Fairfield Connecticut Building Expert Directory

The Construction Project is Late—Allocation of Delay

November 17, 2016 — David Adelstein – Florida Construction Legal Updates
The construction project is late. Very late. The owner is upset and notifies the contractor that it is assessing liquidated damages. The contractor, in turn, claims that the project is late because of excusable, compensable delays and, perhaps, excusable, noncompensable delays. This is a common and unfortunate story between an owner and contractor on any late construction project. Now the fun begins regarding the allocation of the delay! Through previous articles, I discussed that in this scenario the burden really falls on the contractor to establish that the liquidated damages were improperly assessed against it and, thus, it is entitled to additional time and/or extended general conditions as a result of excusable delays. Naturally, this requires the contractor to develop a critical path analysis (time impact analysis) allocating the impacts / delays (and the reasons for the impacts/ delays) to the project completion date. The reason the burden really falls on the contractor is because the owner’s burden is relatively easy – the project was not complete on time pursuant to the contract and any approved changed orders. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.
Mr. Adelstein may be contacted at dma@katzbarron.com

Union THUGS Plead Guilty

October 15, 2014 — Craig Martin – Construction Contractor Advisor
Some time ago, I wrote about union THUGS (The Helpful Union Guys) that tormented merit shops to force contractors to use union labor on projects. The THUGS set fire to equipment, beat contractors with baseball bats, and picketed apartment complexes where contractors lived. Recently two of the ten union members plead guilty to arson-related charges, including two counts of maliciously damaging property by means of fire, extortion, and RICO conspiracy charges. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Alabama Court Determines No Coverage For Insured's Faulty Workmanship

June 28, 2013 — Tred Eyerly
The Alabama Supreme Court found there was no coverage for the insured cabinet maker for claims arising from alleged faulty workmanship. Shane Traylor Cabinetmaker, L.L.C. v. Am. Resources Ins. Co., Inc., 2013 Ala. LEXIS 42 (May 3, 2013). The insured was sued by a homeowner for property damage caused by faulty workmanship. The insurer refused to defend, contending there was no "occurrence." The trial court granted summary judgment to the insurer. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

Construction Up in Northern Ohio

October 02, 2013 — CDJ STAFF
Crain’s Cleveland Business reports that both commercial and residential construction have seen spending increases in the last twelve months. The gain was only 5.4%, but it’s still welcome in the area. “It’s been quiet so long, it wouldn’t take much to generate an upturn,” according to Tom Laird, of Gilbane Building Co. Some of the upturn comes from new building at universities and hospitals, but the corporate sector is also starting new project. Finally, the city of Cleveland is looking for proposals to develop parcels on their waterfront. Still, some are wary. “It might just be a bubble,” said Jason Jones, the general manager of Turner Construction’s Cleveland office. Read the court decision
Read the full story...
Reprinted courtesy of

Claim Preclusion: The Doctrine Everyone Thinks They Know But No One Really Knows What it Means in Practice

April 25, 2023 — Garret Murai - California Construction Law Blog
Generally, I think restraint in litigation is a good thing. Don’t go crazy on your claims, don’t go nut-so in your discovery, and don’t present your case at trial in a way that causes the judge and/or jury to raise their eyebrows or shake their heads in disbelief. But, as with nearly everything, there’s always an exception. One of which is: don’t hold back on a claim because you “think” you might be able to bring it later, because you might not be able to as the next case, 5th and LA v. Western Waterproofing Company, Inc., 87 Cal.App.5th 781 (2023), demonstrates. The 5th and LA Case At the outset, let me first say how much I enjoyed reading this case based on the writing alone. The case, as the 2nd District Court of Appeals states, involves “a second lawsuit about an increasingly leaky roof.” In 2012, property owner 5th and LA hired roofing contractor Western Waterproofing Company, Inc. to remove and recoat a parking lot that served also served as the roof over retail and office space below. Western completed its work in July 2012 and almost immediately 5th and LA noticed water that the coating was failing causing water leaks to the interior of the building. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Show Me the Money: The Good Faith Dispute Exception to Prompt Payment Penalties

March 13, 2023 — Garret Murai - California Construction Law Blog
California has a number of prompt payment penalty statutes on the books. Among them is Civil Code section 8800 which requires project owners on private works projects to pay progress payments to direct contractors within 30 days after demand for payment pursuant to contract or be subject to prompt payment penalties of two percent (2%) per month on the amount wrongfully withheld. Like California’s other prompt payment penalty statutes, however, there is an important carve out: If there is a good faith dispute between the project owner and the direct contractor the project owner may withhold up to 150% of the dispute amount and not be subject to prompt payment penalties. And that, my friends, is a higher-tiered party’s “get out of jail free” card. In a case of first impression, the 1st District Court of Appeals, in Vought Construction Inc. v. Stock (2022) 84 Cal.App.5th 622, examined whether a project owner’s claim for liquidated damages constitutes a good faith dispute under Civil Code section 8800. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Limited Number of Insurance-Related Bills Passed by 2014 Hawaii Legislature

June 11, 2014 — Tred R. Eyerly – Insurance Law Hawaii
Very few insurance-related bills survived the 2014 Hawaii Legislative session, with several consumer-friendly bills failing to make it out of committee. Here is a summary of the bills that passed: SB2365: Limits reimbursement of prescription medications in order to prevent drug prices from becoming an unreasonable cost driver of health care in workers' compensation and motor vehicle insurance claims. SB2470: Appropriates general funds to provide for the sustainability of the Hawaii Health Connector, but provides for greater transparency, stakeholder engagement, and legislative involvement in the activities of the Hawaii Health Connector. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

New York Considering Legislation That Would Create Statute of Repose For Construction

April 05, 2021 — Richard W. Brown & Anna M. Perry - Saxe Doernberger & Vita, P.C.
New York is considering legislation, which, if enacted, would create a statute of repose limiting the number of years after completion of a construction project that legal action may be asserted against a contractor. New York currently remains the only state without a statute of repose for construction. Earlier this year, however, the New York State Legislature introduced Bills S04127 and A01706 (the “Bill”) , which would impose a 10-year period of repose in which an injured party may bring suit against a design professional and/or a contractor for bodily injury or property damage resulting from a construction defect. Currently, contractors and design professionals have exposure to bodily injury and property damage claims resulting from construction defects for an unlimited number of years after completion of a project. If enacted, the Bill would limit the period of repose to 10 years after the project is completed, which is deemed to occur upon substantial completion or acceptance by the owner. An additional 1-year grace period is provided for an injured party to file suit where bodily injury or property damage occurs in the tenth year after completion. The Bill notably limits the applicability of the 10-year statute of repose to third-party actions and thereby preserves the existing 3-year and 6-year statutes of limitation applicable to actions asserted by an owner or client for professional malpractice and breach of contract, respectively. Reprinted courtesy of Richard W. Brown, Saxe Doernberger & Vita, P.C. and Anna M. Perry, Saxe Doernberger & Vita, P.C. Mr. Brown may be contacted at RBrown@sdvlaw.com Ms. Perry may be contacted at APerry@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES