Seattle Washington Building Expert Directory

BWB&O Partners are Recognized as 2022 AV Preeminent Attorneys by Martindale-Hubbell!

December 06, 2021 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Congratulations to BWB&O Partners on their recognition in Martindale-Hubbell® as AV Preeminent attorneys. This honor is given to attorneys who are ranked at the highest level of professional excellence for their legal expertise, communication skills, and ethical standards by their peers. Newport Beach Partner, Nicole Whyte Newport Beach Partner, Keith Bremer Newport Beach Partner, John Toohey Newport Beach Partner, Jeremy Johnson Woodland Hills Partner, John O'Meara Woodland Hills Partner, Patrick Au Arizona Partner, John Belanger Las Vegas Partner, Peter Brown Las Vegas Partner, Lucian Greco Las Vegas Partner, Anthony Garasi San Diego Partner, Vik Nagpal San Diego Partner, Alexander Giannetto Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Depreciating Labor Costs May be Factor in Actual Cash Value

April 20, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The Minnesota Supreme Court considered a certified question from the the U.S. District Court regarding consideration of depreciating labor costs in determining the actual cash value of a loss. Wilcox v. State Farm Fire & Cas. Co., 2016 Min. LEXIS 50 (Minn. Feb. 10, 2016). The insureds' home was damaged by hail. State Farm provided a written estimate that calculated the actual cash value of the loss. To estimate the actual cash value of the damaged property, State Farm first calculated the replacement costs of individual items, such as roof flashing, siding, fascia, gutters, and window screens. Next, State Farm subtracted the pre-loss depreciation of some, but not all, individual items. For example, State Farm depreciated the cost of removing and replacing certain materials, such as siding. State Farm did not depreciate the cost of the new siding separately from the cost of the labor required to install the new siding on the home. Instead, State Farm calculated the removal and replacement of the siding as a single cost, then depreciated the removal-and-replacement cost as a whole. The cost of labor to repair or replace the damaged property was referred to by the court as "embedded labor costs." Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Implied Warranty Claims–Not Just a Seller’s Risk: Builders Beware!

May 10, 2021 — Carin Ramirez - Colorado Construction Litigation
One of the thorns in the side of every construction defect defense litigator is the implied warranty claim. The “implied warranty” is a promise that Colorado law is “implied” into every contract for a sale of a new home that the home was built in a workmanlike manner and is suitable for habitation. Defense attorneys dislike the implied warranty claim because it is akin to a strict liability standard. All that is required to provide the claim is that an aspect of construction is found to be defective — i.e., inconsistent with the building code or manufacturer’s installation instructions — regardless of whether the work was performed to the standard of care. The implied warranty claim is therefore easier to prove than a negligence claim, where a claimant must prove that a construction professional’s work fell below a standard of reasonable care. Additionally, it is not a defense to an implied warranty claim that the homeowners or the HOA are, themselves, partially liable for the defects where damage is due in part to insufficient or deferred maintenance, as it is for negligence claims. The only redeeming aspect to the implied warranty claim was that, until recently, it was believed that it could only be asserted by a first purchaser against the seller of an improvement, because the implied warranty arises out of the sale contract. Recently, the Colorado Court of Appeals opinion in Brooktree Village Homeowners Association v. Brooktree Village, LLC, 19CA1635, decided on November 19, 2020, extended the reach of the implied warranty — though just how far remains to be seen. Specifically, a division of the Court of Appeals held that an HOA can assert implied warranty claims on behalf of its members for defects in common areas, even where there is no direct contractual relationship between the parties to base the warranty upon. Read the court decision
Read the full story...
Reprinted courtesy of Carin Ramirez, Higgins, Hopkins, McLain & Roswell, LLC
Ms. Ramirez may be contacted at ramirez@hhmrlaw.com

Building 47 Bridges in Two Years

December 23, 2023 — Dan Sopczak - Construction Executive
Every construction project has its challenges, but some truly push the boundaries of what is achievable in the heavy civil industry. When the Indiana Department of Transportation sought to modernize its I-65/I-70 North Split Interchange in Indianapolis, Indiana, its request for proposals included building 47 new bridges and rehabilitating six additional bridges on an ambitious two-year timeline—905 days to substantial completion. “Three design-build teams responded to the RFQ, and the same three teams responded to the RFP,” according to INDOT Strategic Communications Director Natalie Garrett. “Proposals were scored and evaluated using the best-value evaluation process defined by INDOT. The score was a combination of a technical proposal score and a price score.” Reprinted courtesy of Dan Sopczak, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Court of Appeals Discusses the Difference Between “Claims-Made” and “Occurrence-Based” Insurance Policies

May 31, 2021 — Garret Murai - California Construction Law Blog
As most contractors know, scope, price and time are the “big” three in any construction contract. Nearly as important, however, are the insurance provisions. Patricularly, when things go bad on a construction project. As the next case, Guastello v. AIG Specialty Insurance Company 61 Cal.App.5th 97 (2021) discusses, the difference between “claims-made” versus “occurrence-based” coverage can be extremely important. The Guastello Case In 2003 and 2004, subcontractor C.W. Poss Inc. built retaining walls in the Pointe Monarch housing development in Dana Point, California. Poss performed all related excavation, ground and grading work. In 2006, Thomas Guastello purchased a home in the development, and in January 2010, a retaining wall close to his lot suffered a massive failure that causing over $700,000 in damages. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Kahana Feld Welcomes Six Attorneys to the Firm in Q4 of 2023

January 16, 2024 — Linda Carter - Kahana Feld
Kahana Feld is pleased to announce the addition of six attorneys to the team in the fourth quarter of 2023. We are excited to have each of these individuals on the team. In our Houston office, Kahana Feld welcomes Partner Donald Loving II and Attorney Elliott Wright. Mr. Loving is a member of the General Liability and Trucking & Transportation practice groups. He earned his Juris Doctor from the University of Houston and has over 30 years of litigation and trial experience, including working as staff & corporate counsel for several prominent insurance carriers including GEICO, Progressive, USAA and Travelers. Mr. Wright is a member of the Construction Defect, General Liability, and Trucking & Transportation practice groups. He earned his Juris Doctor from SMU Dedman School of Law, and has extensive litigation and insurance defense experience. Read the court decision
Read the full story...
Reprinted courtesy of Linda Carter, Kahana Feld
Ms. Carter may be contacted at lcarter@kahanafeld.com

AI-Powered Construction Optioneering Today

April 08, 2024 — Aarni Heiskanen - AEC Business
In this episode of the AEC Business Podcast, Aarni Heiskanen interviews René Morkos, the founder and CEO of ALICE Technologies. They discuss construction tech, AI, and ALICE Core, the company’s latest product launch. How the Construction Technology Landscape has Changed The construction tech industry has evolved significantly since 2015, as discussed with René. In 2015, there was a lack of understanding and reluctance toward construction tech, with some investors even hesitant to invest in the sector. However, by 2017-2018, there was a noticeable shift as construction tech became a sought-after investment opportunity. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES