand the time frames for which construction defect claims can be pursued by homeowners. There is a hard cut-off for construction defect litigation in California known as the Statute of Repose of 10 years. California Code of Civil Procedure (“CCP”) §337.15 provides a statute of repose that bars actions to recover damages for construction defects more than 10 years after substantial completion of the work of improvement. This provision is limited to property damage claims and does not extend to personal injuries (See, Geertz v. Ausonio, 4 Cal.App.4th 1363 (1992) and willful misconduct or fraudulent concealment claims. (See, Acosta v. Glenfed Development Corp., 128 Cal.App. 4th 1278 (2005).
There are also interim statutes of limitations for “patent” and “latent” defects discovered at the home also from the date of substantial completion. CCP §337.1(e) provides for a four year window to bring suit for deficiencies that are apparent by reasonable inspection (patent deficiencies). CCP §337.15(b) provides for deficiencies that are not apparent by reasonable inspection or hidden defects that require invasive testing to become apparent (latent deficiencies). A latent defect can become patent after it “manifests itself” (i.e. becomes observant – for example a roof leak) for which the four year window from the date of discovery would become the applicable statute of limitations.
The discovery rule effectively acts to toll the statute of limitation period on construction defect claims until they become reasonably apparent. (See, Regents of the University of CA v.Harford Accident & Indemnity, Co., 21 Cal.3d 624, 630 (1978). This is similar to a breach of contract claim, also a four year statute of limitation. Finally, the California Right to Repair Statute (SB800) – Civil Code §§895, et seq. specifically Civil Code §896 sets forth the “Functionality Standards” or a list of actionable defect items, including items affecting the component’s “useful life” and a catch-all provision for all items not expressed listed as defects in the statute. (Civil Code §897). The majority of the defects alleged have a 10 year statute of limitations. However, there are shortened statute of limitations for the following items:
| Functionality Standards | Statute of Limitations |
|---|
| Noise Transmission |
1 year from original occupancy of adjacent unit |
| Irrigation |
1 year from close of escrow |
| Landscaping Systems & Wood Posts (untreated) |
2 years from close of escrow |
| Electrical systems, pluming/sewer systems, steel fences (untreated), flatwork cracks |
4 years from close of escrow |
| Paint/Stains |
5 years from close of escrow |
| All other functionality standards (Civil Code §941(a)) |
10 years after substantial completion(date of recordation of valid NOC) |
Preventative Measures to Curb Construction Defect Litigation
Once the builder knows the time frames for construction defect claims, the following are some preventive measures to limit construction defect claims. As a reminder, homeowners are less likely to bring construction defect action if they feel that the builders are taking care of them.
1. Communicate With Homeowners Prior to Claims
It is imperative to communicate with the homeowners throughout the ten years statute of repose period. For example, most builders provide a limited warranty to the homeowners at the time of purchase. Homeowners are generally confused as to the length of the warranty and what the warranty covers. A practical tip to help curb construction defect claims is for the builder to send postcards or letters to the homeowners at the six month, one year and nine-year marks to advise the homeowner of: (1) the existence of the warranty and what is covered at each time frame; (2) the maintenance obligations of the homeowner at the various time frames; and (3) the fact that the home is approaching the ten-year mark. Most builders would rather deal directly with the homeowners through customer service than defend a construction defect litigation action where the costs to defend the claim will vastly exceed the cost to address the individual homeowner issues. The more the builder communicates with the homeowner in advance, the less likely it is that the homeowner engages in litigation against the builder.
2. Timely Response to Homeowner Claims
During the purchase process, provide the homeowners instructions on how to send in a customer service or warranty requests. Provide multiple methods for notification to the builder by the homeowner when issues arise in their home (fax, email, website forms, etc.). The builder should provide a timely response – within 48 hours of the notice if possible. The homeowner wants to receive some notification from the builder that they received their request and, at the very least, will investigate the claim. Even if it is determined to be a maintenance item or homeowner caused damage, the homeowner should receive: (1) an acknowledgement of the claim; (2) an investigation report of the issue; and (3) an action plan or conclusion statement – this can be a declination of repairs with an explanation as to the cause not being the result of original construction. Sometimes even sending a customer service representative to the home to listen to the homeowner claims and explaining that there are not repairs required is sufficient to satisfy the homeowner. The goal is to make sure the homeowner’s claims are acknowledged and that the builder is standing behind its product. In my experience, the fact that the builder failed to respond in a timely fashion to the homeowner is a significant motivating factor as to why the homeowner elected to enter formal litigation against the builder.
3. Be Proactive When Litigation Ensues Despite the fact that the homeowner has engaged an attorney and joined a construction defect action, the builder is not precluded from continuing to communicate with its homeowners. Several builders send letters to the non-plaintiff homeowners reminding them to contact the builder should they have issues at their homes rather than join the ongoing construction defect action. Under the law, clients can always talk to clients even if they are represented by counsel. While the attorneys for the builders cannot speak to the represented construction defect homeowners, the builder can communicate directly with its homeowners offering to honor its warranty and customer service procedures in lieu of the homeowner proceeding with the litigation. Both of these builder attempts to communicate with homeowners post-litigation have a dual effect – some homeowners elect to contact the builder to effectupate repairs and drop the litigation; while others elect to continue with the litigation. So proceed cautiously in this regard.
It is noted, there are many motivating factors for homeowners to bring a lawsuit against homebuilders that have nothing to do with the construction practices or customer service and are merely economically driven. However, these small steps in addition to providing solid construction practices should help curb construction defect litigation by homeowners.
Jason Daniel Feld is a founding partner of Kahana & Feld LLP, an AV Preeminent boutique litigation firm in Orange County specializing in construction defect, insurance defense, employment and general business litigation matters. The firm was founded with the goal of providing high-quality legal services at fair and reasonable rates. The firm believes that what defines attorneys is not their billing rates, but their record of success, which speaks for itself. For more information, please visit: www.kahanafeld.com.
Read the court decisionRead the full story...Reprinted courtesy of
California Court Holds No Coverage Under Pollution Policy for Structural Improvements
October 02, 2018 —
Brian Margolies - TLSS Insurance Law BlogIn its recent decision in Essex Walnut Owner L.P. v. Aspen Specialty Ins. Co., 2018 U.S. Dist. LEXIS 138276 (N.D. Cal. Aug. 15, 2018), the United States District Court for the Northern District of California had occasion to consider the issue of a pollution liability insurer’s obligation to pay for the redesign of a structural support system necessitated by the alleged presence of soil contamination.
Aspen’s insured, Essex, owned a parcel of property it was in the process of redeveloping for commercial and residential purposes. The project required excavation activities in order to construct an underground parking lot, and as part of this process, Essex designed a temporary shoring system comprising tied-in retaining walls in order to stabilize the area outside of the excavation. During the excavation work, construction debris was encountered requiring removal. Aspen agreed to pay for a portion of the costs to remove and dispose the debris under the pollution liability policy it issued to Essex.
Read the court decisionRead the full story...Reprinted courtesy of
Brian Margolies, Traub Lieberman Straus & Shrewsberry LLPMr. Margolies may be contacted at
bmargolies@tlsslaw.com
Florida “get to” costs do not constitute damages because of “property damage”
August 11, 2011 —
CDCoverage.comIn Palm Beach Grading, Inc. v. Nautilus Ins. Co., No. 10-12821 (11th Cir. July 14, 2011), claimant general contractor Palm Beach Grading (?PBG?) subcontracted with insured A-1 for construction of a sewer line for the project.  A-1 abandoned its work and PBG hired another subcontractor to complete construction of the sewer line.  The new subcontractor discovered that A-1?s work was defective requiring repair and replacement of portions of the sewer line which also required the destruction and replacement of surrounding work.
Read the full story…
Reprinted courtesy of CDCoverage.com
Read the court decisionRead the full story...Reprinted courtesy of
