Fairfield Connecticut Building Expert Directory

Supply Chain Delay Recommendations

August 07, 2022 — Denise Motta - Gordon & Rees Construction Law Blog
This Bulletin provides guidance to contractors, subcontractors, suppliers, and others to ensure compliance with contractual change order requirements in the event work on a construction project is impacted by supply chain delays. Contract Protection Tips: The construction industry is being impacted substantially by inability to obtain necessary construction products due to supply chain issues. Most construction contracts do not accommodate time extensions due to supply chain impacts. To address this gap in contract terms, we recommend including language such as: “lack of or failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers” as part of the defined force majeure event under the contract. This provision can be included in the Change Order section of the contract as well by including a provision such as: “If the Work is delayed by the failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers, contractor shall be entitled to a change order for its costs and time associated with the delay.” Read the court decision
Read the full story...
Reprinted courtesy of Denise Motta, Gordon Rees Scully Mansukhani, LLP
Ms. Motta may be contacted at dmotta@grsm.com

Insurer Must Pay To Defend Product Defect Claims From Date Of Product Installation

January 31, 2018 — Michael S. Levine & Brittany M. Davidson - Insurance Recovery Blog
An Iowa federal court recently ruled that an insurer must pay its policyholder’s defense costs from the date of installation of the allegedly faulty product, even though the underlying suits failed to allege when damage purportedly occurred. The ruling opens the door under each of the policyholder’s successive liability policies from 2000 to 2008, allowing the policyholder to recover millions of dollars in defense costs. The policyholder sought summary judgment concerning the date(s) on which the insurer’s defense obligation was triggered by fourteen of the fifteen claims asserted against it. The policyholder argued that the duty attached from the moment property damage potentially occurred, meaning the time when the underlying claimant installed or potentially could have installed the windows at issue in the underlying claims. The policyholder cited to the following evidence to support its claim: actual dates of installation (where available), dates of delivery, purchase or manufacture of the windows; and policy period referenced in the insurer’s claims notes as being potentially implicated by the claim. Reprinted courtesy of Michael S. Levine, Hunton & Williams and Brittany M. Davidson, Hunton & Williams Mr. Levine may be contacted at mlevine@hunton.com Ms. Davidson may be contacted at davidsonb@hunton.com Read the court decision
Read the full story...
Reprinted courtesy of

Improper Classification Under Davis Bacon Can Be Costly

April 01, 2015 — Craig Martin – Construction Contractor Advisor
The Department of Labor announced late last year that it had recovered nearly $2 million in back wages and fringe benefits from a subcontractor that provided constructions services at the federally funded Crescent Dunes Solar Energy Project in the Nevada desert. This was not a failure to pay Davis Bacon wages, but a failure to properly classify laborers on the project. The DOL determined that the laborers should have been paid as skilled trade steelworkers, not general laborers. As the subcontractor found out, this proved very costly. The subcontractor submitted its bid, classifying its laborers as general laborers and designating their wage at $30.00. The laborers were to assemble billboard sized mirrors on the project. There is some indication that the Department of Energy agreed with the classification, even though the Department of Labor has the final say on classifications. The Department of Labor’s investigation revealed that the laborers routinely performed duties in skilled trades, such as ironworking, electrical work, painting or bridge crane operation. Based on these activities, the Department of Labor concluded that the laborers should have been paid $60.00 per hour plus fringe benefits. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Gatluak Ramdiet Named to The National Black Lawyers’ “Top 40 Under 40” List

February 20, 2023 — Lewis Brisbois
New York, N.Y. (February 2, 2023) - New York Associate Gatluak Ramdiet was recently named to The National Black Lawyers (NBL) “Top 40 Under 40” list. The NBL “Top 40 Under 40” recognizes the most talented Black attorneys under the age of 40 who have an outstanding reputation among peers, the judiciary, and the public. The honorees on this list are nominated from leading lawyers, current members, and Executive Committee members. Mr. Ramdiet is a member of Lewis Brisbois' Medical Malpractice, Healthcare, Life Sciences, General Liability, Construction, and Toxic Tort & Environmental Litigation Practices. He represents individual and institutional clients in complex and high exposure claims, with particular experience handling matters involving catastrophic injuries and serious medical conditions. As part of the New York Medical Malpractice team, he regularly represents individual healthcare providers, including physicians, physician assistants, and nurse practitioners. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

Court Strikes Expert Opinion That Surety Acted as a “De Facto Contractor”

November 27, 2023 — David Adelstein - Florida Construction Legal Updates
Designating and admitting experts is a vital component of any construction dispute. Many construction disputes require experts. Many construction disputes can only be won with the role of an expert. Thus, experts and construction disputes go hand-in-hand. No doubt about it! Time needs to be spent on developing the right expert opinions to support your burden of proof. This means you want to designate the right expert that can credibly and reliably render an expert opinion. It is common for one party to move to strike the testimony and expert opinions of another party. This is referred to as a Daubert motion. Sometimes the motion is about gamesmanship. Sometimes it is to see how the judge rules on the issue. Sometimes there is a legitimate reason associated with the expert opinion. And, sometimes, it is a combination of the above. Regardless of the reason, parties know the weight expert opinions can have and, therefore, treat the opinions seriously prompting the Daubert motion. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

BHA’s Next MCLE Seminar in San Diego on July 25th

July 02, 2014 — Beverley BevenFlorez-CDJ STAFF
There are just three weeks remaining to sign up for Bert L. Howe & Associate’s next California MCLE seminar, UNDERSTANDING CONSTRUCTION DEFECT LITIGATION. This activity will be presented on Friday, July 25th at noon, in BHA’s San Diego offices, located at: 402 W. Broadway Suite 400 San Diego, CA 92101 There is no cost for attendance at this seminar and lunch will be provided. This course has been approved for Minimum Continuing Legal Education credit by the State Bar of California Committee on MCLE in the amount of 1.0 credit hours, of which 0.0 credit hours will apply to legal ethics/professional responsibility credit. The seminar will be presented by Charlie Miller, general contractor and project manager. Water intrusion through doors, windows and roofing systems, as well as soil and foundation-related movement, and the resultant damage associated therewith, are the triggering effects for the vast majority of homeowner complaints today and serve as the basis for most residential construction defect litigation. The graphic and animation-supported workshop/lecture activity will focus on the residential construction process from site preparation through occupancy, an examination of associated damages most often encountered when investigating construction defect claims, and the inter-relationships between the developer, general contractor, sub trades and design professionals. Typical plaintiff homeowner/HOA expert allegations will be examined in connection with those building components most frequently associated with construction defect and claims litigation. The workshop will examine: • Typical construction materials, and terminology associated with residential construction • The installation process and sequencing of major construction elements, including interrelationship with other building assemblies • The parties (subcontractors) typically associated with major construction assemblies and components • An analysis of exposure/allocation to responsible parties. Attendance at THE UNDERSTANDING CONSTRUCTION DEFECT LITIGATION seminar will provide the attendee with: • A greater understanding of the terms and conditions encountered when dealing with common construction defect issues • A greater understanding of contractual scopes of work encountered when reviewing construction contract documents • The ability to identify, both quickly and accurately, potentially responsible parties • An understanding of damages most often associated with construction defects, as well as a greater ability to identify conditions triggering coverage To register for the event, please email Charlie Miller at cmiller@berthowe.com. If you have any questions, please feel free to contact Charlie at (800) 482-1822 (office) or (714) 353-1959 (cell). Read the court decision
Read the full story...
Reprinted courtesy of

Appeals Court Rules that Vertical and Not Horizontal Exhaustion Applies to Primary and First-Layer Excess Insurance

August 31, 2020 — Christopher Kendrick & Valerie A. Moore – Haight Brown & Bonesteel LLP
In Santa Fe Braun v. Ins. Co. of North America (No. A151428, filed 7/13/20), a California appeals court relied on Montrose Chemical Corp. of California v. Superior Court (2020) 9 Cal.5th 215 (Montrose III), to hold that absent express policy wording to the contrary, horizontal exhaustion of all primary insurance is not required in order to trigger first-layer excess coverage. Beginning in 1992, Braun was sued for asbestos injuries from refineries it constructed and maintained. Braun had primary coverage and multiple layers of excess coverage for the relevant time period. After defending for years, the primary insurers reached a settlement under which they paid their limits into a trust which would fund the ongoing defense and settlements. Certain of the excess insurers settled and also contributed to the trust. Reprinted courtesy of Christopher Kendrick, Haight Brown & Bonesteel LLP and Valerie A. Moore, Haight Brown & Bonesteel LLP Mr. Kendrick may be contacted at ckendrick@hbblaw.com Ms. Moore may be contacted at vmoore@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Governmental Immunity Waived for Independent Contractor - Lopez v. City of Grand Junction

September 17, 2018 — Frank Ingham - Colorado Construction Litigation Blog
On July 12, 2018, the Colorado Court of Appeals announced its decision in Lopez v. City of Grand Junction, 2018 WL 3384674 (Colo. App. 2018). The Court considered whether immunity is waived under Colorado’s Governmental Immunity Act (“CGIA”), pursuant to section C.R.S. § 24-10-106(1)(f), in situations where the public entity hired an independent contractor to perform the work. The Court held that if the public entity would have been liable under the CGIA for the conduct that caused the injury, had it performed the work itself, then it is liable for the work performed by its independent contractor. Read the court decision
Read the full story...
Reprinted courtesy of Frank Ingham, Higgins Hopkins McClain & Roswell, LLC
Mr. Ingham may be contacted at ingham@hhmrlaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES