Fire Raging North of Los Angeles Is Getting Fuel From Dry Winds
June 17, 2024 —
Brian K Sullivan - BloombergA wildfire raging north of Los Angeles has sent smoke billowing south and forced more than 1,000 people to evacuate — and with dry winds raking the hills, the blaze is poised to intensify.
A red flag fire warning has been raised in the area around the Post Fire, which is forecast to be whipped with winds reaching at least 20 miles (32 kilometers) per hour, according to the California Department of Forestry and Fire Protection, commonly called Cal Fire. The flames, which have burned more than 14,000 acres (5,700 hectares), are only about 8% contained and the smoke has prompted air quality alerts in parts of Los Angeles County and Ventura County.
“Crews are working to establish perimeter fire lines around the fire’s edges,” Cal Fire said in a report. “Aircraft are being utilized to halt the fire’s forward progress but are facing challenges due to limited visibility.”
Along with the Post Fire, crews are battling 10 other blazes throughout the state that flared up over the weekend in an ominous start to wildfire season. While California had heavy snow and rain this past winter, that doesn’t mean a respite from fires. The moisture that kept drought away allowed for grasses and brush to grow, meaning more wildfire fuel as California enters its driest months.
Read the court decisionRead the full story...Reprinted courtesy of
Brian K Sullivan, Bloomberg
Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?
January 27, 2020 —
Ted R. Gropman & Christine Z. Fan - ConsensusDocsConstruction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date.
Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved.
There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973).
Reprinted courtesy of
Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP
Mr. Gropman may be contacted at gropmant@pepperlaw.com
Read the court decisionRead the full story...Reprinted courtesy of
COVID-19 Response: Recent Executive Orders Present Opportunities for Businesses Seeking Regulatory and Enforcement Relief and Expedited Project Development
June 15, 2020 —
Karen C. Bennett, Jane C. Luxton & Amanda L. Tharpe - Lewis BrisboisWashington, D.C. (June 8, 2020) - Two recent Executive Orders (EO) aimed at promoting economic recovery from the COVID-19 crisis offer regulatory and enforcement relief and encourage agencies to expedite infrastructure project approvals. The May 19, 2020 EO 13924, “Regulatory Relief to Support Economic Recovery,” directs agencies to determine whether previous regulatory reforms would promote economic recovery if made permanent and encourages compliance assistance through exercising enforcement discretion, including declining enforcement. And the June 4, 2020 EO 13927, “Accelerating the Nation’s Economic Recovery from the COVID-19 Emergency by Expediting Infrastructure Investments and Other Activities,” aims to speed up the permitting process for infrastructure projects to strengthen the national economy. As businesses look to move forward and recover from the COVID-19 pandemic, they should closely review these EOs for opportunities to take advantage of streamlined treatment and faster project approvals.
EO 13294 supplements the Administration’s efforts to address the economic crisis brought on by the COVID-19 pandemic by encouraging federal agencies to rescind, modify, waive, or provide exemptions from federal regulations that may inhibit economic recovery and to provide guidance to businesses, particularly small businesses, on what is required of them under federal law for reopening. Specifically, the EO directs agency heads to identify regulatory standards that may inhibit economic recovery and consider rescinding or waiving those regulations, exempting regulated entities from compliance, exercising enforcement discretion, or extending regulatory compliance and enforcement deadlines. It also allows for compliance assistance through accelerated regulatory procedures to receive a pre-enforcement ruling and directs agencies to assess previous regulatory reforms to determine whether making them permanent would promote economic recovery. Since taking office, the Trump Administration has made regulatory reform a cornerstone of its agenda. This Executive Order is a continuation of the aggressive steps taken by the Administration to reduce the regulatory burden faced by American businesses that many argue increases operating costs, inhibits job creation, and stifles economic growth.
Reprinted courtesy of Lewis Brisbois attorneys
Karen C. Bennett,
Jane C. Luxton and
Amanda L. Tharpe
Ms. Bennett may be contacted at Karen.Bennett@lewisbrisbois.com
Ms. Luxton may be contacted at Jane.Luxton@lewisbrisbois.com
Ms. Tharpe may be contacted at Amanda.Tharpe@lewisbrisbois.com
Read the court decisionRead the full story...Reprinted courtesy of
East Coast Evaluates Damage After Fast-Moving 'Bomb Cyclone'
March 06, 2022 —
Scott Van Voorhis - Engineering News-RecordCoastal areas in the northeast US are assessing damage from a fast-moving “bomb cyclone” that caused temperatures to plummet, triggered heavy flooding and high winds, and dumped 2 ft of snow in some New England areas.
Reprinted courtesy of
Scott Van Voorhis, Engineering News-Record
ENR may be contacted at enr@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
He's the Top U.S. Mortgage Salesman. His Daughter Isn't Buying It
July 16, 2014 —
Lorraine Woellert – BloombergDavid Stevens, chief executive officer of the Mortgage Bankers Association, has spent his career lauding the merits of homeownership. One person still isn’t buying it: his daughter.
Sara Stevens, 27, knows interest rates are low, rents are high and owning a home can build wealth. She also had a front-row seat to the worst real-estate slump since the Great Depression.
“The world has changed,” she said.
Six years since the collapse of Lehman Brothers triggered a financial meltdown, some young adults are more risk averse and view the potential upsides of status and wealth more skeptically than before the crisis, altering the homeownership calculation. It’s more than the weight of student loans, an iffy job market and tight credit -- even those who can buy are hesitant.
Read the court decisionRead the full story...Reprinted courtesy of
Lorraine Woellert, BloombergMs. Woellert may be contacted at
lwoellert@bloomberg.net
Supreme Court Rejects “Wholly Groundless” Exception to Question of Arbitrability
February 06, 2019 —
Justin Fortescue - White and Williams LLPIn newly appointed Supreme Court Justice Brett Kavanaugh’s first opinion, the United States Supreme Court held that the “wholly groundless” exception to arbitrability, which some federal courts had relied on as justification to decide questions of arbitrability over the express terms of a contract, was inconsistent with the Federal Arbitration Act and Supreme Court precedent. Based on this decision, where a contract delegates the question of arbitrability to an arbitrator, courts must respect the parties’ contract and refer the question to the arbitrator. Schein v. Archer & White, 586 U.S. __ (2019).
In Schein, Archer & White brought a lawsuit against Henry Schein alleging violations of federal and state antitrust laws and seeking both monetary damages and injunctive relief. The relevant contract between the parties contained an arbitration provision that provided:
“Any dispute arising under or related to this Agreement (except for actions seeking injunctive relief . . .) shall be resolved by binding arbitration in accordance with the arbitration rules of the American Arbitration Association.”
Read the court decisionRead the full story...Reprinted courtesy of
Justin Fortescue, White and Williams LLPMr. Fortescue may be contacted at
fortescuej@whiteandwilliams.com
Alabama Appeals Court Rules Unexpected and Unintended Property Damage is an Occurrence
June 17, 2015 —
Beverley BevenFlorez-CDJ STAFFIn Pennsylvania National Mutual Casualty Insurance Company v St. Catherine of Siena Parish, a U.S. appeals court affirmed "that unexpected and unintended property damage is an ‘occurrence,’” reported Construction Equipment Guide. The underlying case involved roof leaks after the replacement of two Parish roofs, which ultimately led to a trial where Parish was awarded $350,000 in compensatory damages for breach of contract. However, Penn National disputed any obligation to pay, stating that “a breach of contract claim was not an ‘occurrence’ under the policy and even if such claims were an occurrence, the contractual liability and/or ‘your work’ exclusions would bar recovery.”
However, the U.S. District Court for the Southern District of Alabama ruled “that there was coverage for the property damage caused by the leaks because an ‘accident’ meant an unintended and unforeseen injury and the allegedly faulty workmanship led to damage to other areas of the structure and thus damage beyond simply the cost to replace the defective roof.”
Read the court decisionRead the full story...Reprinted courtesy of
Insurer’s Attempt to Shift Cost of Defense to Another Insurer Found Void as to Public Policy
June 09, 2016 —
Garret Murai – California Construction Law BlogWhile construction can sometimes be risky, construction litigation is almost always expensive. This volatile mix of risk and expense has made risk shifting, through indemnity and insurance, a primary goal and concern of project owners, contractors and suppliers alike. Construction insurers know this all too well and insurers, even between themselves, seek to shift risk.
As one primary insurer found, however, risk shifting provisions in their policies – specifically, one which sought to shift the cost of defense to another insurer – is not without its limitations.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Wendel Rosen Black & Dean LLPMr. Murai may be contacted at
gmurai@wendel.com
