The Contractor’s Contingency: What Contractors and Construction Managers Need to Know and Be Wary Of
December 04, 2023 —
Skyler L. Santomartino - Peckar & Abramson, P.C.Contractors and construction managers who enter into cost reimbursable contracts subject to a guaranteed maximum price (GMP) are responsible for all project costs exceeding the GMP. For this reason, it is imperative that contractors negotiate and incorporate into the GMP a financial buffer that accounts for the unanticipated project costs that are not reimbursable as change orders or costs of the work. This is where the contractor’s contingency comes into play.[
1]
The contractor’s contingency is a vehicle that allows contractors to mitigate some of the risks inherent in GMP contracts. When drafted properly, a contingency clause allows the contractor and only the contractor to access funds set aside by the owner to address unpredictable or unknown project costs.
Read the court decisionRead the full story...Reprinted courtesy of
Skyler L. Santomartino, Peckar & Abramson, P.C.Mr. Santomartino may be contacted at
ssantomartino@pecklaw.com
Residential Construction Rise Expected to Continue
May 10, 2013 —
CDJ STAFFHousingwire reports that Fannie Mae has predicted strong increases in housing starts over the last few years, with an expected return to normal by 2016. If this holds true, residential construction will include 2.5 million jobs.
Read the court decisionRead the full story...Reprinted courtesy of
New York’s Second Department Holds That Carrier Must Pay Judgment Obtained by Plaintiff as Carrier Did Not Meet Burden to Prove Willful Non-Cooperation
November 23, 2020 —
Craig Rokuson - Traub LiebermanIn the recent case of DeLuca v. RLI Insurance Company, 2020 WL 5931054 (October 7, 2020), the Supreme Court, Appellate Division, Second Department held that RLI had a duty to pay a judgment obtained by an underlying plaintiff against RLI’s insured, MLSC. The underlying plaintiff brought the action directly against the carrier after obtaining a judgment against MLSC, and when the judgment remained unsatisfied, serving RLI with the judgment. As an initial matter, the court found that the direct action by the plaintiff was proper under New York Insurance Law 3420(a), which allows for an injured plaintiff to maintain a direct action against a carrier if a judgment against that carrier’s insured remains unsatisfied for a period of 30 days and the carrier is served with that judgment. In that event, the plaintiff steps into the shoes of the insured and is entitled to the rights of the insured (and is also subject to the carrier’s coverage defenses).
Reprinted courtesy of
Craig Rokuson, Traub Lieberman
Mr. Rokuson may be contacted at crokuson@tlsslaw.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense
October 01, 2024 —
David Adelstein - Florida Construction Legal UpdatesA federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!!
In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:
The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.
Jackson Construction Co., supra, at 90.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Kahana & Feld P.C. Enhances Client Offerings, Expands Litigation Firm Leadership
March 22, 2017 —
Kahana & Feld, P.C.SANTA ANA, Calif., March 9, 2017 – Celebrating 10 successful years of practice, Managing Partner
Amir M. Kahana, Esq. , of Kahana & Feld P.C. (formally Kahana Law), is pleased to announce he has added as name partner
Jason Daniel Feld, Esq., expanding client offerings to include insurance defense and bolstering its construction defect and real estate law practice.
Feld joins the AV Preeminent firm that for the past decade has become known for its prowess in general business litigation matters, including cases involving employment, construction, real estate and intellectual property law. The firm is home to a group of proven trial attorneys who are among Southern California’s top rated counsel.
Feld brings 18 years of experience, with his practice focusing on defending homebuilders, contractors and developers in Arizona, Texas and California. He primarily chooses to represent smaller, family-owned and operated clients, providing the unique opportunity to also assist with overall best practices and risk prevention. In addition, Feld serves on several prominent insurance carrier panels, allowing him to cultivate valuable relationships with the builder and contactor community. A resident of Tustin Ranch, Feld received his juris doctor cum laude from Whittier Law School and a bachelor’s degree from University of Houston.
“Jason’s breadth of experience, leadership and work ethic are qualities I have admired throughout the many years of our friendship. He embodies the integrity and admirable character that are at the core of our firm’s fabric,” said Kahana, a resident of Irvine. “I am thrilled to have Jason join forces with our firm as we enter our second decade and are poised for significant growth. Our clients will benefit from our expanded areas of practice, allowing us to provide counsel and litigation support in a variety of areas.”
Under Kahana’s leadership, the firm has become known for holding its client relationships in the highest regard while providing premier quality legal services and sound risk assessment at a reasonable cost. With integrity always coming first, the firm’s record of success extends well beyond the office as each associate is proudly involved in his or her community, donating time and resources to a variety of worthy community organizations.
“I feel honored to join Amir and this talented and energetic firm,” said Feld. “I feel fortunate to have found a new home with partners and associates who share the same values and commitment to serving the community. I look forward to helping grow the firm in the years ahead.”
About Kahana & Feld, P.C.
Kahana & Feld, P. C. focuses on general business litigation and insurance defense, with particular emphasis on employment, real estate, construction defect and intellectual property litigation. The AV Preeminent firm is led by attorneys who have been named among Southern California’s Top Rated. The firm was founded with the goal of providing high-quality legal services at fair and reasonable rates. The firm believes that what defines attorneys is not their billing rates, but their record of success, and Kahana & Feld’s track record speaks for itself. For more information, please visit: http://www.kahanafeld.com
Read the court decisionRead the full story...Reprinted courtesy of
New York Considers Amendments to Construction Industry Wage Laws that Would Impose Significant Burden Upon Contractors
August 04, 2021 —
Richard W. Brown & Michael D. Angotti - Saxe Doernberger & Vita, P.C.A bill that would amend the the wage and hour requirements of the New York Labor Law was recently passed by the New York State Legislature and is expected to be signed by Governor Cuomo. Bill Number S2766C (the “Bill”) is intended to protect construction workers against wage theft. However, it places a heavy burden on contractors to police the payroll practices of its downstream subcontractors and exposes them to potentially significant liability for the wage and hour violations of their subcontractors.
The proposed Bill would make a contractor or upstream subcontractor jointly and severally liable for any wages owed to employees of their subcontractors. The Bill allows for a private right of action for such subcontractor’s employee (or such employee’s representative) to bring a civil or administrative action seeking payment of unpaid wages owed pursuant to Section 198 of the New York Labor Law. In such an action against a subcontractor for unpaid wages, the contractor or upstream subcontractor is not only jointly and severally liable for any unpaid wages, but also for the prevailing claimant’s reasonable attorney fees, prejudgment interest, and, absent a good faith defense, liquidated damages equal to the amount of the wages owed.
Reprinted courtesy of
Richard W. Brown, Saxe Doernberger & Vita, P.C. and
Michael D. Angotti, Saxe Doernberger & Vita, P.C.
Mr. Brown may be contacted at RBrown@sdvlaw.com
Mr. Angotti may be contacted at MAngotti@sdvlaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Housing Starts in U.S. Surge to Seven-Year High as Weather Warms
May 20, 2015 —
Sho Chandra – BloombergNew residential construction in the U.S. surged in April to the highest level in more than seven years, indicating the industry has moved beyond a weather-related soft patch to regain strength.
Housing starts jumped 20.2 percent to a 1.14 million annualized rate, the most since November 2007, from a 944,000 pace in March, a Commerce Department report showed Tuesday in Washington. The median forecast of 83 economists surveyed by Bloomberg was 1.02 million. More permits, a proxy for future construction, were issued than at any time since June 2008.
An improving labor market and mortgage costs close to multiyear lows are reviving residential construction, a sign that the weakness in early 2015 was probably due to harsh winter weather. Builders including PulteGroup Inc. have said the spring selling season is off to a good start, and sentiment data for May showed developers are optimistic about the next six months.
Read the court decisionRead the full story...Reprinted courtesy of
Shobhana Chandra, Bloomberg
Property Owner’s Defense Goes Up in Smoke in Careless Smoking Case
September 23, 2019 —
Michael J. Ciamaichelo - The Subrogation StrategistProperty owners owe a duty of reasonable care to avoid causing harm to neighboring properties. When a property owner knows or should know about a condition that poses a risk of danger to neighboring properties, the property owner must exercise reasonable care to make the condition safe. The Court of Special Appeals of Maryland recently held that, where hundreds of discarded cigarette butts had accumulated in a bed of mulch over an extended period of time prior to the fire at issue, the owner of the property with the mulch beds owed a duty of care to its neighbors to prevent a foreseeable fire.
In Steamfitters Local Union No. 602 v. Erie Insurance Exchange, 2019 Md. App. LEXIS 430 (May 30, 2019), a fire originated in a strip of mulch at property owned by the Steamfitters Local Union No. 602 (Union) and caused damage to neighboring properties. The fire occurred when an unknown person discarded a cigarette butt into the mulch. Following the fire, investigators found “hundreds, if not thousands of cigarettes” in the mulch where the fire originated. A representative for the Union acknowledged that there were more butts in the mulch “than there should have been” and that, “[i]n the right situation,” a carelessly discarded cigarette could cause a fire. The Union, however, had no rules or signs to prohibit or regulate smoking at the property, where apprentices would often gather prior to class.
The insurance companies for the damaged neighbors filed subrogation actions alleging that the Union, as the property owner, failed to use reasonable care to prevent a foreseeable fire. A jury found in favor of the subrogating insurers and against the Union.
Read the court decisionRead the full story...Reprinted courtesy of
Michael J. Ciamaichelo, White and Williams LLPMr. Ciamaichelo may be contacted at
ciamaichelom@whiteandwilliams.com